中英文双语合同【汇集20篇】

中英文客户交易协议

scope of agreement (协定的范围)

all transactions and all contracts entered into between snc ??and the customer, shall be governed by the terms of this customer agreement and the terms of any additional written statements of snc ??trading regulations or snc ??additional schedules which may from time to time be set forth or amended by snc ??and which shall thereupon constitute a portion of this customer agreement, except to the extent (if any) that snc ??shall agree or notify the customer in writing that other or additional terms apply. any proposals for, additions to, or modifications of this agreement, absent written agreement by an authorized person employed by snc ??to the contrary, are void and shall have no effect.

snc 和客户之间所有交易和所有合同应受本项客户协议和任何关于snc 的交易规章，或snc 所有的附加条款约束。snc 可能随时设定或更改这些条款而即时构成客户协议的一部分。如有必要(如果有的话)，如须采用其他或附加的条款，snc 应以书面形式同意或通知客户。任何对此协议的补充或修改建议，如没有由snc 聘请的授权人的书面协议，均为无效。

this agreement refers and extends to a potential dealing relationship between the customer and snc in otc non-deliverable foreign exchange (currencies) on a spot settlement basis as is commonly dealt in the international interbank market, and all other provisions of this agreement notwithstanding, the customer agrees, understands and warrants that the dealing relationship between the customer and snc ??hereunder shall not extend at any time to the dealing, trading, brokering of or advice related to any exchange listed.

这项协议提及并延伸到客户和snc 之间潜在交易关系。此关系是指在国际银行间市场，按本协议规定的场外即时外汇交易关系。客户同意、理解和认同其与snc 的交易关系，在任何时候都不涉及任何交易所的做市，交易或代理活动。

subject to the terms and conditions of this agreement, the full completion of the account setup requirements and acceptance of customer’s application to open an account with snc , snc ?will open and maintain account(s) in customer’s name for the purpose of engaging in cash settled transactions with and for customer in currencies markets on a spot settlement basis, and provide such other services and products as snc ?may, in its sole discretion, determine to offer in the future. unless expressly stated otherwise in writing, all contracts and other transactions entered into between snc and customer shall be governed by the terms of this customer agreement, including the risk disclosure statement and snc ?trading policies, to the extent annexed hereto, as amended from time to time.

根据符此项协议的条件，从接受客户的申请snc 开户到帐户的全面设置和完成，snc 须以客户的名义维护并为客户在帐户从事现金结算和在货币市场上现货结算；并在将来提供其他服务和产品。除非另有书面明文规定，所有合同及其他snc 与客户应受本客户协议，包括风险声明，snc外汇交易政策，需在必要时修订。

risk acknowledgements （风险须知）

customer acknowledges and understands that trading and investment in leveraged otc foreign currency contracts is highly speculative, involves an extreme degree of risk, and is generally appropriate only for persons who can assume risk of loss in excess of their margin deposit. customer understands that because of the low margin/high leverage normally available in foreign currency trading, price changes in foreign currency contracts may result in significant losses. such losses may substantially exceed customer’s investment and margin deposit. by customer directing snc ?to enter into any foreign currency contract, any profit or loss arising as a result of a fluctuation in the exchange rate affecting such currency will be entirely for the customer’s account and risk.

客户确认并明白，交易和投资在场外杠杆式外汇合约是有高度投机性，涉及极端的风险程度，而且通常只适合可承担损失超过其保证金风险的人。客户理解，由于低保证金/高杠杆作用，进行外币交易时，外币汇率收缩引起的价格变动可能导致重大损失。这种损失可能大大超出客户的投资金额和保证金。客户通过snc 进入任何外汇合同，由于货币的汇率波动所造成的利润或亏损将完全属于账户承担的风险。

customer warrants that the customer is willing and able, financially and otherwise, to assume the risk of foreign currency trading, and in consideration of snc ??carrying his/her account(s), customer agrees not to hold snc ??responsible for losses incurred through following its trading recommendations or suggestions or those of its employees, agents or representatives. customer recognizes that guarantees of profit or freedom from loss cannot be given and it is impossible to predict performance in foreign currency trading. customer acknowledges that customer has received no such guarantees from snc ??or from any of its representatives or any introducing broker or other entity with whom customer is conducting his/her snc ??account and has not entered into this agreement in consideration of or in reliance upon any such guarantees or similar representations. all transactions effected for customer’s accounts and all fluctuations in the market prices of the contracts carried in customer’s accounts are at customer’s risk, and customer shall be solely liable therefore under all circumstances. customer represents and warrants that customer is willing and financially able to sustain such losses, and that the trading of spot foreign exchange (currencies) is a suitable investment vehicle for the customer. snc ?is not responsible for delays or partial or total failures in any online (electronic) trading platforms or any communications facility or other causes beyond snc ?reasonable direct control. the customer understands and recognizes that the transactions to be conducted pursuant to this agreement are not conducted on a regulated market or exchange. customer represents that it is aware of the risks inherent in the trading of otc foreign exchange (currencies) and is financially able to bear such risks and withstand any losses incurred. (for a further discussion on the risks of trading foreign exchange please refer to the risk disclosure statement).

客户权证，其愿意且能够在财务上承担外币交易的风险；并考虑虽然他/她的帐号是由snc 开通，如其雇员，代理人或代表提供交易建议，他们对建议导致的亏损不负任何责任。客户要知道，在外币交易中担保或保证免受损失和预测交易回报是不可能的。客户要理解snc 或任何其代表或任何介绍经纪人或其他实体对客户在他/她的snc 外汇账户的任何交易也没有这类的担保。在任何情况下，客户须对所有所有与帐户相关的交易或者因市场价波动引起的风险承担全部责任和风险。客户须愿意并在经济上承担交易损失，并同意即时外汇交易是合适的投资产品。在snc 无法直接控制的情况下，snc 对任何因网上(电子)交易平台或任何通讯设施或其他原因造成的延时，部分或完全故障不负任何责任。客户需理解并确认依照本协定进行交易与在规范的市场或交易所进行的交易有所不同。客户须知在场外或电子外汇交易所涉及到的风险并且具有承担亏损的经济能力。(对进一步关于外汇交易的风险的讨论，请参阅风险声明)。

?customer’s representations and warranties (客户的事实陈述和保证)

as of the date hereof, the date of each contract and other transaction in customer’s account and any date on which snc ?risk disclosure statement or trading policies are revised, updated or amended, customer represents and warrants to snc ??and agrees for the benefit of snc ??that:

自每份合同签订的日期及在客户的帐户中任何交易的日期起，或者对任何snc 风险声明或交易规定的修改日起，对于所有修改或更新，客户向snc表明及保证，并站在snc 的利益角度同意以下：

customer is of sound mind, legal age (18 in the usa) and legal competence.

客户是理智，达到法定年龄(在美国为十八岁)和遵循法律规定。

customer (if not a natural person) is duly organized and validly existing under the applicable laws of the jurisdiction of its organization.

客户(如果不是自然人)，是有效存在正式组建并经由法律管辖的组织。

execution and delivery of this agreement and all contracts and other transactions contemplated hereunder and performance of all obligations contemplated under this agreement and all contracts and other transactions contemplated hereunder have been duly authorized by customer.

本协定的所有合同和其他在第二十八条和所有根据这项协议的义务下的合同，所有合同和由授权的顾客按照第二十八条规定的义务下执行和实施的其他交易。

each person executing and delivering this agreement and all contracts and other transactions contemplated hereunder on behalf of customer performing the obligations contemplated under this agreement and any contract and other transaction contemplated hereunder on behalf of customer, has been duly authorized by customer to do so.

每个人的执行和兑现这项协议，所有合同和其他以第二十八条代表客户履行合同义务的交易合同，这项协议和任何合同和其他交易下，谨代表客户的利益。

execution and delivery by customer of this agreement and all contracts and other transactions contemplated hereunder, and performance of all of customer’s obligations contemplated under this agreement and any contract and other transaction contemplated hereunder, will not violate any statute, rule, regulation, ordinance, charter, by-law or policy applicable to customer. ???????????

客户根据本协定的所有合同和其他交易的情况的执行、交付，所有客户的合同义务的行为应依照这项协议和任何合同和其他交易的情况，不违反任何法规、规则,规章、条例、章程，法律或政策适用于顾客。

customer has full beneficial ownership of customer’s account. customer has not granted and will not grant a security interest in customer’s account with snc ?(other than the security interest granted to snc ?hereunder) to any person without snc ?prior written consent. customer has full beneficial ownership of all collateral and will not grant any security interest in any collateral to any person (other than the security interest granted to snc ?hereunder) without prior written consent of snc .

客户已拥有客户帐户的全部实益。客户在snc 帐户没有且而不会有对未经snc 事先书面同意的任何人给予权益担保(除第二十八条安全利益给予snc )。客户拥有所有抵押的的充分实益，也不会在任何人未经snc 事先书面同意的任何抵押中给予任何权益担保(除下文中利益安全给予了snc )。

customer will execute and deliver all documents, give all notices, make all filings and take such other actions as snc , in its sole discretion, deems necessary or desirable to evidence or perfect any security interest in favour of snc ?or to protect snc ?interests with respect to any collateral.

客户将像snc 一样自主执行和提供所有文件，发出所有通知，进行所有备案和采取其他行动。在其认为必要或适宜时，为了有利于snc ，对任何抵押提供证明或者表示尊重。

customer hereby warrants that regardless of any subsequent determination to the contrary, customer is suitable to trade foreign currency and is a sophisticated foreign exchange investor.

客户在此保证，不论之后有何相反的决定，客户是适合进行外汇交易，而且是成熟的外汇投资者。

customer has read and understands the risk disclosure statement contained in this agreement. customer will review snc ?risk disclosures, including, without limitation, snc ?risk disclosure statement, each time they are amended. customer will not affect any opening transaction in customer’s account unless customer understands snc ?revised risk disclosures, and customer agrees that in effecting any opening transaction it is deemed to represent that it has read and understands snc ?revised risk disclosures as in effect at the time of such opening transaction.

客户已阅读并了解本协议的风险声明。在每次对snc 风险声明修订后，客户需无限制的重新阅读声明内容。客户不会影响客户的帐户中的任何开盘交易的，除非客户明白snc 风险披露的修改，和客户同意在实际开盘交易时的任何开盘交易进行均被视为已经阅读并理解已修改的snc 外汇风险披露。

customer has read and understands the trading policies contained in this agreement, including, without limitation, snc ?trading policies. customer will review snc trading policies, including, without limitation, snc ?trading policies each time they are amended. customer will not affect any opening transaction in customer’s account unless customer understands snc revised trading policies, and customer agrees that in effecting any opening transaction it is deemed to represent that it has read and understands snc ?revised trading policies as in effect at the time of such opening transaction.

客户已经阅读并理解载于本协议的买卖政策，包括但不限于snc 交易政策。客户将审查snc 买卖政策，其中包括但不限于snc 交易政策每次都被修订。顾客不会影响任何开盘交易的客户的帐户，除非客户明白snc 买卖政策的修改，和客户同意在实际开盘交易时的任何开盘交易进行均被视为已经阅读并理解已修改的snc 外汇买卖政策。

customer acknowledges that customer has conducted simulated trading using the snc demo trading platform for a period that has allowed the customer to develop a full understanding of the snc ?internet trading platform an online trading system for spot foreign exchange real-time trading.

客户承认曾使用snc 进行模拟外汇交易演示平台，已经允许客户建立一个对snc 外汇网上交易平台的全面认识，为即期外汇实时交易的网上交易系统。

all information provided by customer to snc , including information regarding customer’s trading experience and investment sophistication, is true, correct and complete, and customer will notify snc ?promptly of any changes in such information.

所有客户提供给snc 的外汇信息，包括客户真实、正确及完整的交易经验和投资的复杂化，客户将通知snc 外汇及时更改这些信息。

trading （交易）

4.1???? authorization to trade for customer’s account

subject to the terms of this agreement and all related agreements, including the risk disclosure statement and snc ??trading policies document hereto, the customer account application and any applicable addenda thereto, customer authorizes snc ??to enter, purchase, sell, and clear otc foreign exchange contracts on a spot basis for the customer’s account in accordance with customer’s electronic, written or oral instructions received through the snc ?internet trading platform - an online trading system connected directly to the snc ??trade execution desk, via telephone directly to the snc ??trade execution desk, or via any other communicative means available.

本协议相关的条款和所有的承诺，包括snc 外汇风险披露声明和snc 交易政策文件，客户帐户申请书和任何适用的增编，客户授权snc 外汇进行交易。在现货的基础上按照客户的电子、书面或口头指示为客户的账户，通过snc 外汇网上交易平台——网上交易系统直接与snc 连接应用，可以透过电话或其他通信手段直接连接到snc 外汇交易服务台，明确场外外汇买卖合约

customer agrees to be responsible for any transaction instruction received by snc either electronically via the snc ??internet trading platform (or similar product), or orally over the telephone.? before executing a transaction, snc will require the customer at least?? to provide user name and password authorization electronically via a login procedure or if contacted via the telephone, orally via an identification procedure.? correct information will authenticate the customer and allow the customer to conduct transactions in the authorized snc account for that authentication.

客户同意对snc 通过snc 网上交易平台 (或类似产品)，或电话收到的任何交易指令负责。在执行一项交易前，snc 会请求客户要至少提供经电子授权登录的用户名和密码，如果是通过电话联系，以口头通过鉴定程序。正确的资料将认证客户，并授予其有在snc 帐户进行交易的权利。

if customer’s account is a joint account, snc is authorized to act on the instructions of any one owner without further inquiry, with regard to trading in the account and/or the disposition of any and all assets in the account. snc shall have no responsibility for further inquiry into such apparent authority and no liability for the consequences of any actions taken or failed to be taken by snc ?and any of its employees in reliance on any such instructions or on the apparent authority of any such authorized person(s).

如果客户的账户是一个联名账户，snc 有权在没有作进一步调查下，识演任何户主的角色，买卖和/或处置任何和所有资产帐户。对于交易账户. snc 不承担对这种表见权力的进一步探讨，并这类表见授权，不对snc 和其信赖的任何雇员，按指示或按任何授权的表见代理人，采取或未能采取的任何行动的后果负责。

????? 4.2 pricing information（定价信息）

snc ?will make available, by posting on the snc ?internet trading platform-- an online trading system, or by customer electronically contacting any alternative designated by snc, by telephoning the snc ?dealing execution desk, or by any other communicative means available to snc ?and it’s customers, bid and ask prices at which snc ?is prepared to enter foreign currency contracts with authorized customers. each bid or ask price shall be for a spot contract with a specified date and for a specific foreign currency pair.? snc makes no warranty expressed or implied; that bid and ask prices shown represent prevailing bid and ask prices in the interbank market.?? in addition, although snc reasonably expects to make available continuous prices during business hours, because of a number of factors including but not limited to technology failures, communication system delays, lack of interbank liquidity or high market volatility, snc makes no warranties that dealing prices and liquidity will be available continuously to customers either electronically or via the telephone or by any other communication devise.

snc 将通过snc 网上交易平台——一网上交易系统，或由客户通过其他任何snc 和其客户指定的方式，拨到snc 或其他任何snc 和其客户协定的交易执行服务台，snc 在已设立的外汇合同与授权客户出价和询价。每次出价或询价应为有具体日期的某一特定外币组合的现货合同。snc 不担保明示或暗示，显示在银行间市场的报价和询价报价为无效的出价或询价。此外，虽然snc 有理由预期在交易时间内定一个持续有效的价格，但由于若干因素，包括但不仅仅是技术故障、通讯系统的延误、银行间缺少流动资金或较大市场波动，snc 不担保客户通过电子或电话或其他任何通信方式下得到的交易价格和流动性可持续有效。

???? 4.3 execution of orders (下单的执行)

all contracts made and entered into between customer and snc hereunder will be entered into by snc ?as principal.? snc ?will reasonably attempt to execute all orders that it may, in its sole discretion, accept from customer for the purchase or sale of contracts in accordance with the customer’s electronic, written or typed, or oral instructions. however, snc shall not be responsible for any loss or damage caused, directly or indirectly, by any events, actions or omissions beyond the reasonable direct control of snc , including, without limitation, loss or damage resulting, directly or indirectly, from any delays or inaccuracies in the transmission of orders and/or information due to a breakdown in or failure of any transmission or communication facilities.

所有客户和snc 签订的合同，将被snc 录入。snc 将合理地尝试执行的所有命令，它可在其自行斟酌，接受客户以电子、书面、打字或口头知识的买卖合同。然而，snc 不应对受到任何事件、超出snc 合理直接控制的行为或不行为，直接或间接造成的损失或损害承担任何责任，其中包括但不仅仅是，因任何传输或通讯设施损坏或失败直接或间接造成任何传递订单和/或信息的拖延或不准确。

customer acknowledges, understands and agrees that all market orders and non-market orders such as limit orders, stop-loss orders, one cancels the other orders, or any other non-market order transmitted and accepted by a snc representative, are accepted by snc ?and undertaken on a “best-efforts basis” in accordance with the relevant provisions of the trading policies, as amended from time to time. the customer acknowledges, however, that due to market conditions or other circumstances, snc ?may be unable to execute the order at the market or specified level and the customer agrees that snc ?will bear no liability for failure to execute such orders.? this includes but is not limited to all orders that are entered over a weekend or holiday period when snc is closed for

business.? in such circumstances, orders will be executed on a “best-efforts basis” once the market is reopened on the next snc business day. customer acknowledges that execution may not be immediate or at the price dictated by the opening level due to imbalances in orders, market conditions, market liquidity or other circumstances.? snc shall have no responsibility for delays in the transmission of orders due to disruption, market conditions, failure or mal of communications facilities and shall not be liable for any claims, losses, damages, costs or expenses, including attorneys’ fees, to any person or entity as a result of its negligence.

客户承认、理解并同意，所有市场订单和非市场订单，如限价单、止损订单、一放取消另一方订单，或任何其他受snc 的代表传播和接受的非市场订单，都被snc 所接受和在"尽最大努力"的基础上按照有关规定、营运政策、不时修正、客户确认开展。但是，由于市场条件或其它情况，snc 可能无法在市场或客户指定水平上执行。客户需同意，snc 将不承担任何这些命令执行失败的责任。这包括但不仅仅是所有在一个周末或假期期间，snc 停止交易时入场的订单。在这种情况下，当市场在未来snc 的交易日重新开放时，订单将在"尽最大努力"的基础上被执行。客户明确，由于订单不平衡、市场条件、市场流动资金或其他情况，执行不一定是即时的或在规定的价格水平上。snc 不对在发送订单过程中，因扰乱、市场条件、通讯设施的失效或故障造成的延误负责；并不为由于其疏忽造成任何索赔、损失、成本或费用，包括任何人或实体在内的律师费承担责任。

??? 4.4???? positions and orders limitations (仓位和下单限制)

snc ?reserves the sole discretionary right to limit the number of open positions which customer may enter, acquire or maintain with snc , to refuse acceptance of any order entered by customer or to alter its dealing relationship with the customer to include or exclude use of any electronic trading network or other trade execution method in any manner and to any extent.

snc 保留自行裁量，以限制客户与snc 获得或维持，可能进入的未平仓合约数。拒绝接受任何客户的入场命令或改变其与客户，包括或不包括使用任何电子交易网络或其他以任何方式任何程度的办法执行的交易关系。

???? 4.5 netting (对冲)

snc ?retains the right to net all hedged positions at the end of each month at their sole discretion.

snc 有权在每月末自由决定对冲所有仓。

margin requirements (保证金要求)

customer shall provide to and maintain with snc ?margin in such amounts and in such forms, and within such limits as snc , in its sole discretion, may from time to time require. margin requirements, including initial (opening) margin and maintenance margin requirements, are defined in snc ?trading policies. snc ?may change margin requirements at any time. customer agrees to deposit by immediate wire transfer such additional margin when and as required by snc , and will immediately meet all margin calls in such mode of transmission as snc ?shall, in its sole discretion, designate; provided, however, and notwithstanding any demand for additional margin, snc ?may at any time proceed to liquidate customer’s account in accordance with trading policies. any failure by snc ??to enforce its rights hereunder shall not be deemed a future waiver of such rights by snc , and the customer shall impute no liability to snc ??whatsoever for losses resulting from such failure. no previous margin requirement by snc ?shall preclude snc ?from increasing or decreasing that requirement without prior notice. snc ?may call for additional margin (“margin call”) at any time customer’s margin balance falls below the snc ?maintenance margin level as applied to that account and at any time snc , in its sole discretion, believes that it is prudent to do so. snc ?may at any time liquidate customer’s account in accordance with trading policies and paragraph 12 below.

客户应提供并保持snc 一定数额和一定形式的保证金；而在snc 限度可随时斟酌决定保证金的要求，包括初期(开户时) snc 交易政策指定的保证金和维持保证金的要求。snc 可以在任何时候改变保证金要求。客户立即电汇同意并视snc 需要存入额外保证金时，会立即满足所有保证金要求，在这种传播方式为snc 应自行划定提供的。然而,尽管有额外保证金的需求，按照交易政策和第12段，snc 可以在任何时候进行客户帐户的清算。

security agreement (安全协议)

in order to secure any indebtedness or other obligations at any time owing from customer to snc , including, without limitation,

为了确保任何从客户到snc 在任何时间的债务或义务，包括没有限制，

indebtedness or other obligations under any account, contract or other transaction with snc ?; or

任何账户的债务或其他义务，合约或其它与snc 的交易；或者

any indebtedness or other obligations resulting from any guarantee by customer of any account, contract or other transaction with snc ?, customer hereby assigns, pledges and grants to snc ??a security interest in and right of setoff against:

snc 在保障权益下有权取消任何债务或因任何客户帐户的任何保证，合同或其它与snc 的交易，客户的转让、认捐和送赠；

all of customer’s accounts with snc ;

所有snc 帐户的客户

all contracts, cash and other property in customer’s account at snc ??or delivered or otherwise provided by customer to secure its indebtedness or other obligations to snc ??or in snc ??possession or control for any purpose (including safekeeping); and

所有在snc 或交付或客户另有规定的合约、现金及其他在客户帐户的财物，以确保其对snc 欠债或其他义务，或snc 为任何目的的控制包括安全保管)；

all products and proceeds of the foregoing (collectively, (i), (ii) and (iii) are referred to as “collateral”).

所有前述的产品和收益((i)、(ii)、(iii)被称为"抵押品")。

in the event of indebtedness of customer to snc ??for reasons including but not limited to (a) and (b) outlined above, snc ??shall have the right to sell, pledge, rehypothecate, assign, invest, commingle and otherwise use any collateral it holds (including, but not limited to, using the contracts as collateral for a loan to snc ?) free from any claim or right of any nature whatsoever of the customer, including any equity or right of redemption by the customer and to register any collateral in the name of snc ?, its custodian or a nominee for either. any failure by snc ?to enforce its rights hereunder shall not be deemed a future waiver of such rights by snc . snc ?is irrevocably appointed as attorney-in-fact for customer and is authorized, without notice to customer, to execute and deliver any documents, give any notice and to take any actions on behalf of customer, including the execution, delivery and filing of financing statements, that snc ?deems necessary or desirable to evidence or to protect snc ?interest with respect to any collateral. in the event that the collateral deemed acceptable to snc ?(“eligible collateral”) is at any time insufficient to satisfy customer’s indebtedness or other obligations to snc , including obligations to provide margin in accordance with trading policies and paragraph 7 hereof, customer shall promptly pay upon demand the entire amount of such deficit in accordance with trading policies and paragraph 8 hereof.

因客户的snc 债务原因，包括但不仅仅是上述的(a)和(b)，snc 有权出售、抵押、质押、转让、投资，并以其它方式使用任何其所持有的抵押品(包括但不仅仅是，以合同作为snc 的贷款抵押品)，客户不具有对包括客户或其监护人或提名人的任何股权或赎回权，和在snc 名下登记任何抵押品，提出任何索赔或应具的权利。任何snc 对行使其权利的失败，不被认为是snc 未来放弃这些权利。snc 不可撤消地在不通知客户的情况下作为客户和授权的实际代理人，代表客户执行和提供任何文件，发出任何通知并采取任何行动，包括处理、发送融资档案，snc 在举证和保护snc 利益与尊重任何抵押品上被认为是必要或适合的。snc 认为是可接受的抵押品( "合格的抵押品" )，即在任何时候，当客户不足以抵偿snc 的负债或其他义务，包括按照贸易政策和第7条，提供保证金的义务，客户应按照贸易政策和第八条要求的，迅速支付全部负债金额。

capacity (性能)

any and all contracts and transactions made and entered into by snc ?hereunder as a result of customer directing snc ?to enter into such contracts and transactions, are made and entered into by snc ?as principal. unless otherwise agreed to in writing snc ?shall act as principal in any and all contracts and transactions with the customer and not as broker, intermediary, agent, and advisor or in any fiduciary capacity. the customer understands and recognizes that any and all transactions and contracts entered as a result of customer directing snc ??to enter into such transactions and contracts may be entered by snc , as principal, with financial institutions including, without limitation banks, clearing institutions and foreign exchange dealers (“counter party”) at the sole discretion and option of snc . customer represents, agrees and authorizes snc ??to act as principal in entering, delivering, selling, purchasing and clearing with counter party any and all customer’s contracts. customer shall guarantee and hold snc ?harmless against any loss it may sustain thereby. snc ??may, at its sole discretion and option, act as principal in purchasing, selling, delivering and clearing any contracts, including all customer’s contracts, with the counter party(s).

因客户的snc 债务原因，包括但不仅仅是上述的(a)和(b)，snc 有权出售、抵押、质押、转让、投资，并以其它方式使用任何其所持有的抵押品(包括但不仅仅是，以合同作为snc 的贷款抵押品)，客户不具有对包括客户或其监护人或提名人的任何股权或赎回权，和在snc 名下登记任何抵押品，提出任何索赔或应具的权利。任何snc 对行使其权利的失败，不被认为是snc 未来放弃这些权利。snc 不可撤消地在不通知客户的情况下作为客户和授权的实际代理人，代表客户执行和提供任何文件，发出任何通知并采取任何行动，包括处理、发送融资档案，snc 在举证和保护snc 利益与尊重任何抵押品上被认为是必要或适合的。snc 认为是可接受的抵押品( "合格的抵押品" )，即在任何时候，当客户不足以抵偿snc 的负债或其他义务，包括按照贸易政策和第7条，提供保证金的义务，客户应按照贸易政策和第八条要求的，迅速支付全部负债金额。

rollovers (隔夜利息)

in the absence of an offsetting or closing liquidation trade done prior to the close of business, snc ?is authorized to rollover all or any portion of the foreign currency positions in customers account at snc ?’s absolute discretion and at customer’s risk to the next settlement spot date.?? rollovers will be executed at rates determined by snc and at snc ’s absolute discretion.? rollover debits or credits will be reflected in the customer’s account at a time after the normal close of the business day for snc.? snc reserves the right to change at its sole discretion, any rollover debits or credits at any time if snc, at its sole discretion deems that the amount debited or credited was in error.

在交易结束前未对所完成的交易作对冲或关闭清算，snc 被授权在其自行决定的和对客户在之后现货交收日的风险下，滚转客户帐户中全部或任何外币份额。滚转执行情况由snc 在其自行的决定权基础上决定。滚转的借记或信贷将在正常交易日关闭后一段时间内反映在客户的帐户上。如果snc 的自行决定的借记或信贷数额被认为有错误，snc 保留自行斟酌在任何时候改变任何借记或贷记的权利。

?liquidation of accounts and deficit balances (账户和赤字余额的清算)

in the event of (在以下情况)

the death or declaration of incompetence of customer;

死亡或被宣告不能成为客户；

the filing of a petition in bankruptcy, or a petition for the appointment of a receiver, or the institution of any insolvency or similar proceeding by or against customer;

递交了一份破产、呈请委任接管人，或任何提起破产诉讼或由客户或对客户的类似诉讼的请愿书；

the filing of an attachment against any of customer’s accounts carried by snc ?;

提交一份snc 对任何客户的帐户进行的附件；

insufficient margin, or snc ??determination that any collateral deposited to protect one or more accounts of customer is inadequate, regardless of current market quotations, to secure the account;

保证金不足，或snc 不管目前的市场报价，为保护一个或多个保证金不足客户帐户，以保证账???? 户，而给予的任何抵押存款；

customer’s failure to provide snc ?any information requested pursuant to this agreement; or

客户未能向snc 提供任何这项协定要求的信息；

any other circumstances or developments that snc ??deems appropriate for its protection; in snc ?’s sole discretion it may take one or more or any portion of, the following actions;

任何其他snc 认为是适当保护的情况或发展；在snc 自行斟酌后，可能采取的一个或多个行动如下：

satisfy any obligation customer may have to snc , either directly or by way of guaranty of surety, out of any of customer’s funds or property in its custody or control;

履行任何客户对snc 可能有的义务，或直接由保证人担保，对任何客户的资金或财产保管或控制；

sell or purchase any or all foreign currency contracts or other property held orcarried for customer, and

出售或购买任何或全部外币合约，或客户持有的其他财产；

cancel any or all outstanding orders or contracts, or any other commitments made on behalf of customer. any of the above actions may be taken without demand for margin or additional margin, without prior notice of sale or purchase or other notice to customer, customer’s personal representatives, heirs, executors, administrators, trustees, legatees, or assigns, and regardless of whether the ownership interest shall be solely that of the customer or be held jointly with others. customer shall at all times be liable for the payment of any deficit balance in customer’s account upon demand by snc ??and, in all cases, customer shall be liable for any deficiency remaining in customer’s account in the event of the liquidation thereof in whole or in part by snc ??or by customer.

取消任何或所有未完成的订单或合同，或任何代表客户的其他承诺。有上述情况，未经买卖或其他事先给客户的通知，客户的代表、继承人、遗嘱执行人、监护人、受托人、遗嘱赠予人，或转让，无论受益人是客户单独提名还是联名提名，可不扣除保证金或额外保证金。客户应随时有支付任何snc 要求的赤字。在所有情况下，客户应承担任何帐户中部分由snc 或由客户清算后剩下的赤字。

in the event that the proceeds realized pursuant to liquidation are insufficient for the payment of all liabilities of customer due to snc, customer shall promptly pay upon demand the entire amount of any such deficit, together with all other deficits and all unpaid liabilities of customer.?? included are?? all costs of enforcement and collection, such as, but not limited to, actual attorneys’ fees, disbursements, travel and other expenses, interest on any such deficit and liabilities at a rate equal to five (5) percentage points above the then prevailing prime rate at snc ’s principal bank or the maximum interest rate allowed by law, whichever is lower and any other cost incurred by snc . in the event snc ?incurs expenses other than those for collection of deficits with respect to customer’s account, customer agrees to pay all such expenses in full.

诉讼使依法清算由于snc 客户不足以支付的所有负债。连同其他所有赤字和所有积欠债务，客户应按要求及时支付全部赤字金额，包括所有执行费用和集资等，但不仅限于实际支付律师的费用、付款、旅费和其他费用，任何此类赤字和负债的利息率在最高法律所允许的snc 主体银行主要利率的五个百分点以上，或法律批准和低于snc 其他任何费用的最低利率。客户同意足额支付snc 支出（除客户帐户部分的赤字的收款）的所有费用。

charges (收费)

snc will supply, upon request, a structure of commissions charged at the time of the request. although snc ?reserves the right to change its fee structure at any time at its sole discretion, snc ?will initially only charge for incidental banking related fees such as wire transfers for deposits/withdrawals and returned check fees.? snc ?will also charge customer for the purchase of optional, added services offered by snc .

snc 会根据要求收取佣金或经纪费。虽然snc 保留在任何时间自行改变收费结构的权利，但snc 只收取银行附带的相关费用，如电汇存款/取款和退还支票的收费。snc 也将收取客户可选择性购买、由snc 提供的增值服务的费用。

customers who are introduced to snc ?by an introducing brokers or third party advisor

被外汇经纪人或第三方顾问介绍给snc 的客户

if an introducing broker or third party advisor introduces the customer to snc , the customer understands that snc ?may pay fees, commissions or other compensation to such person or entity for the introduction. customer acknowledges and agrees that as an introducing broker or third party advisor to snc , the introducing broker or third party advisor does not hold or collect any funds on behalf of snc ?or for the customer’s account.? funds should instead be sent via a wire transfer or other means directly to snc ?for purposes of depositing into your trading account.? snc does not control and cannot endorse or vouch for the accuracy of any information or advice customer may have or will receive by the introducing broker or third party advisor. included in the information and advice without limitation are actual or implied promises made by the

introducing broker regarding the future profit or losses in customer accounts as a result of third party trading systems, research reports, market trading advice or interpretation of economic news and events. if customer receives information or trading advice from an introducing broker or third party, snc ?shall in no way be held responsible for any loss resulting from the customers use of information or advice. snc ?provides or otherwise makes available a snc ?risk disclosure document to customers when they open accounts. any customer introduced by introducing brokers or third parties should carefully read the snc ??account application, snc ??risk disclosure document and snc ??trading policies document and should not rely on information supplied by the introducing broker or third party. customer should understand that introducing brokers or third party advisors are often not regulated by a government agency and that the introducing broker or third party advisor shall have the right to access information regarding the account of the customer including but not limited to account information, customer address, phone number, email address. the introducing broker or third party advisor will not have trade authorization privileges unless granted in writing by the customer via the signing of a power of attorney document authorizing the trading.

如果介绍经纪人或第三方顾问向客户介绍snc 外汇，顾客了解到snc 外汇可能需向个人或实体支付费用、佣金或其他报酬等进行介绍。客户确认并同意介绍经纪人或第三方顾问介绍snc 外汇，介绍经纪人或第三方顾问不持有或收取任何代表snc 外汇的保证金资金或为客户的帐户。资金应该是透过电汇或其他方式直接发往snc ，作为将保证金进入交易的帐户。snc 外汇不管制，并不认同或担保客户可能或会接受经介绍经纪人或第三方顾问的任何资料或意见的准确性。包括介绍经纪人就未来由于第三方电子交易系统、研究报告、市场交易咨询或解释经济新闻和事件致使客户账户盈利或亏损所作为的，没有限制的实际或默示承诺的信息和意见。若客户从介绍经纪人或第三方收到信息或买卖咨询，snc 外汇绝不对由客户使用信息或忠告所致的任何损失负责。snc 外汇提供或以其他方式使snc 现有的外汇风险在客户开户时披露。任何介绍经纪人或第三方的客户应当仔细阅读snc 外汇帐户申请书，snc 外汇风险披露文件及snc 外汇交易政策文件，而不应依赖通过中间商或第三方提供的信息。客户确认并明确，保证金外汇交易涉及的风险非常高，许多人因买卖外汇而损失金钱。所有客户应该明白，他们在买卖外汇时只是买卖风险资本基金。风险资本基金，是指就算损失，也不会改变你或你的家人的生活的资金。客户也应明白，介绍经纪人或第三方顾问不常常政府机构规范，而该介绍经纪人或第三方顾问有权查阅有关客户帐户的信息，包括但不限于帐号客户地址、电话号码、电子邮件地址等。介绍经纪人或第三方顾问不会有贸易授权的特权，除非客户经书面并签署一份授权书，给予其授权买卖的文件。

introducing brokers responsibility to snc ?and to their clients

?(介绍经纪人向snc 和客户应负责任)

introducing brokers have certain responsibilities to clients and snc ?with respect to their introduced accounts:

介绍经纪人为客户和snc 外汇就其帐户介绍的责任：

responsible for communicating with their introduced clients investment objectives and investment opportunities given those objectives,

负责与客户沟通，投资目标和这些目标带来的投资机会；

responsible for complying with all legal requirements, rules and regulations applicable to being a licensed introducing broker

遵守所有适用于持牌经纪引用的法律规定、法规；

responsible for complying with all legal requirements, rules and regulations applicable to their customers

遵守所有适用于客户的法律规定、法规；

determining any commission structure and communicating the structure to the introduced clients.

确定任何佣金架构和向客户解释结构.

the introducing broker will not be responsible for (介绍经纪人将不负责):

the opening of the account including, but not limiting to the approving, servicing and monitoring of customer’s accounts(s) and obtaining and verifying account information as is required by the law and regulation,

初始帐户包括但不仅限于客户帐户的批准、服务和监督的和获取并核实法律规定的所需要的帐户信息；

collecting funds from the clients for the purpose of facilitating margin foreign exchange trading or satisfying margin requirements,

从客户以促进保证金外汇买卖或满足保证金要求的目的出发，集资资金；

executing any transactions or accepting any orders for the customer’s account(s), or performing any action that would cause or appear to cause a change in customer position or account , including but not limited to rolling over spot positions, liquidating positions, paying interest, requiring margin, or accepting additional funds or paying out funds to the customer,

为客户的账户执行任何交易或接受任何订单，或从事任何造成或看起来造成客户或账户价值状况改变的行动，包括但不限于再投资当场作出的状况、清算状况、支付利息、保证金，或接受额外资金或支付款项的客户。

providing any account statements to the customers,

向客户提供任何帐单；

responding to complaints or inquiries.

回应投诉或咨询。

?statements and confirmations (声明和确认)

confirmation of trades will be made online as the trades are executed and should immediately be reflected in the customer’s snc ?margin monitor, snc ?open positions window, account statement report and in their trade history report. trades done over the telephone will be executed for the customers account on their behalf and also be reflected online snc ?margin monitor, snc ?open positions window, account statement report and in their trade history report.? reports and all online position windows and statements of accounts for customer shall be deemed correct and shall be conclusive and binding upon customer if not objected to by telephone immediately upon receipt and such objection is confirmed in writing within three (3) business days after the transmission to customer or if snc ?does not change the confirmed execution price and details. snc ?reserves the right to change confirmed rates, prices or trade details of executed and confirmed deals if snc ?feels the electronic or verbal price or details from that deal was executed was in error.?? margin calls or trade corrections shall be conclusive and binding unless objected to immediately by telephone, fax or email. written objections on customer’s part shall be directed to snc , attn: customer objections, 46 nelson st, quincy, massachusetts, 02169 and shall be deemed received only if actually delivered or mailed by registered mail, return receipt requested. failure to object shall be deemed ratification of all actions taken by snc, or snc ?agents prior to customer’s receipt of said reports. trades executed online will be confirmed online at the time of the trade and trades entered into by telephone will be confirmed verbally and online by the end of the business day. pending orders or trades executed while the customer is offline will be reflected in the customers snc open position window, in the snc ?margin monitor, account statement report and in their trade history report upon logging back into the snc ?application. customer’s account statements will be available online in the reports section of the snc internet trading platform and customer monthly statements will be available by e-mail, fax and/or mail. customer’s failure to receive a trade confirmation shall not relieve customer of the obligation to object as set out herein. customer understands and acknowledges that oral information provided by snc ?to customer regarding confirmations of trades and statements of account may be unverified and incomplete due to delays in transmission and other factors beyond snc ?reasonable control. customer therefore acknowledges and agrees that any reliance upon such oral information is at customer’s risk and customer further agrees to immediately call to snc ?attention any such oral information which customer has reason to believe is inconsistent with customer’s own information. no provision of this agreement shall operate to prevent snc ?from correcting any error or omission upon discovery. the customer agrees that such errors, whether resulting in a profit or loss, shall be corrected and customer’s account will be credited or debited in such manner and extent as to place the account in the same position in which it would have been had the error not occurred. snc ?reserves the right to be the final arbiter as related to disputed orders.

交易确认将在网上随交易执行，应该立即反映在客户的snc 外汇保证金监测上，snc 外汇平仓窗口，帐目报表及报告及其在其历史上的交易报告。为客户帐户以电话执行业务时，那些也会反映在snc 外汇保证金上。当交易确认将在网上执行，应该立即反映在客户的snc 外汇保证金监测上，snc 外汇开通平仓窗口snc即期外汇帐目报表及其历史上的交易报告。对客户帐户有权用电话执行交易，之后也会反映在网上的snc 外汇保证金检测系统上，snc 外汇开通平仓窗口，snc即期外汇帐目报表及其历史上的交易报告。报告和所有在线的平台及帐目报表,为客户视为正确、确凿和有约束力，如果顾客不反对通过电话立即收到异议书面确认，其会在snc 外汇并不改变已确认的执行价格及细节后的三个营业日内传递给客户。如果snc 外汇认为电子或口头报价的详情有误，snc 外汇储备有权改变已确认的汇率、价格或交易细节的执行情况和已确认的交易。除非不能立即至电、传真或电子邮件通知，否则保证金偿还或交易更正应受约束。顾客书面反对应当邮寄到snc 经办人: 马萨诸塞州昆士市,来尔森街46号, 邮编02169提出，以收到回执为确认。无效的异议,应视为批准snc外汇所执行的交易，或snc 外汇代理人事先收到客户的通知。当在网上或电话执行交易，将以口头和网上在最后一个交易日回复确认。未完成的交易或执行时客户离线，将反映在客户的snc外汇平台中，在snc 外汇保证金检测、帐目报表及在其历史上的交易报告计回snc 中应用。客户的帐户报表，可在网上snc 外汇交易平台查询部门查询；顾客每月报表可通过电子邮件、传真或邮件查询。若客户未能收到确认，客户仍有权再这点上提出异议，客户理解和承认在snc 外汇合理控制下，snc 提供的口头资料可能为在传送和其他因素之外未核实的及因延误导致不完整的。因此，客户需意识到任何依赖等口头资料对客户有一定的风险，对这类即时的口头信息，客户有理由相信与自身的信息不符。本协议没有规定操作可防止或纠正任何错误或遗漏。是否造成了损益，客户都应同意这种错误，在某程度阻止贷记或借记上错误的发生。snc 保留对相关争议的最后仲裁权利。

communications (信息传达)

reports, statements, notices and any other communications may be transmitted to customer at the address set forth herein, or to such other address as customer may from time to time designate in writing to snc. all communications sent, whether by mail, telegraph, e-mail, fax, messenger or otherwise, shall be deemed transmitted by snc ??when deposited in the united states mail, or when received by a transmitting agent, or communications or recording device, designated by customer or otherwise within customer’s actual or constructive control, and such communication shall be deemed delivered to customer personally, whether actually received by customer or not, and customer hereby waives all claims resulting from failures to receive such communications. all communications sent by customer shall not be deemed effective until accepted by snc . customer shall notify snc immediately of any change in customer’s address by e-mail to or by mail or other delivery service to snc attn: customer accounts, 46 nelson st, quincy, massachusetts, 02169.

报告、声明、告示及任何其他通信可发送到客户所阐述的地址，或其它在客户给snc 寄信时流下的地址。所有由客户指定或客户实际上或结构上的控制的信息发送，不管是邮件、电报、电子邮件、传真、信使或其他，应视为由snc 发出的，在美国存放或从转发代理、通信或录音装置收到。无论客户实际收到与否，这种信息发送应视为已交付给客户个人，客户因此放弃所有因通信失败的索赔要求。在收到snc 回复前，所有的客户信函都应视无效。客户应发电子邮件 或邮寄或其他寄递方式到：snc ?经办人:客户帐户，马萨诸塞州昆士市,来尔森街46号, 邮编02169。

force majeure (不可抗力)

snc ??shall not be liable to the customer for any loss, cost, damage or expense sustained or incurred by the customer, directly or indirectly, by reason of any cause beyond snc ?’s control, including but not limited to, natural disasters, acts of god, civil unrest, war, insurrection,? international? intervention,? governmental? action (including,? without? limitation,? exchange? controls,? forfeitures, nationalizations, devaluations), market conditions, inability to communicate with any relevant person or entity or any breakdown or failure of any transmission or communication system or computer facility, whether belonging to snc , customer or any market or any settlement or clearing system.

snc 不对客户，因任何snc 可控制外的原因，包括但不仅限于，自然灾害天灾、动乱、战争、叛乱、国际干预、政府行为(包括但不仅仅限于外汇管制、没收、国有化、贬值)、市场条件、无法沟通、任何有关个人或实体，或任何任何传输、通信系统或计算机设施，是否关于snc 的客户、任何市场或任何结算、清算系统的故障或失效，而客户任何持续或招致的直接或间接损失、费用、损坏负责。

?trading recommendations (交易建议)

customer acknowledges, understands and agrees that

客户明确、理解并同意：

any market recommendations and information communicated to customer by snc ??or any introducing broker affiliated with snc ??do not constitute an offer to sell or the solicitation of an offer to buy any foreign currency contract;

市场上任何介绍经纪人或任何隶属于snc 的经纪人通过snc 传达给客户的建议和信息，并不构成出售或要约购买外币合同的要约；

such recommendation and information, although based upon information obtained from sources believed by snc ??to be reliable, may be incomplete and may be unverified; and

虽然这些建议和信息是由snc 所得，但可能为不可靠、不完整和不核实的；

snc ?makes no representation, warranty or guarantee as to, and shall not be responsible for, the accuracy or completeness of any information or trading recommendation furnished to customer; and

snc 不保证或担保，并不负责其提供给客户的任何资料或买卖建议的准确性或完整性；

customer further acknowledges that, should customer grant trading authority or control over customer’s account to a third-party (authorized agent), whether on a discretionary or non-discretionary basis, snc ?shall in no way be responsible for reviewing customer’s choice nor making any recommendations with respect thereto.

客户进一步明确，不论是自愿还是非自愿的基础上，客户向第三方(授权代理人)给予交易授权或帐户控制权，snc 绝不对客户的选择审查负责，也不提出任何建议并表示尊重。

?intellectual property and confidentiality (知识产权和保密)

all copyright, trademark, trade secret and other intellectual property rights in the snc ?internet trading platform (“snc ?pro”), an online trading system, shall remain at all times the sole, exclusive and absolute property of snc ?and customer shall have no right or interest in the snc ?pro except for the right to access and use the fip as specified herein. customer acknowledges that the snc ?pro is confidential and proprietary to snc ?and has been developed through the expenditure of substantial skill, time, effort and money of snc . the customer agrees and warrants that customer will protect the confidentiality of snc ??at all times by allowing access to the snc ?pro only by its employees and agents on a need to access basis. customer will not publish, distribute, or otherwise make any information available to third parties derived from or relating to the snc ?internet trading platform. customer will not copy, modify, de-compile, reverse engineer, and make derivative works of the snc ?internet trading platform or in the manner in which it operates. any violation of the above shall be subject to prosecution under the applicable state and federal laws.

所有在snc 网上外汇交易平台(“snc ?pro”)，网上交易系统的版权、商标、商业秘密和其它知识产权，应一直由snc 对财产统一管理。客户除有权查阅和使用规定具体提到的外，在snc ?pro没有权利或利益。客户承认，snc 通过付出大量技能、时间、精力和金钱，使fip为保密和专利的。客户同意并保证，客户要在雇员和代理人因需要对其允许进入snc ?pro的时候，保护snc 的保密性。顾客不公布或以任何其他资料让第三方获得或涉及、snc 网上外汇交易平台。顾客不得利用复制、修改、反向编译、逆向工程，产出盗版snc ，或以其运作方式的网上交易平台。违反上述任何规定，可根据州和联邦适用的法律被检控。

indemnification (赔偿)

customer agrees to indemnify and hold snc , its affiliates, employees, agents, successors and assigns harmless from and against any and all liabilities, losses, damages, costs and expenses, including attorney’s fees, incurred by snc ?arising out of customer’s failure to fully and timely perform customer’s agreements herein or should any of the representations and warranties made by customer herein or at any time fail to be true and correct. except as otherwise expressly stated herein, customer also agrees to pay promptly to snc ??all damages, costs and expenses, including attorney’s fees, incurred by snc ??in the enforcement of any of the provisions of this agreement, any other agreements between snc ??and customer, and any contracts and other transactions hereunder.

客户同意，使snc 及其联营公司、雇员、代理、承继人和受让人免受所有债务、损失、损失赔偿、费用和开支，包括因snc 没有充分和及时根据协议满足客户，而引起的律师调解费。除非另有明确说明，客户需同意马上赔偿snc 一切损失、成本及费用，包括snc 在执行任何有关本协定规定，其他关于snc和客户协议、合同和其他下文提到的交易，引起的律师调解费。

disclosure and financial information (披露财务资料)

the customer represents and warrants that the financial information disclosed to snc ?in this document and any and all documents provided by customer in connection with the customer’s account are an accurate representation of the customer’s current financial condition, trading experience and the level of investment sophistication. the customer additionally represents to snc ?that the information provided by the customer in connection with this agreement is full, complete and accurate and snc ?is entitled to rely on this information until snc ?receives written notice from the customer of any change in such information. the customer represents and warrants that the customer has very carefully considered the portion of the customer’s assets which the customer deems to be risk capital; the customer recognizes that risk capital is the amount of money the customer is willing to put at risk and if lost would not, in any way, change the customer’s life style or otherwise materially effect customer.

客户代表及保证，由客户就其帐户的准确财政现状、交易记录和投资行为，向snc 在这份文件和任何所有文件披露财务信息。除此之外，客户需向snc 表示，其提供与本协议有关的信息为充分、完整和准确的，snc 有权收到客户一书面通知其信息的改变。客户代表并保证，已对其资本风险作详细考虑，不因其投资损失而致使其在生活模式上或物质上改变。

disclosure and customer information (披露客户资料)

snc ?will not share or sell information regarding its customers and/or prospective customers, except to its employees, agents, affiliates, partners, and associates as reasonably required in the ordinary course of snc ?business, including, but not limited to, snc ?banking or credit relationships. snc ?may also disclose to federal or state regulatory agencies and law enforcement authorities’ information regarding customer and customer’s transactions in response to a request for such information and may disclose information regarding customer and customer’s transactions in response to a court order or subpoena.

snc 不会共享或出售其客户和/或潜在客户的信息，除非在一般snc 业务过程中，其雇员,代理人,分支机构,合作伙伴，包括但不仅限为，snc 外汇银行或信用关系的合理要求。snc 还可能向联邦或州的监管机构和执法机关透露资料，并就客户和其帐户交易的法庭命令或传票要求披露有关客户及交易信息。

joint accounts and trust accounts (联合帐户和信托帐户)

if more than one natural person as the customer executes this agreement, all such natural persons agree to be jointly and severally liable for the obligations assumed in this agreement. if this agreement is executed by a trust, partnership or unincorporated association, the customer hereby agrees to indemnify, defend, save and hold harmless and free snc ?for any losses, claims, costs, damages and expenses resulting directly or indirectly from breach of any fiduciary or similar duty or allegation thereof.

如果有一个以上的自然人作为客户执行本协议，所有这些自然人都应同意承担在本协议的连带责任。 如果由信托、合伙企业或法人团体执行本协议，客户在此同意赔偿、保护、保存并免除因任何违反受托人或类似的职责或指控，对snc 直接或间接造成的

信托说明书-----不动产转移声明（中英文对照）

信托说明书

-----不动产转移声明

本信托声明书于19___年___月___日 由___（姓名，地址）（以下简称“受托人”）作出。

this declaration of trust is made the _______day of ____19__， by（name）（address）.（hereinafter referred to as " the trustee"）

鉴于

whereas：

1.（略）

1.（omitted）

2. 该项住宅事实上已转让给（姓名，地址）（以下简称“委托人”）

2. the said premises were in fact assigned to （name and address of

beneficiary） （hereinafter referred to as "the principal "）

本文据证明，受托人在此宣称，从该转让日起，已为委托人以信托而持有并将继续持有该住宅，该住宅的收入和利润及销售或处理时所得的收益，受托人在此同意，在该委托人要求时将该住宅转让、转移或作其他处理给委托人，或按委托人指示或指定在其时或以其指定的形式转让给其指定的人。

now the deed witnesseth that the trustee doth hereby declare that the trustee

has since the date of the said assignment held and henceforth hold and stand

possessed of the said premises and the income and profits thereof and the proceeds

of sale thereof in case of the same shall be sold or disposed of upon trust for

the principal and the trustee doth hereby agree to assign transfer or otherwise

dispose of the said premises to the principal at the said (principal) request or

to such person or persons at such time or times or in such manner as the said

principal shall direct or appoint.

并在此声明，在本文据存在期间，一受托人有权指定新的或额外的受托人。

it is hereby further declared that the trustee shall，during the subsistence

of this deed，have power of appointing new or additional trustees.

为昭信守，受托人于上述日期盖章签字

i n witness whereof the trustee hereto has hereunto set his hand and seal the

共2页，当前第1页12

外贸合同中英文

编号： no：

日期： date ：

签约地点： signed at：

卖方：sellers：

地址：address： 邮政编码：postal code：

电话：tel： 传真：fax：

买方：buyers：

地址：address： 邮政编码：postal code：

电话：tel： 传真：fax：

买卖双方同意按下列条款由卖方出售，买方购进下列货物：

the sellers agrees to sell a nd the buyer agrees to buy the undermentioned goods on the terms a nd conditions stated below.

1 货号 article no.

2 品名及规格 description&specification

3 数量 quantity

4 单价 unit price

5 总值：

数量及总值均有_____%的增减,由卖方决定。

total amount

with _____% more o r less both in amount a nd quantity allowed at the sellers option.

6 生产国和制造厂家 country of origin a nd manufacturer

7 包装： packing：

8 唛头： shipping marks：

9 装运期限：time of shipment：

10 装运口岸：port of loading：

11 目的口岸：port of destination：

12 保险：由卖方按发票全额110%投保至_____为止的_____险。

insurance：to be effected by buyers for 110% of full invoice value covering _____ up to _____ only.

13 付款条件：

买方须于_____年_____月_____日将保兑的，不可撤销的，可转让可分割的即期信用证开到卖方。 信用证议付有效期延至上列装运期后15天在中国到期，该信用证中必须注明允许分运及转运。

payment：

by confirmed, irrevocable, transferable a nd divisible l/c to be available by sight draft to reach the sellers before ___/___/_____ a nd to remain valid for ingotiation in china until 15 days after the aforesaid time of shipment. tje l/c must specify that transhipment a nd partial shipments are allowed.

14 单据：documents：

15 装运条件：terms of shipment：

16 品质与数量、重量的异义与索赔：quality/quantity discrepancy a nd claim：

17 人力不可抗拒因素：

由于水灾、火灾、地震、干旱、战争或协议一方无法预见、控制、避免和克服的其他事件导致不能或暂时不能全部或部分履行本协议，该方不负责任。但是，受不可抗力事件影响的一方须尽快将发生的事件通知另一方，并在不可抗力事件发生15天内将有关机构出具的不可抗力事件的证明寄交对方。

force majeure：

either party shall not be held responsible for failure o r delay to perform all o r any part of this agreement due to flood, fire, earthquake, draught, war o r any other events which could not be predicted, controlled, avoided o r overcome by the relative party. however, the party affected by the event of force majeure shall inform the other party of its occurrence in writing as soon as possible a nd thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days after its occurrence.

18 仲裁：

在履行协议过程中，如产生争议，双方应友好协商解决。若通过友好协商未能达成协议，则提交中国国际贸易促进委员会对外贸易仲裁委员会，根据该会仲裁程序暂行规定进行仲裁。该委员会决定是终局的，对双方均有约束力。仲裁费用，除另有规定外，由败诉一方负担。

共6页，当前第1页123456

国际有限责任公司成立合同（中英文对照）

第一章 总则

chapter one general provisions

中国_________公司和_________国_________公司，根据《中华人民共和国中外合资经营企业法》和中国的其他有关法规，同意在中华人民共和国_________省_________市共同投资举办合资经营企业，特订立本合同。

this contract is made by and between（name of the chinese company）and（name of the foreign company)，who agree to jointly set up and run a joint venture in_________city，_________province in china under the act of sino-foreign joint ventures of the people’s republic of china and other chinese laws and regulations concerned.

第二章 合营各方

chavier two partners of the joint venture

第一条 本合同的各方

中国_________公司（以下简称甲方），在中国_________地登记注册，其法定地址在中国___省____市___区____街_____号；法定代表：姓名_________职务_________国籍_________

______国_____公司（以下简称乙方），在国地登记注册，其法定地址在_____。法定代表：姓名____ 职务_____国籍______

1. parties to the contract

name of the chinese company，（ herein called party a），registered in（name of place），address for service of process：_________street，_________district，_________city，province，china；legal representative：name_________，post _________ ，nationality_________.

name of the foreign company，（herein called party b），registered in（name of place），address for service of process：_________ ；legal representative: name _________，post _________ ，nationality _________.

第三章 成立合资经营公司

chapter three establishment of the joint venture

第二条 甲、乙方根据《中华人民共和国中外合资经营企业法》和中国的其他有关法规，同意在中国境内建立合资经营_________有限责任公司（以下简称合营公司）。

2.party a and party b agree to set up_________co.，ltd.（hereinafter called joint venture）in china under the act of sino-foreign joint ventures of the people’s republic of china and other relevant chinese laws and regulations.

第三条 合营公司的名称为_________有限责任公司。

外文名称为_________。

合营公司的法定地址为_________省_________市_________路_________号。

3.chinese name of joint venture：_________ co.，ltd.

foreign name of joint venture：_________.

共19页，当前第1页12345678910111213141516171819

甲方:

乙方:

经甲乙双方友好协商，现就甲方委托给乙方完成的申报中文材料翻译成英文材料事项签订如下协议。

一、翻译稿件名称：材料。具体包括：

1、拟建考察报告(含建设发展规划及规划图册);

2、申报书;

3、申报自评报告;

4、风光片解说词。

二、工作时间：甲方于x年x月日前将需翻译的中文定稿材料交付乙方。乙方应于x年x月x日前将翻译好的英文成稿交付甲方。

三、交稿方式：乙方应向甲方提供英文成稿打印件及电子文本(文件格式：coredraw9.0排版)各一份。

四、协议总金额：协议全部工作任务总费用为xx元，大写人民币xx元整。甲方在签订协议之日起向乙方支付x万元，余款在乙方交付成稿并经甲方验收后一次性结清。

五、翻译质量：乙方保证翻译成稿质量，做到忠实原文、翻译准确、语句通顺、行文流畅，达到甲方提供给乙方的《综合报告》(英文版)的翻译水平。如双方对译文水平发生争议，由双方共同认可的第三方进行评判。

六、其它事项：乙方负责为甲方在申报国际评审会上作英文陈述，陈述费用不再另付。乙方在申报材料的英文翻译稿进行电脑排版时，需就排版格式等有关问题与甲方提供的印刷厂技术员进行联系沟通，以保证英文成稿的电子文本符合甲方印刷要求。

七、本协议自签订之日起具有法律效力，双方应共同遵守，否则由违约方赔偿对方由此造成的一切损失。

八、本协议未尽事宜，由双方友好协商解决。

九、本协议壹式肆份，甲乙双方各执贰份，具有同等法律效力。

甲方(签章)：乙方(签章)：

日期：日期：

经双方友好协商，甲方愿意委任______作为在______销售其产品的独家经销商。为了明确双方的权利和义务，特订立本协议。

甲方：公司(以下简称甲方)

地址：

电话：传真：Email：

乙方：

地址：

电话：传真：Email：

第一条、双方关系：在本协议的有效期内，甲方和______公司的关系纯属卖方和买方的关系。本协议不产生代理权，任何一方不能向第三者代表另一方，若由此而致使另一方受损，则越权的一方须承担赔偿责任和法律责任。

第二条、产品。本协议所称的产品，系指甲方所制造的产品。

第三条、经销权甲方给予__________公司在的范围内以独家进口并销售其产品的权利。

第四条、专营权除________公司外，甲方不得再委任范围内的其它公司为其经销商和代理商。

第五条、价格甲方必须向乙方提供最优惠的价格。最优惠的价格即必须低于正常贸易的价格。

第六条、交易方式发生在双方间的每一笔交易都必须订立合同，双方均须受到每一个合同的约束

第七条、卖方责任

1.自费向乙方提供新产品的样品，每个样品为1-2个。

2.同意乙方在进行业务推广时向客户介绍甲方的网站，并表明其独家经销的身份。

3.在协议的有效期限内：甲方如获得专利产品的注册、或商标、或其他商业标志，均须立即向乙方提供。

4.甲方必须将希望与其建立商业关系的境内新客户转给乙方。

5.不断提供有助于推销产品的意见和资料。

第八条、经销商责任

1.自费维持一个有经营能力的机构，切实地为甲方推销产品。

2.自费参加一些交易会或制作为了推销甲方产品的网站、目录等广告物。

3.在本协议的有效时限内，第一年的每个月的交易额必须达到万元，以后每年递增20%

4.向甲方提供一个由甲方认可的银行为结算银行。

5.不得购买和销售其他公司的同类产品

6.不断地向甲方提供国内相关的商业情报

第九条、有效时限本协议自_____生效，有效期为___年。期满前三个月内，双方如未能在续签本协议上达成一致，则本协议在期满时自动失效，双方再不受其约束。

第十条、违约本协议的任何一方发生了违约行为，另一方得以书面的形式通知其纠正。如若违约一方在三个月内仍未纠正其违约行为，则另一方有权中止本协议。

第十一条、一般条款

1.不可抗力：本协议的任何一方如遭遇到所力不能及的事由，以致全部或部份无法履行本协议，则可在下列范围内免除其责任。如：火灾、水灾、海啸、地震、雷击、台风、旋风、疫病、爆炸、机械事故、战争、暴乱、制裁、劳工纠纷或政府的政策性行为，或其它的确实非人力所能抗拒的原因。但一方必须将得到政府或有关机构证明的不可抗力原因的书面通知，以最快的速度送达另一方并直到另一方确认收到该通知时为止。

2.转让：本协议在任何一方在未征得另一方以书面的方式明确表示同意之前，任何涉及本协议所规定的权利和义务的转让均属无效。

3.商业机密本协议的任何一方均不得在有效期内及期满的一年内向第三者泄漏双方之间的商业秘密，若由此而造成另一方的利益损失，则另一方有追索泄漏商业秘密一方的经济责任的权利。

4.仲裁凡因本协议或其相关的事情而导致争执时，双方应当友好协商解决，解决不成，应提请中国贸易促进委员会进行仲裁，该仲裁是终局的，双方由于进行仲裁而发生的合理费用均由败诉方负担。

5.协议文本本协议以英文和中文两种文字书就，如若两种文字在字义上产生抵触时，必须按照两种文字的意义做出折中判断。本协议一式份，双方各执一份。本协议经双方签字后将于所约定的时间生效。

签订地点：

甲方：

乙方：

日期：

合同号：

no：

日期：

date：

为在平等互利的基础上发展贸易，有关方按下列条件签订本协议：

this agreement is entered into between the parties concerned on the basis of equality and mutual benefit to develop business on terms and conditions mutually agreed upon as follows:

1. 订约人 contracting parties

供货人(以下称甲方)：

销售代理人(以下称乙方)：

甲方委托乙方为销售代理人，推销下列商品。

supplier: (hereinafter called "party a")

agent:(hereinafter called "party b")

party a hereby appoint party b to act as his selling agent to sell the commodity mentioned below.

2. 商品名称及数量或金额 commodity and quantity or amount

双方约定，乙方在协议有效期内， 销售不少于商品。

it is mutually agreed that party b shall undertake to sell not less than... of the aforesaid commodity in the duration of this agreement。

3. 经销地区 territory

只限在.....。

in ... only.

4. 订单的确认 confirmation of orders

本协议所规定商品的数量、价格及装运条件等，应在每笔交易中确认，其细目应在双方签订的销售协议书中作出规定。

the quantities, prices and shipments of the commodities stated in this agreement shall be confirmed in each transaction, the particulars of which are to be specified in the sales confirmation signed by the two parties hereto.

5. 付款 payment

订单确认之后，乙方须按照有关确认书所规定的时间开立以甲方为受益人的保兑的、不可撤销的即期信用证。乙方开出信用证后，应立即通知甲方，以便甲方准备交货。

after confirmation of the order, party b shall arrange to open a confirmed, irrevocable l/c available by draft at sight in favour of party a within the time stipulated in the relevant s/c. party b shall also notify party a immediately after l/c is opened so that party a can get prepared for delivery.

6. 佣金 commission

在本协议期满时，若乙方完成了第二款所规定的数额，甲方应按装运货物所收到的发票累计总金额付给乙方*%的佣金。

upon the expiration of the agreement and party bs fullfilment of the total turnover mentioned in article 2, party a shall pay to party b... % commission on the basis of the aggregate amount of the invoice value against the shipments effected.

7. 市场情况报告 reports on market conditions

乙方每3个月向甲方提供一次有关当时市场情况和用户意见的详细报告。同时，乙方应随时向甲方提供其他供应商的类似商品样品及其价格、销售情况和广告资料。

party b shall forward once every three months to party a detailed reports on current market conditions and of consumers comments. meanwhile, party b shall,from time to time, send to party a samples of similar commodities offered by other suppliers, together with their prices, sales information and advertising materials.

8. 宣传广告费用 advertising & publicity expenses

在本协议有效期内，乙方在上述经销地区所作广告宣传的一切费用，由乙方自理。乙方须事先向甲方提供宣传广告的图案及文字说明，由甲方审阅同意。

party b shall bear all expenses for advertising and publicity within the aforementioned territory in the duration of this agreement and submit to party a all patterns and/or drawings and description for prior approval.

9. 协议有效期 validity of agreement

本协议经双方签字后生效，有效期为天，自至。若一方希望延长本协议，则须在本协议期满前1个月书面通知另一方，经双方协商决定。

若协议一方未履行协议条款，另一方有权终止协议。

this agreement, after its being signed by the parties concerned, shall remain in force for... days from ... to ... if either party wishes to extend this agreement, he shall notice, in writing, the other party one month prior to its expiration. the matter shall be decided by the agreement and by consent of the parties hereto. should either party fail to implement the terms and conditions herein, the other party is entitled to terminate this agreement.

10. 仲裁 arbitration

在履行协议过程中，如产生争议，双方应友好协商解决。若通过友好协商达不成协议，则提交中国国际贸易促进委员会对外贸易仲裁委员会，根据该会仲裁程序暂行规定进行仲裁。该委员会的决定是终局的，对双方均具有约束力。仲裁费用，除另有规定外，由败诉一方负担。

all disputes arising from the execution of this agreement shall be settled through friendly consultations. in case no settlement can be reached, the case in dispute shall then be submitted to the foreign trade arbitration commission of the china council for the promotion of international trade for arbitration in accordance with its provisional rules of procedure. the decision made by this commission shall be regarded as final and binding upon both parties. arbitration fees shall be borne by the losing party ,unless otherwise awarded.

11. 其他条款 other terms & conditions

(1) 甲方不得向经销地区其他买主供应本协议所规定的商品。如有询价，当转达给乙方洽办。若有买主希望从甲方直接订购，甲方可以供货，但甲方须将有关销售确认书副本寄给乙方，并按所达成交易的发票金额给予乙方*%的佣金。

party a shall not supply the contracted commodity to any other buyer(s) in the above mentioned territory. direct enquiries, if any, will be referred to party b. however, should any other buyers wish to deal with party a directly, party a may do so. but party a shall send to party b a copy of sales confirmation and give party b...% commission on the basis of the net invoice value of the transaction(s)concluded.

Between_______

whose registered office is at_____(hereinafter called "the Principal") and__________

其注册登记营业处设在 (以下简称为“委托人” 与

whose registered office at______(hereinafter called "the Agent") IT IS AGREED AS FOLLOWS

其注册登记营业处设在 (以下简称为代理人)就以下达成协议：

Art. 1 Territory and Products第一条 地区与产品

1.1. The Principal appoints the Agent, who accepts, as his commercial agent to promote the sale of the products listed in Annex 1, §1 (hereinafter called "the Products") in the territory defined in Annex 1, §2 (hereinafter called "the Territory").

委托人委任代理人，而代理人接受委托作为委托人的商事代理，在附件1§2中规定的地区(以下简称为“地区”)，推销附件1§1所列举的产品( 以下简称“产品”)。

1.2. If the Principal decides to sell any other products in the Territory, he shall inform the Agent in order to discuss the possibility of including them within the Products defined under article 1.1. However, the above obligation to inform the Agent does not apply if, in consideration of the characteristics of the new products and the specialization of the Agent, it is unreasonable to expect that such products may be represented by the Agent (e.g. products of a completely different range).

如果委托人决定在“地区”内销售任何其它产品，委托人应通知代理人以便讨论是否可能将这些产品包括在1.1所规定的“产品”之中。但是如果考虑到新产品的性能以及代理人的专长，而期望将这类产品交由该代理人代理是不合理的(例如完全不同类别的产品)，上述通知代理人的义务就不适用。

Art. 2 Good faith and fair dealing第二条 诚信与公平

2.1. In carrying out their obligations under this agreement the parties will act in accordance with good faith and fair dealing.

为履行本协议所规定的义务，当事人将依照诚信与公平的原则进行活动。

2.2. The provisions of this agreement, as well as any statements made by the parties in connection with this agency relationship, shall be interpreted in good faith.

本协议的条款以及当事人就本代理关系所作的声明，都应该以诚信的原则进行解释。

Art. 3 Agents functions 第三条 代理人的职责

3.1. The Agent agrees to use his best endeavours to promote the sale of the Products in the Territory in accordance with the Principals reasonable instructions and shall protect the Principals interests with the diligence of a responsible businessman.

代理人同意遵照委托人合理的指示，尽最大努力在“地区”内促进“产品”的销售，并应以负责任的商人的勤勉和努力，保护委托人的利益。

3.2. The Agent shall not solicit orders from outside the Territory unless permitted to do so by the Principal. Where the Agent negotiates with customers in the Territory business which results in contracts of sale with customers established outside the Territory, article 15.2. shall apply. E.g. for goods to be sold to subsidiary established in another country: the agent is acting within his territory, hat the sale is made to a foreign customer, and the agent would have (in absence of article 15.2) no right to commission.

非经委托人同意，代理人不得经“地区”之外的地方征求定货。如果代理人与该“地区”内的顾客洽谈商务导致与设立在本“地区”之外的顾客签订销 售合同，应适用第15.2节的规定。

3.3. Unless otherwise specifically agreed, the Agent has no authority to make contracts on behalf of, or in any way to bind the Principal towards third parties. He only solicits orders from customers for the Principal, who is free (save as set forth in article 4.2. hereafter) to accept or to reject them. The other alternative, i.e. to give the agent the authority to conclude contracts on behalf of the principal has not been considered in the model form, since it is rather uncommon in international trade. Of course, if the parties have special reasons for permitting the agent to make contracts on behalf of the principal, they can so provide in article 3.3. It should be noted that in certain cases the third party (customer) may rely on the apparent authority of the agent this means that, especially in legal systems where it is common that the agent is authorized to act on behave of the principal, the exclusion of any such authority provided for in the contract between principal

and agent (like art. 3.3. of this model form) does not necessarily bind a third party which had good reasons to rely on the apparent authority of the agent. It is, therefore, recommended that the principal avoids any action which may give third parties the impression that the agent has representative powers, and that he informs, if necessary and possible, third parties that the agent has no authority to bind the principal.

除非另有专门的协议，代理人无权代表委托人签约，也无权在签约中用任何方法使委托人受第三人之约束。代理人仅能为委托人经顾客处招揽定货，而委托人(除以下第4.2节的规定外)有接受或拒绝定货的自由。

3.4. When negotiating with customers, the Agent shall offer Products strictly in accordance with the terms and conditions of the contract of sale which the Principal has communicated to him. This is to ensure that orders by the customers conform to the Principals terms and conditions (e.g. prices, delivery terms, etc.): if this is not the case (because the agent has given incorrect information to the prospective customer) the principal will be in an embarrassing situation (at least from the commercial point of view) if the refuses the order.

代理人在与顾客洽商业务时，应严格按照委托人向其交代的销售合同的条款和条件对“产品”进行报价。

3.5. The Agent is not entitled to receive payments on the Principals behalf without prior written authorization from the Principal to that effect. When the Agent has been so authorized, he must transmit them as soon as possible to the Principal and until then hold them separately on deposit on the Principals behalf.

代理人未经委托人对该事项的事先书面授权，无权代表委托人收取付款。如果业经授权收款，则代理人必须尽快将付款转交给委托人，而在转交之前，应以委托人的名义将付款单独地存放。

Art. 4 Acceptance of orders by the Principal第四条 委托人接受定单

4.1. The Principal shall inform the Agent without undue delay of his acceptance or rejection of the orders transmitted by the latter. The Principal may accept or reject any individual order transmitted by the Agent at his own discretion.

委托人应不无故迟延地通知代理人对其转交的定单予以接受或拒绝。委托人对代理人转交的任何定单的接受或拒绝可由其自行决定。

4.2. The Principal may not however unreasonably reject the orders transmitted by the Agent. In particular, a repeated refusal of orders contrary to good faith (e.g. if made for the only purpose of hindering the Agents activity) shall be considered as a breach of contract by the Principal.

但是委托人不得无理地拒绝接受代理人所转交的定单。应特别指出有悖诚信原则的反复拒绝接受定单(例如，这样做的目的只是妨碍代理人的活动)，则被认为是委托人违约。

Art. 5 Undertaking not to compete第五条 保证不进行竞争

5.1. Without the prior written authorization of the Principal, the Agent shall not represent, manufacture or distribute any products which are in competition with the Products, for the entire term of this contract.

未经委托人事先以书面授权，代理人在合同的全部期限内不得代表、制造或经销与“产品”相竞争的任何产品。

5.2. The Agent may represent, distribute or manufacture any products which are not competitive with the Products, provided he informs the Principal in advance of such activity. However, the above obligation to inform the Principal does not apply if, in consideration: (i) of the characteristics of the products which the Agent wants to represent, and (ii) of the field of activity of the principal for whom the Agent wishes to act, it is unreasonable to expect that the Principals interests may be affected.

代理人可以代表、经销或制造与“产品”无竞争的任何产品，但是应在进行上述活动前事先通知委托人。然而，如果考虑到鉴于：(1)代理人打算代理的产品的性能以及(2)代理人打算为之进行代理业务的委托人的经营范围，委托人的利益按合理的期待可能不会被影响，则上述向委托人事先通知的义务不适用。

5.3. The Agent shall refrain from representing or distributing non-competitive products of a manufacturer who is a competitor of the Principal, if requested to do so by the Principal, provided the latters request is reasonable, taking into account all the circumstances of the case. E.g. if there are reasons to fear that the collaboration with a competitor may impair the confidence between the parties or the protection of confidential information.

若委托人如此要求，并且从实际情况来看该要求是合理的，则代理人须不为与委托人竞争的制造商代表或经销非竞争性产品。

5.4. The Agent declares that he represents (and/or distributes or manufactures, directly or indirectly) the products listed in Annex II on the date on which this contract is signed.

在本合同签字之日，代理人宣布对附件11所列举的产品作为代表(和/或直接或间接地进行经销或制造)。

Art. 6 Sales organization, Advertising and Fairs第六条 销售机构、广告和展销

6.1. The Agent shall provide an adequate organization for sales and, where appropriate, after-sale service, with all necessary means and personnel, in order to ensure the fulfillment of his obligations throughout the Territory under this agreement.

为了保证在整个“地区”履行本协议项下的义务，代理人应以必要的手段和人力建立充分的销售机构，并且当适宜时，建立售后服务。

6.2. The parties may agree on the advertising to be jointly made in the Territory. The contents of any advertising must be approved by the Principal. The cost of advertising carried out by the Agent shall be apportioned between the parties as indicated in Annex III, §1.

当事人可同意在“地区”内联合进行宣传广告。广告的内容必须经委托人批准。代理人所作广告的费用应按附件三§1的规定，由当事人分摊。

6.3. The parties shall agree on their participation in fairs or exhibitions within the Territory. The cost of the Agents participation in such fairs and exhibitions shall be apportioned between the parties as indicated in Annex III, §2.

当事人应同意参加在“地区”内举办的交易会或展览会。代理人参加交易会和展览会的费用应按附件三§2的规定由当事人分摊。

Art. 7 Sales Targets-Guaranteed Minimum Target

第七条 销售目标 保证完成的最低目标

A distinction is made between a "sales target" (7.1., 7.2.) the non-attainment of which does not, in principle, involve a contract breach, and o "guaranteed minimum target" (7.3.), which implies a possible contract termination (or other consequences) in case of non-attainment. If the parties wish to agree upon such "guaranteed minimum target", they must fill in Annex IV.

7.1. The parties may agree annually on the sales targets for the forthcoming year.

当事人可每年商定来年的销售目标。

7.2. The parties shall make their best efforts to attain the targets agreed upon but the non attainment shall not be considered as a breach of the contract by a party, unless that party is clearly at fault.

当事人应竭尽全力地实现商定的目标，但是未实现目标不应认为是某一方的违约，除非该方有明显的过错。

7.3. In Annex IV the parties may agree on a Guaranteed Minimum Target and on the consequences of its non-attainment.

在附件五中当事人可以商定保证完成的最低目标以及未能实现目标的后果。

Art 8 Sub-agents 第八条 分代理人

(In certain circumstances it may be advisable to add a clause providing that each party agrees not to engage subagents and/or employees of the other party. ) The Agent may engage sub-agent. The Agent must carry out agents, provided he informs his activity without recourse the Principal at least one month before the engagement to sub-agents. The Agent shall be responsible for the activities of his subagents.

代理人可以聘用分代理人，但至少代理人必须自己进行业务活动，不依但至少在聘用前一个月通知委托人。代理人应对分代理人的活动责。

Art. 9 Principal to be kept informed 第九条 向委托人通报情况

9.1. The Agent shall exercise due diligence to keep the Principal informed about his activities, market conditions and the state of competition within the Territory. He shall answer any reasonable request for information made by the Principal.

代理人应以适当勤勉向委托人通报其在“地区”内的活动，市场情况以及竞争状况，代理人应答复委托人提出的合理的有关提供信息的要求。

9.2. The Agent shall exercise due diligence to keep the Principal informed about:

代理人应以适当勤勉向委托人通报有关：

(i) the laws and regulations which are to apply in the Territory to which the Products must conform (e.g. import regulations, labeling, technical specifications, safety requirements, etc.), and

在“地区”内要实施的“产品”必须符合的法律和法规，(如进口条例、标签、技术规格、安全要求等);

(ii) the laws and regulations concerning his activity, as far as that they are relevant for the Principal.

有关代理人业务活动的法律和法规，只要是与委托人有关。

Art. 10 Financial responsibility第十条 财务责任

10.1. The Agent shall satisfy himself, with due diligence, of the solvency of customers whose orders he transmits to the Principal. He shall not transmit orders from customers of which he knows or ought to know that they are in a critical financial position, without informing the Principal in advance of such fact.

代理人应以适当勤勉查明他向委托人转交定单的顾客的支付能力。对于代理人知道或应该知道财务处于危急情势的顾客之定单，在未事先向委托人通报这种情况下，不得将其定单转交委托人。

10.2. The Agent shall act as a del credere agent only if, and to the extent, the parties have expressly agreed thereto. In that case they should complete and sign Annex V.

只有经当事人明确商定并仅在双方商定的范围内，代理人才能充当担保买方信用的代理人。双方为此应填写并签署附件五。

Art. 11 Principals trademarks and symbols 第十一条 委托人的商标和标志

11.1. The Agent shall use the Principals trademarks, trade names or any other symbols, but for the only purpose of identifying and advertising the Products, within the scope of this contract and in the Principals sole interest.

代理人应使用委托人的商标、商名和其它任何标志，但其唯一目的是为了识别和宣传“产品”，而且只限于在本合同的范围内和为了委托人的利益。

11.2. The Agent hereby agrees neither to register, nor to have registered, any trademarks, trade names or symbols of the Principal (or which are confusingly similar with the Principals ones), in the Territory or elsewhere.

代理人在此同意不在本“地区”或其它地区将委托人的商标、商名或标志(或与以上商标、商名或标志相近似而可能引起混乱名)如以注册或使之被注册。

11.3. The right to use the Principals trademarks, trade names or symbols, as provided for under the first paragraph of this article, shall cease immediately for the Agent, on the expiration or termination, for any reason, of the present contract.

本条第一所规定的关于使用委托人的商标、商名或标志的权利，在本合同期满或由于任何原因而终止时，应立即终结。

11.4. The Agent shall notify the Principal of any infringement of the Principals trademarks, trade names or symbols that comes to his notice.

代理人一旦发现委托人的商标、商名或标志被侵权时，应通知委托人。

Art. 12 Complaints by Customers第十二条 顾客投诉

The Agent shall immediately inform the Principal of any observations or complaints received from customers in respect of the Products. The parties hereto shall deal promptly and properly with such complaints. The Agent has no authority to engage in any way the Principal, unless after he has received a specific authorization to such effect.

代理人应立即将收到的或注意到的顾客对“产品”的意见或投诉通知委托人。当事人应及时并恰当地处理这些投诉。除非代理人收到专门的书面授权，他无权以任何方式将委托人卷入。

Art. 13 Exclusivity 第十三条 排他性

13.1. The Principal shall not, during the life of this contract, grant any other person or undertaking within the Territory the right to represent or sell the Products.

委托人在本合同有效期内，不得授予“地区”内的其他人或企业“产品”的代理权和销售权。

13.2. The Principal is however entitled to deal directly, without the Agents intervention (provided he informs the latter) with customers situated in the Territory; in respect of any sales arising therefrom, the Agent shall be entitled to the commission provided for in this contract.

然而，委托人有权与“地区”内的顾客直接进行交易而无须代理人介入(但应通知代理人);经此形成的任何销售，代理人应有权取得按本合同规定的佣金。

13.3. The Principal shall be entitled to deal directly with the special customers listed in Annex VI, §2; in respect of the sales to such customers the Agent shall be entitled to the reduced commission provided for in Annex VI, §2. Paragraph 13.3. shall not apply if §2 of Annex VI (Special customers/Reduced commission) has not been filled in by the parties.

委托人有权与附件六§2所列举的特别顾客直接进行交易;同这一类顾客的销售，代理人应有权取得按附件六§2规定的减低的佣金。如果当事人未 填写附件六§2(特别顾客与减低的佣金)，则第13.3款不适用。

Art. 14 Agent to be kept informed 第十四条 向代理人通报情况

14.1. The Principal shall provide the Agent with all necessary written information relating to the Products (such as price lists, brochures, etc.) as well as with the information needed by the Agent for carrying out his obligations under the contract.

委托人应向代理人提供有关“产品”的所有必要的书面资料(诸如价格表、宣传小册子等)以及代理人为履行本合同义务而需要的其它资料。

14.2. He shall furthermore inform the Agent without undue delay of his acceptance, refusal and/or non-execution of any business transmitted by the Agent.

委托人还应该不无理迟延地通知代理人，其是否接受或拒绝和/或不予执行代理人所转交的生意。

14.3. The Principal shall keep the Agent informed of any relevant communication with customers in the Territory.

委托人应经常将其与“地区”内顾客的交往情况向代理人通报。

14.4. If the Principal expects that his capacity of supply will be significantly lower than that which the Agent could normally expect, he will inform the Agent within a reasonable time.

如果委托人预料其供货能力比代理人通常所期望的要低得多，委托人应在合理的时间内向代理人进行通报。

Art. 15 Agents commission第十五条 代理人佣金

15.1. The Agent is entitled to the commission provided for in Annex VI, §1, on all sales of the Products which are made during the life of this contract to customers established in the Territory.

代理人有权在本合同的有效期内，从向设立在“地区”内的顾客销售“产品”中收取附件六§1规定的佣金。

15.2. If the Agent, when dealing with customers established in the Territory, solicits orders resulting in contracts of sale with customers established outside the Territory, and if the Principal accepts such orders, the Agent shall be entitled to receive a reduced commission, the amount of which shall be decided on a case by case basis. Similarly, the Agents commission shall be reduced when an other agent solicits orders with customers established outside the Territory resulting in contracts of sale with customers established within the Territory.

如果代理人与在“地区”内设立的顾客进行业务中，由于招揽定单导致与“地区”外设立的顾客签订销售合同，并且如果委托人接受这种定单，则代理人应有权收取减低的佣金，其数量应根据具体情况个案决定。同样，若其他代理人在“地区”外设立的顾客招揽定单导致与“地区”内设立的顾客签订销售合同，则代理人的佣金也应减低。

15.3. A reduced commission may be agreed in advance between the Principal and the Agent in appropriate circumstances where a customer is to be granted terms or conditions which are more favorable than the Principals standard conditions. If the parties have filled in §3 of Annex, VI the figures indicated therein shall apply in the respective situations.

在适当情况下，如果给予顾客的条款和条件比委托人的标准条件更为优惠，委托人和代理人之间可以事先商定经过减少的佣金。如果当事人已填写附件六§3，其中指明的数额应分别适用于各种情况。

15.4. Unless otherwise agreed in writing, the commission covers any expenses incurred by the Agent in fulfilling his obligations under this contract (such as telephone, telex, office, travel expenses, etc.)

除非另有书面商定，代理人为履行本合同之义务所发生的任何支出(如电话、电传、办公费用、差旅支出等)应由佣金负担。

Art. 16 Method of calculation commission and payment第十六条 佣金和报酬的计算方法

16.1. Commission shall be calculated on the net amount of the involves, i.e. on the effective sales price (any discount other than cash discounts being deducted) clear of any additional charges (such as packing, transportation, insurance) and clear of all tariffs or taxes (including value added tax) of any kind, provided that such additional charges, tariffs and taxes are separately stated in the invoice.

佣金应根据发票的净金额计算，即实际销售价格(现金折扣以外的所有折扣都扣除)扣除任何附加费用(诸如包装、运输、保险)，并扣除所有的关税和税收(包括增值税)，如果这些附加费用，关税和税收在发票上分别列明的话。

16.2. The Agent shall acquire the right to commission after full payment by the customers of the invoiced price. In case of partial payment made in compliance with the sales contract, the Agent shall be entitled to a proportional advance payment. In case the Principal is insured against the risk of non-payment by his customers, the parties may agree that a commission be paid on the sums obtained by the Principal from the insurer, by filling in Annex VI, 4.1.

代理人在顾客全部支付发票价格后即取得收取佣金的权利。如果按照销售合同部分付款，代理人有权按比例预支其佣金。如果委托人就顾客不付贷款的风险而投保，当事人可以商定，通过填写附件六、4•1款，佣金以委托人从保险人处所得到的金额中进行支付。

16.3. The Principal shall provide the Agent with a statement of the commissions due in respect of each quarter and shall set out all the business in respect of which such commission is payable. The commission shall be paid not later than the last day of the month following the relevant quarter.

委托人应每一季度向代理人提交到期佣金的报表并且列举应付佣金的有关生意。佣金不得迟于该季度之后第一个月的最后一天支付。

16.4. The Agent is entitled to all the information, and in particular extracts from the Principals books, in order to check the amount of the commission due to him. The Principal shall permit an independent auditor appointed for that purpose by the Agent to inspect the Principals books for the purpose of checking the data relevant for the calculation of the Agents commission. The costs of such inspection shall be borne by the Agent.

代理人有权取得所有资料，特别是委托人帐册的摘录，以便检查其应得的佣金额。委托人应允许代理人为此目的指定独立的审计师审查有关计算代理人佣金的材料，这种审查的费用应由代理人负担。

16.5. Should any governmental authorization (e.g. due to exchange control regulations in the Principals country) be necessary for the Principal to transfer abroad the commission (or any other sum the Agent may be entitled to receive), then the payment of the amount shall be made after such authorization has been given. The Principal shall take all necessary steps for obtaining the above authorizations.

如果委托人将佣金(或代理人应收取的其他金额)转至国外须经政府授权(例如由于委托人国家的外汇管制条例)，则应在取得这种授权后才进行支付。委托人为取得上述授权应采取所有的必要步骤。

16.6. Except as otherwise agreed, the commission shall be calculated in the currency of the sales contract in respect of which the commission is due.

除非另有约定，佣金应以须付佣金的销售合同的币种进行计算。

16.7. Any taxes imposed on the Agents commission in the Territory are for the Agents account.

在“地区”内就代理人佣金征收的任何税金都由代理人负担。

Art. 17 Unconcluded business第十七条 未成交的业务

17.1. No commission shall be due in respect of offers or orders transmitted by the Agent and not accepted by the Principal.

代理人转交的报价或定单没有被委托人接受，不应支付佣金。

17.2. If a contract made by the Principal as a result of orders transmitted by the Agent is not thereafter put into effect, the Agent shall be entitled to commission unless non performance of the contract is due to reasons for which the Principal is not responsible.

如果代理人转交定单致使委托人签订合同，但此后合同未能生效，代理人应有收取佣金的权利，除非合同未能履行非由委托人应负责任的原因造成。

Art. 18 Term of the Contract第十八条 合同条款

18.1. This contract is concluded 18.1. This contract enters for an indefinite period -------

and enters into force on into force on the -------- and shall remain in force --------- until ---.

本合同的期限为无限，自__日起生效。本合同自__日起生效，并在__以前继续有效。

18.2. This contract may be 18.2. This contract shall be terminated by either party by automatically renewed for notice given in writing by successive periods of one means of communication year, unless terminated by ensuring evidence and date of either party by notice given receipt (e.g. registered mail in writing by means of with return receipt, special communication ensuring courier, telex), not less than evidence and date of receipt 4 months in advance. If the (e.g. registered mail with contract has lasted for more return receipt, special courier, than five years, the period of telex), not less than four than five years, the period of telex), not less than four notice will be of 6 months. months before the date of The end of the period of expiry, by registered mail notice must coincide with the with return receipt. If the end of a calendar month. contract has lasted for more The parties may agree in than five years, the period of writing on longer periods of notice will be of 6 months. notice. The parties may agree in writing on longer periods of notice.

任何一方当事人可至少提前四个月通过保证有证据和收到日期的书面通讯手段(如有回执的挂号信、专门信使、电传)通知终止本合同。如果合同已持续五年以上，通知期限为六个月。通知期限的终止日应与某日历月份的最后一天相重合。当事人可以用书面约定更长的通知期限。除非任何一方当事人在合同满期之日前不少于四个月通过保证有证据和收到日期的书面通讯手段(如有回执的挂号信、专门信使、电传)提出终止合同，则本合同将以一年为一期自动连续延长。如果合同已持续五年以上，通知期限为六个月。双方可以通过书面约定更长的通知期限。

Art. 19 Unfinished business 第十九条 未完成的业务

19.1. Orders transmitted by the Agent or received by the Principal from customers established in the Territory before the expiry or termination of this contract and which result in the conclusion of a contract of sale not more than six months after such expiration, shall entitle the Agent to commission.

在本合同期满或终止前，代理人转交的或委托人收到在“地区”内设立的顾客订单，并因而在合同满期后的六个月内签订了销售合同，代理人有权对此收取佣金。

19.2. No commission is due to the Agent for contracts of sale made on the basis of orders received after the expiry or termination of this contract, save if such transaction is mainly attributable to the Agents efforts during the period covered by the agency contract and if the contract was entered into within a reasonable period after the expiry or termination of this contract. The Agent must however inform the Principal in writing, before the expiry or termination of this contract, of the pending negotiations which may give rise to commission under this paragraph.

以在本合同期满或终止后所收到的定单为根据而签订的销售合同，代理人不应从中收取佣金，除非该交易主要归功于代理人在代理合同有效期内所作的努力，而且该销售合同是在本合同期满或终止后的合理期限内生效。然而，代理人必须在本合同期满或终止之前按本章节的规定，将尚未结束而据此款规定可能发生佣金的业务书面通知委托人。

Art. 20 Earlier termination 第二十条 提前终止合同

20.1. Each party may terminate this contract with immediate effect, by notice given in writing by means of communication ensuring evidence and date of receipt (e.g. registered mail with return receipt, special courier, telex), in case of a substantial breach by the other party of the obligations arising out of the contract, of in case of exceptional circumstances justifying the earlier termination.

如果出现一方当事人根本违反合同义务的情况或出现使提早终止合同成为合理的异常情况，各方当事人可以通过确保有证据和收到日期的书面通讯手段(例如有回执的挂号信、专门信使、电传)通知对方立即终止合同。

20.2. Any failure by a party to carry out all or part of his obligations under the contract resulting in such detriment to the other party as to substantially deprive him of what he is entitled to expect under the contract, shall be considered as a substantial breach for the purpose of article 20.1. above. Circumstances in which it would be unreasonable to require the terminating party to continue to be bound by this contract, shall be considered as exceptional circumstances for the purpose of article above.

一方当事人由于不履行本合同的全部或部分义务而损害另一方当事人的利益以致使其基本丧失期望从本合同取得的利益，则此种不履行应视为是上述20.1款中所谓的根本违约。若要求提出终止合同的一方仍受本合同之约束成为不合理，这种情况应视为是上述20.1款中的异常情况。

20.3. The parties hereby agree that the violation of the provisions ------ under 18 of the present contract is to -------- be considered in principle, unless the contrary is proved, as a substantial breach of the contract. Moreover, any violation of the contractual obligations may be considered as a substantial breach, if such violation is repeated notwithstanding a request by the other party to fulfill the contract obligations. The parties may make reference here to those particles for which a breach is consider of particular importance. This may be the case for articles 5 (non competition), 7.3. (Guaranteed minimum target: if agreed), 11.2. (unauthorized registration of the principals trademarks by the agent), 13.1. (grant of exclusivity by the principal) and 15.1 (payment of commission to the agent). It is recommended that the use of this article should be limited to essential situations only.

双方当事人商定，违反本合同------的条款应在原则上视为是根本违反合同，除非经证明情况与此相反。此外，如尽管一方当事人请求另一方当事人履行合同义务，而另一方仍再三违反合同义务，则任何违反都可以视为是根本违反合同。

20.4. Furthermore, the parties agree that the following situations shall be considered as exceptional circumstances which justify the earlier termination by the other party: bankruptcy, moratorium, receivership, liquidation or any kind of composition between the debtor and the creditors, or any circumstances which are likely to affect substantially one partys ability to carry out his obligations under this contract.

另外，双方当事人同意认定以下情况为异常情况，可以作为一方要求提前终止合同的理由：破产、延期偿付权、破产财产管理、清算或任何债权人和债务人之间的偿付协议，以及其他可能严重影响一方执行本合同义务能力的情况。

20.5. If the parties have filled in Annex VII, the contract may also be terminated by the Principal with immediate effect in case of change of control, ownership and or management of the agent- company, according to the provisions set forth in Annex VII.

如果双方当事人已填写附件七，遵照该附件的条款，一旦作为代理的公司的控制权、所有权和/或经营发生变化，委托人也可以立即终止合同。

20.6. If a party terminates the contract according to this article, the arbitrators ascertain that the reasons put forward by that party did not justify the earlier termination, the termination will be effective, but the other party will be entitled to damages for the unjustified earlier termination. Such damages will be equal to the average commission for the period the contract would have lasted in case of normal termination, unless the damaged party proves that the actual damage is higher (or, respectively, the party having terminated the contract proves that the actual damage is lower). The above damages are in addition to the indemnity which may be due under article 21.

如果一方当事人按照本条规定终止合同，但是仲裁员确定该方所提出的理由并不能证明提前终止是正当的，终止将生效，但是另一方当事人有权因不正当的提前终止取得损害赔偿金。赔偿金应相当于若合同正常终止所持续的期限的平均佣金，除非受损失一方证明实际损失要高于此数。(或者，终止合同一方证明实际损失低于此数)。上述赔偿金是在第21条规定应付的补偿费之外。

Art. 21 Indemnity in case of termination第二十一条 终止合同的补偿

21.1. The Agent shall be en- 21.1. The Agent shall not be titled to an indemnity ("good-

entitled to an indemnity for will indemnity") if and to the goodwill or similar extent that:

compensation 20 ("goodwill indemnity") in case of

如果发生以下情况，代理人无权要求商誉补偿或类似的赔偿。

a) he has brought the termination of the contract. Principal new customers or This provision does not limit has significantly increased the Agents right to claim the volume of business damages for breach of contract ness with existing customers as far as the termination by and the Principal the Principal amounts to such continues to derive a breach, and is not already substantial benefits from covered by article 20.6. the business with such customers, and

代理人为委托人带来新的顾客或是大量增加了与现有顾客的业务，且委托人能够继续与这些顾客进行业务并得到实质性收益，以及

b) the payment of this indemnity is equitable having regard to all the circumstances and, in particular, the commission lost by the Agent on the business transacted with such customers.

考虑所有的情况特别是代理人与上述顾客所进行业务的佣金损失，支付这一笔补偿费是公平的。

21.2. The amount of the in indemnity shall not exceed a figure equivalent to an indemnity for one year calculated from the Agents average annual remuneration over the preceding five years and, if the contract lasted for less than five years, the indemnity shall be calculated on the average for the period in question.

补偿费的数额不得超过相当于一年的补偿，即按过去五年中代理人年平均报酬计算，如果合同持续期不满五年，应按实际年限的平均数进行计算。

21.3. The Agent will lose the right to indemnity if he does not claim the indemnity in writing within one year from contract termination.

如果在合同终止后的一年内，代理人未书面提出补偿的要求，其要求补偿的权利即告丧失。

21.4. The Agent shall have no right to indemnity in the following cases:

在下列情况下，代理人无权要求补偿：

a) where the Principal has terminated the contract according to the conditions set out in article 20;

委托人按照第20条的条件终止合同;

b) where the Agent has terminated the contract, unless the termination is justified under article 20 or on grounds of age, infirmity or illness in consequence of which the Agent cannot reasonably be required to continue his activities;

代理人终止合同，除非根据第20条该终止是合理的或由于代理人年老、体弱和疾病，要求其继续他的业务活动是不合理的。

c) where, in accordance with article 26.2, the Agent assigns his rights and duties under the agency contract to another person.

根据第26.2款，代理人将其在代理合同中的权利与义务转让给他人。

21.5. The goodwill indemnity provided for under this article is in lieu of any compensation for loss or damage arising out of the contract expiration or termination (except damages for breach of contract). In some countries, such as EEC countries which have adopted the EEC directive or other countries with similar mandatory rules, alternative A would violate mandatory requirements. 20 This broad definition is meant to cover any compensation to be paid in case of contract termination independent from a breach of contract by the Principal, including payments which are not defined as an "indemnity", or "goodwill indemnity, see above, §2 of the introduction.

本条所规定的商誉补偿是用以代替由于合同期满或终止所产生的损失的任何一种补偿(违约损害赔偿金除外)。

Art. 22 Return of documents and samples第二十二条 退回文件和样品

Upon expiry of this agreement the Agent shall return to the Principal all advertising material and other documents and samples which have been supplied to him by the Principal and are in the Agents possession.

在合同期满时代理人应退回委托人提供给代理人并由代理人占有的所有宣传广告材料、其他文件和样品。

Art. 23 Arbitration, Applicable law第二十三条 仲裁--适用法律

23.1. Any dispute arising out of or in connection with the present Contract shall be finally settled in accordance with the Rules of Conciliation and Arbitration of the international Chamber of Commerce by one or more arbitrators designated in accordance to said Rules.

本合同引起的或与本合同有关的任何争端，应遵照“国际商会调解和仲裁规则”，由按照上述规则指定的一个或一个以上的仲裁员进行最终的解决。

23.2. The arbitrators shall apply the provisions constrained in this contract and the principles of law generally recognized in international trade as applicable to international agency contracts, with the exclusion - subject to article 23.3. hereunder of national laws. If the Agent is established within the EEC, the mandatory provisions of the EEC Directive of 18 December 1986 shall also apply.

仲裁员应适用本合同所包含的条款以及国际贸易中普遍承认适用于国际代理合同的法律原则，并在第23.3款管辖下，排除国内法。如果代理人是在欧共体国家中设立，则1986年12月18日的欧共体指令的强制性条款也同样应该适用。

23.3. The arbitrators shall in any case consider such mandatory provisions of the law of the country where the Agent is established which would be applicable even if the parties submit the agreement to a foreign law. The arbitrators will take the above provisions into account to the extent they embody principles which are universally recognized and provided their application appears reasonable in the context of international trade.

可能即使双方当事人将协议交付某一外国法管辖，代理人设立国法律的强制性规则也仍得适用;仲裁员在任何情况下都应考虑此类规则。仲裁员将考虑上述强制性规则，如果它们体现普遍承认的原则并且它们的适用从国际贸易的角度看是合理的。

Art. 24 Automatic inclusion under the present contract 第二十四条 本合同自动包含规则

24.1. If the parties have not made a choice between the alternative solutions provided in articles 8 and 18 under the letters A and B, by deleting one of the alternatives, and provided they have not expressly made a choice by other means, alternative A shall be considered applicable.

如果双方当事人没有对第8条和第18条中字母A和B所列举的供选用的方案作出选择并删除其中的一种，而且如果双方也没有明示地用其它方法作出选择，应认为方案A适用。

24.2. If the parties have not made a choice between the alternative solution provided in article 21 (goodwill indemnity in case of termination) under the letters A and B, by deleting one of the alternatives, and provided they have not expressly made a choice by other eans, alternative A shall be considered applicable if the Agent is established in a country where a goodwill indemnity in case of termination is recognized by mandatory law and alternative B shall apply in the opposite case.

如果双方当事人没有对第21条(终止合同的商誉补偿)中的字母A和B所列举的供选用的方案作出选择并删除其中的一种，而且如果双方没有明示地用其他方法作出选择，则当代理人设立在合同终止时商誉补偿为强制法律所承认的国家中时，方案A应认为是适用的;反之，方案B应适用。

24.3. The annexes attached to this contract form an integral part of the agreement. Annexes or part of annexes which have not been filled in will be effective only to the extent and under the conditions indicated in this contract.

本合同的附件构成协议的组成部分。各附件或部分附件未经填写者，其有效程度仅由依照本合同规定的条件。

Art. 25 Previous agreements - Modifications - Nullity第二十五条 先前的协议•修改•废除

25.1. This Contract replaces any other preceding agreement between the parties on the subject.

本合同取代双方当事人之间过去有关该事项的任何其他协议。

25.2. No addition or modification to this contract shall be valid unless made in writing. However a party may be precluded by his conduct from asserting the invalidity of additions or modifications not made in writing to the extent that the other party has relied on such conduct.

除非以书面形式做成，对本合同所进行的补充和修改均无效。但是若一方当事人已依赖另一方的行为，则另一方可能因其自己的行为而致无权声称该非书面做成的补充或修改无效。

25.3. The nullity of a particular clause of this contract shall not involve the nullity of the whole agreement, unless such clause is to be considered as substantial, i.e. if the clause is of such importance that the parties (or the party to the benefit of which such clause is made) would not have entered into the contract if it knew that the clause would not be valid.

本合同某一条款的无效不应导致整个合同无效，除非该条款被认为是实质性的，即该条款如此重要，以致双方当事人(或该条款是为某利益而制定的一方当事人)如果知道该条款无效，就不会签订合同。

Art. 26 Prohibition of assignment第二十六条 禁止转让

26.1. The present contract cannot be assigned without prior written agreement between the two parties.

未经双方当事人事前书面同意，本合同不得转让。

26.2. If article 21 A is applicable, and if there has been assignment by the Agent with the Principals consent according to article 21.4(c), the goodwill indemnity of the new agent shall be calculated by also taking into account the activity of the old agent, according to article 21. It is expressly agreed that the amount that may have been paid by the new agent to the previous one shall not be taken into account when calculating the indemnity. The purpose of this sentence is to make clear that the price paid by the new agent to the old one (which price may be influenced by facts which are out of the scope of the agency agreement), is not a basis for calculating the indemnity.

如果适用第21条A，并且代理人按照第21.4(C)节，经委托人同意转让了合同，根据第21条，在计算新代理人的商誉补偿时，也应考虑前任代理人的活动。在计算补偿(注21)时，双方明示商定新代理人可能向前任代理人支付的金额不考虑在内。

Art. 27 Authentic text 第二十七条 有效文本

The English text of this contract is the only authentic text.

本合同的英文文本是唯一的有效文体。

Made in on the ----------合同签订的地点日期

The Principal委托人The Agent 代理人

If the contract is written in another language this clause should of course be modified to indicate the language of the contract.

ANNEX I PRODUCTS AND TERRITORY附件一 产品和地区

(Article 1.1.) (第1.1款)

§1. Products §1.产品

If this paragraph 1 of Annex I has not been filled in, all products manufactured and/or sold

by the Principal at present and in the future shall be considered as "Products" for the

purpose of this contract.----------

If the parties choose this solution (including any future products in the contract) problems may arise in case of conflict between new products from the manufacturer and products of other manufacturers already represented by the agent. If such problems are foreseeable, the parties should define appropriate rules for solving the conflict.

如果附件一的本段1未经填写，委托人在目前和将来所制造和/或销售的所有产品都应视为本合同中的“产品”(注23)。 │

§2. Territory §2.地区

If this paragraph 2 of Annex I has not been filled in, the whole territory of the country where the Agent has his place of business will be considered as "Territory" for the purpose of this contract.

如果附件一的本段2未经填写，代理人设立营业地的国家的整个领土应视为本合同中的“地区”。

ANNEX II PRODUCTS AND PRINCIPALS REPRESENTED BY THE AGENT

附件二 代理人所代理的产品和委托人

(Article 5.4.) (第5.4节)

This Annex is applicable only if filled in by the parties.

本附件仅在经双方当事人填写后才能适用

The Agent hereby declares that he represents (and/or distributes or manufactures) the following products, directly or indirectly, at the time of the conclusion of the present contract:

代理人兹宣布，从本合同签订之日起，其直接或间接地代理和/或销售或制造)以下产品：

PRINCIPAL委托人 PRODUCTS产品

ANNEX III ADVERTISING, FAIRS AND EXHIBITIONS附件三 广告•交易会和展览会

§1. Advertising (art. 6.2.) §1.广告(第6.2款)

Except as otherwise agreed in writing, the costs of agreed advertising shall be shared between the parties as follows:

除非另有书面约定，经过同意的广告费用应由双方当事人按下列比例进行分摊：

--------- Principle: %委托人__%

--------- Agent: %代理人___%

If the figures left blank in the above paragraph are not filled in by, the parties, each party will bear the advertising expenses it has incurred.

如果双方未在上段的空格中填写数字，则各方负担其已经发生的广告费用

§2. Fairs and exhibitions (art. 6.3.) §2.交易会和展览会(第6.3款)

Except as otherwise agreed in writing, the costs for participation in fairs and exhibitions in the Territory shall be shared between the parties as follows:

除非另有书面约定，参加“地区”内的交易会和展览会的费用应由双方按下列比例进行分摊：

--------- Principal: %委托人__%

--------- Agent: %代理人__%

If the figures left blank in the above paragraph are not filled in by the parties, each party will bear the expenses for participation in fairs and exhibitions it has incurred.

如果双方未在上段的空格中填写数字，则各方负担其已经发生的参加交易会和展览会的费用。

ANNEX IV GUARANTEED MINIMUM TARGET附件四 保证完成的最低目标

(Article 7.3) (第7.3款)

This Annex IV is applicable only if the parties have fixed the minimum target by filling in

one of the alternative figures hereafter --------

本附件仅在双方填写以下供选用的方式之一，从而确定了最低目标后才能适用。

The Agent undertakes, during each year, to transmit orders for not less than:

代理人在每一年度中承诺向委托人转交的定单不能低于：

If this alternative is chosen, care should be taken in order to avoid that the agreed sum is automatically reduced (from year to year) as a consequence of inflation, e.g. by providing a yearly increase. If at the end of the year the above Guaranteed Minimum Target has not been attained, for

reasons other than those for which the Principal can be held responsible, subject to giving one months notice, the Principal shall be entitled at his choice, to terminate this contract, or to cancel the Agents exclusivity, or to reduce the extension of the Territory. This right must however be exercised in writing not later than two months after the end of the year in which the Guaranteed Minimum Target has not been attained. Unless the parties hereafter agree on different figures, the Guaranteed Minimum Target indicated above shall also be applicable for each year of the duration (including the case of renewal) of this agreement.

如果在该年度末，上述目标没有实现，且非委托人的责任，则委托人有权选择终止本合同，或取消代理人的独家代理权，或缩小“地区”的范围，但应提前一个月通知。此权利必须以书面形式在未实现保证完成最低目标的年度终了之后的两个月内行使。除非将来商定不同的数字，上述保证实现的最低目标应在本合同的期限内(包括合同展期)的每一年度中适用。

ANNEX V DEL CREDERE25附件五 担保买方支付(注25)

(Article 10.2) (第10.2款)

In choosing the options parties should pay attention to the legal rules of the country where the agent is established. In some legal systems (e.g. Great Britain) there are no limitations; in others (e.g. Germany) the del credere obligation must be limited to specific business or customers and a special commission must be paid; in other countries (e.g. Italy) del credere may be granted on all business, and without special commission, but only for a percentage of the loss.

This Annex V is applicable only to the extent it is filled in and provided it has been signed

by the parties

本附件五仅在经填写并经双方当事人签字后方才适用

The Agent shall act as a del credere agent according to the conditions stated hereafter.

A del credere obligation means that the Agent undertakes to reimburse to the Principal the total or partial amount (according to the alternative solutions under §2 hereafter) of unpaid sums that the Principal is entitled to receive from customers and which have not been paid for reasons for which the Principal is not responsible. The del credere obligation does not cover the expenses incurred by the Principal for recovering his credits.

根据下述条件，代理人应担当担保买方支付的代理人。

担保买方支付的义务是指代理人承担向委托人偿付未付款的全部或部分金额( 根据以下§2的选用方案)。该欠款委托人有权经顾客收取，而且未支付欠款并非委托人的责任。保付货价的义务不包括委托人为上回拖欠款所发生的费用。

1. The agent shall be responsible: 代理人应负责：

.A for any business transmitted by him所有由其转交的业务

.B. only for business or customers expressly agreed case by case

仅限于逐项明示约定的顾客或业务

2. The agents responsibility shall be: 代理人的责任应为：

.A unlimited无限的

.B limited to ¡õ% of the sums not recovered26限于尚未收回金额的(注26)__%

.C limited to ¡õtimes the agreed commission限于约定佣金的□□倍

Options 2.B and 2.C may be used together: e.g. not more than 15% of the sums not recovered and not more than three times the agreed commission.

3. The agent shall be entitled to an extra commission of ¡õ% on all business on which he has granted del credere.

代理人对所有授予担保买方支付的业务，有权收取□□%的额外佣金。

4. No del credere is due if the loss is due to reasons for which the Principal is clearly responsible.

如果由于委托人明显的责任而造成损失，不成支付保付货价。

5. The Agent has no right to commission according to article 16.2. However, the del credere obligation shall in no case exceed the total amount due by the customer minus the Agents commission.

根据第16.2款，代理人无权收取佣金。但是担保买方支付的义务决不应超过顾客应付总金额减去代理人佣金的金额。

The Principal委托商The Agent代理商

ANNEX VI COMMISSIONS附件六 佣金

§1. Amount of commission (Art. 15.1.) §1.佣金金额(第15.1款)

1.1. Simple commission简单佣金

Amount of commission is ¡õ%佣金金额为------%

1.2. Different levels of commission according to the value of the sales contract.

根据销售合同价值而定的不同佣金标准

§3. Negotiation margins and discounts (Art. 15.3.) §3.谈判幅度和折扣(第15.3款)

3.1. Negotiation margins谈判幅度

The Agent has a negotiation margin of ------% on the prices set out in the price-list in force. Therefore, the Agent may propose to customers any discount within such margins without reduction to his rate of commission.

代理人对现行价格目录上所列的价格有百分之------的谈判幅度。因此代理人可以向顾客提出在此幅度内的任何折扣而不降低其佣金比例。

3.2 Authorized discount经认可的折扣

The Agent is entitled to propose to customers the following discounts, which entail a reduction in his commission, in accordance with the schedule hereunder:

代理人有权向顾客提出以下折扣，但其佣金根据下列细表相应降低：

3.3. Discount to be agreed upon待商定的折扣

The Agent undertakes not to propose to the customers any discount higher that the maximum discount shown in the schedule set out in §3.2. above, without prior written authority from the Principal.

代理人承诺未经委托人事先以书面授权，不向顾客提出高于上述§3.2表格上所列的最高折扣。

§4. Commission on insured credits (art. 16.2) 经保险的赊欠款的佣金(第16.2节)

If the Principal is insured against the insolvency of his customers, and he is paid by the insurer (instead of receiving the price from the customer) the Agent is entitled:

如果委托人就顾客无力偿付进行投保，并且其从保险人处得到了该款额(而不是从顾客处收取贷款)，则代理人有权收取：

to a half commission on the sums paid by the insurer按保险人支付总额计算的佣金的一半。

to the full commission on the sums paid by the insurer, after deduction of the costs or expenses borne by the Principal with reference to the non-payment.

按保险人支付总额计算的佣金的全部，扣除委托人就解决顾客不支付所支付的成本或费用。

ANNEX VII CHANGE OF CONTROL, OWNERSHIP AND/OR MANAGEMENT IN THE

AGENT COMPANY

附件七 代理公司改变控制权、所有权或管理权

(Article 20.5) (第20.5款)

The principal may terminate the agreement with immediate effect, if:

委托人可以立即终止合同，如果：

Mr. ceases to own more than ------% of the shares of the Agent company

先生不再拥有代理公司____%以上的股份。

Mr. ceases to be the of the Agent company先生不再担任代理公司的___职务。

Specify here the position that the qualifying person has in the agent company, e.g. director, general manager, president of the board, as the case may be. This clause may be dangerous for the agent company, particularly if the qualifying person is not the owner, but only an employee. At the same time, if alternative A of article 21 is applicable, the Agent company may terminate this contract on grounds of the --------- age, infirmity or illness of Mr. ------- according to article 21.4 A, (b), without losing the right to the goodwill indemnity under such provision.

同时，如果第21节的方案A适用，代理公司可以根据第21.4节的A(b)由于_先生年高、体弱或有病而终止本合同，但按照以上条款其不丧失商誉补偿的权利。

司，其主营业地在_______(以下简称卖方)

与他方当事人X、 Y、 Z公司，按______国法律组建并存在的公司，其主营业地在______(以下简称代理商)所签订。

双方一致同意约定如下：

第一条 委任与接受

在本协议有效期内，卖方指定代理商为本协议第四条项下商品的独家代理商，在第三条所规定的区域内招揽顾客的订单。代理商同意并接受上述委任。

第二条 代理商的义务

代理商应严格遵守卖方随时给予的任何指令，而且不得代表卖方作出任何担保、承诺以及订立契约、合同或作其他对卖方有约束力的行为。对于代理商违反卖方指令或超出指令范围所用的一切作为或不作为，卖方都将不承担任何责任。

第三条 代理区域

本协议所指的代理区域是：________ (以下简称区域)。

第四条 代理商品

本协议所指的代理商品是_________ (以下简称商品)。

第五条 独家代理权

基于本协议授予的独家代理权，卖方不得在代理区域内，直接地或间接地，通过其他渠道销售、出口代理商品。代理商也不得在代理区域内经销、分销、或促销与代理商品相似或有竞争性的商品，也不能招揽或接受到区域外销售为目的订单。在本协议有效期内，对来自于区域内其他顾客有关代理商品的订单、询价，卖方都应将其转交给代理商。

第六条 最低代理额和价格

在本协议有效期内，如果卖方通过代理商每所(12个月)从顾客处收到的货款总金额低于_______ ，则卖方有权提前30天书面通知代理商解除本协议。

卖方应经常向代理商提供最低的价格表以及商品可以成交的条款、条件。

第七条订单的处理

在招揽订单时，代理商应将卖方成交的条件、合同的一般条款充分通知顾客，也应告知顾客任何合同的订立都须经卖方的确认。代理商应将其收到的订单立即转交给卖方，以供卖方选择是否接受订单。卖方有权利拒绝履行或接受代理商所获得的订单或订单的一部分，而代理商对于被拒绝的订单或其中的一部分，无任何佣金请求权。

第八条 费用分担

除另有约定外，所有的费用和支出，如电讯费、差旅费以及其他有关商品销售的费用，都应由代理商承担。除此以外，代理商还应承担维持其办公处所、销售人员以及用于执行卖方中有关代理商的义务而发生的费用。

第九条 佣金

卖方接受代理商直接获得的所有订单后，就应按商品净销售额的百分之_____，以______(货币)支付给代理商佣金。佣金只有在卖方收到顾客的全部货款后，每6个月支付一次，以汇付方式支付。

第十条商情报告

卖方和代理商都应按季度或按对方要求提供有关市场信息的报告，以尽可能促进商品的销售。代理商应向卖方报告商品的库存情况、市场状况及其他商业活动。

第十一条 商品的推销

在代理区域内，代理商应积极地充分地进行广告宣传以促进商品的销售。卖方应向代理商提供一定数量的广告印刷品、商品样本、小册子以及代理商合理要求的其他材料。

第十二条 工业权保护

在本协议有效期内，代理商可使用卖方的商标，但仅限于代理商品的销售。如果在本协议终止后，代理商地销售库存代理商品时，仍可使用卖方的商标。代理商也承认使用于或包含于代理商品中的任何专利、商标、版权以及其他工业产权，都属于卖方所有，并且不得以任何方式提出异议。一旦发现浸权，代理商应及时通知卖方并协助卖方采取措施保护卖方产权利益。

第十三条 协议期限

本协议经双方签字生效。在本协议终止前至少3个月，卖方或代理商应共同协商协议的续延。如果双方一致同意续延，在上述规定的条款、条件下，附上补充文件，本协议将继续有效另外_______年。发生续延，本协议将于______年______月______日终止。

第十四条 协议的中止

在本协议有效期内，任何一方当事人不履行合同或违反本协议的条款，如第五、六、十一条，双方当事人座争取及时解决争议的问题以期双方满意。如果在违约方接到书面通知后30日内问题仍不能解决，非违约方将有权中止本协议，由此造成的损失、无力偿付债务、清算、死亡以及被第三人兼并，另一方当事人可提出中止本协议，而无需书面通知对方。

第十五条 不可抗力

任何一方对由于下列原因而导致不能或暂时不能履行全部或部分协议义务的，不负责任：

自然灾害、政府采购或禁令以及其他任何双方在签约时不能预料、无法控制且不能避免和克服的事件。但受不可抗力影响的一方，应尽快地将发生的事件通知对方，并附上证明材料。

第十六条 准据法

本协议有关贸易条款应按 INCOTERM90解释。本协议的有效性、组成以及履行受中华人民共和国法律管辖。

第十七条 仲裁

对于因履行本合同发生的一切争议，双方应友好协商解决，如协商无法解决争议，则应提交中国国际经济贸易仲裁委员会(北京)，依据其仲裁规则，仲裁费应由败诉一方承担，仲裁委员会另有规定的除外。

本合同由双方代表签字后生效，一式两份，双方各执一份。

A.B.C.公司 及 x.y.z公司

代表________ 代表________

英文文本

EXCLUSIVE AGENCY AGREEMENT

This Agreement is made and entered into this _____ day of _____ ,19 - by and between A.B.C.Co.Ltd. a corporation duly organized and existing under the laws of Peoples Republic of China,with its principal place of business at ____ (hereinafter called Seller) and X.Y.Z.Co.Ltd. a corporation duly organized and existing under the laws of ____,with its principal of business at ____(hereinafter called Agent). Whereby it is mutuly agreed as follows:

Article 1. Appointment

During the effective period of this Agreement. Seller hereby appoints Agent as its exclusive agent to solicit orders for products stipulated in Article 4 from customers in the territory stipulated in Article 3 and Agent accepts and assumes such appointment.

Article 2. Agents Duty

Agent shall strictly conform with any and all instructions gvien by Seller to Agent from time to time and shall not make any representation,warranty,promise,contract,agreement or do any other act binding Seller. Seller shall not be held responsible for any acts or failures to act by Agent in excess of or contrary to such instructions.

Article 3. Territory

The territory covered under this Agreement shall be expressly confined to ____(hereinafter called Territory)

Aricle 4. Products

The products covered under this Agreement shall be expressly conned to ____(hereinafter called products)

Article 5. Exclusive Right

In consideration of the exclusive right herein granted, Seller shall not,dicectly of indirectly,sell of export products to Territory through other channel than Agent and Agent shall not sell, distribute or promote the sale of any products competitive with of similar to Products in Territory and shall not solicit or accept orders for the prupose of selling Produets outside Terrtory. Seller shall refer to Agent any inpuiry or order for products Seller may receive from others in Territory during the effective period of this Agreement.

Aritcle 6. Mimimum Transaction and Price

In the event that during one year (12 months) during the effective period of this Agreement,aggregate payment received by Seller from customers on orders obtained by Agent under this Agreement amounts to less than _____, Seller shall have the right to terminat this Agreement amounts to less than _____,Seller shall have the right to terminate this Agreement by giving thirty (30) days written notice to Agent.

The seller shall from time to time furnish the Agent with a statement of the minimum prices and the terms and conditions of sales at which the goods are respectively to be sold.

Article 7. orders

In soliciting orders ,Agent shall adepuately advise customers of the general terms and conditions of Sellers sales note or contract note and of any contract being subject to the confirmation of acceptance by Seller.Agent shall immediately dispatch any order received to Seller for its acceptance or rejection.

The seller shall have the right to refuse to execute or accept any such orders or any part thereof and the Agent shall not be entitled to any commission in respect of any such rejected order or part thereof refused.

Article 8. Expenses

All expenses and disbursements such as cabling,traveling and other expenses incurred in connection with the sale of products shall be for the account of Agents, unless especially arranged.Further Agent shall, at this own expenses,maintain office(s), salesmen and others sufficient for the performance of the obligation of Agent in conformity with any and all instructions given by Seller.

Article 9.Commission

Seller shall pay to Agent commission in _____ currency at the rate of ______% of the net invoiced selling price of products on all order directly obtained by Agent accepted by Seller. Such commission shall be payable every six months only after Seller receives the full amount of all payments due to Seller. Payments of such commission shall be made to Agent by way of remittance.

Article 10.Information and Report

Both Seller and Agent shall quartely and/or on the request of either party furnish information and market report each other to promote the sale of products as much as possible.Agent shall give Seller shall furnish with or without charge to Agent reasonable quantity of advertising literatures catalogues,leaflets,and the like as Agent may reasonably require.

Article 11. Sales Promotion

Agent shall diligently and adequately advertise and promote the sale of Products throughout Territory.Seller shall furnish with or without charge to Agent reasonable quantity of advertising literatures catalogues,leaflets,and the like as Agent may reasonably require.

Article 12 .Industrial Property Rights

Agent may use the trade - mark(s) of Seller during the effective period of this Agreement only in connection with the sale of Products, provided that even after the termination of this Agreement Agent may use the trade - mard(s) inconnection with the sale of Products held by it in stock at the time of termination. Agent shall also acknowledge that any and all patents, trade - marks, copyright and other industrial property rights used or embodied in Products shall remain to be sole properties of Seller and shall not dispute them in any way. If any infringement being found, Agent shall promptly notify seller and asist seller to take steps to protect its right.

Article 13. duration

This Agreement shall enter into force on the signing of both parties. At least three(3) months before the expiration of the term, both Seller and Agent shall consult each other for renewal of this - Agreement. If the renewal of this Agreement is agreed upon by both parties,this - Agreement shall be renewed for another_________ year(s) period under the terms and conditions herein set forth,with amendments, if agreed upon by both parties. Unless this Agreement shall expire on _______.

Article 14. Termination

In case there is any nonperformance and/or violation of the terms and conditions including Article 5,6,11 under this Agreement by either party during the effective period of this agreement,the parties hereto shall do their best to settle the matter in question as prompt and amicable as possible to mutual satisfaction.Unless settlement should be reacher within thirty (30) days after notification in writing of the other party,such other party shall have the right to cancel this Agreement and the loss and damges sustained thereby shall be indemnified by the party responsible for the nonperformance and/or violation. Further in case of bandruptcy or insolvency or liquidation or death and/or reorganization by the third party of the other party ,either party may forth with terminate this Agreement without any notice to the other party.

Article 15. Force Majeure

Either party shall not be held responsible for failure or delay to perform all or any part of the due to Acts of God, Governmet orders or restriction or any other events which could not be predicted at the time of the conclusion of the Agreement and could not be controlled,avoided or overcome by the parties.Hovever, the party effected by the Event of Force Majeure shall inform the other party of its occurrence in Written as soon as possible.

Article 16. Trade Terms and Governing Law

The trade terms under this Agreement shall be governed and interpreted under the provisions of 1990 Incoterms and this Agreement shall be governed as to all matters including valitity,construction,and preformance under the laws of Peoples Republic of China.

Article 17. Arbitration:

All disputes arising from the performance of the Agreement should be settled through friendly negotiations. Should no settlement be reached through negotiation, the case shall then be submitted for arbitration to the China International Economic and Trade Arbitration Commission(Beijing) and the rules of this Commission shall be applied. The award of the arbitration shall be final and binding upon both parties. The Arbitration fee shall be born by the losing party unless otherwise awarded by the arbitration organization.

WITNESS THEREOF: This Agreement shall come into effect immediately after it is signed by boty parties in two original copies;each party holds one copy.

A.B.C Corp. X.Y.Z.Corp.

BY____________ BY____________

出租方(甲方)lessor (hereinafter referred to as party ) ：

承租方(乙方)lessee (hereinafter referred to as party ) ：

根据国家有关法律、法规和有关规定，甲、乙双方在平等自愿的基础上，经友好协商一致，就甲方将其合法拥有的房屋出租给乙方使用，乙方承租使用甲方房屋事宜，订立本合同。

in accordance with relevant chinese laws 、decrees and pertinent rules and regulations ,party and party have reached an agreement through friendly consultation to conclude the following contract.

一、 物业地址 location of the premises

甲方将其所有的位于上海市_________区____________________________________的房屋及其附属设施在良好状态下出租给乙方___________使用。

party will lease to party the premises and attached facilities all owned by party itself, which is located at _______________________________________ __________________________ and in good condition for_____________ .

二、 房屋面积 size of the premises

出租房屋的登记面积为_________平方米(建筑面积)。

the registered size of the leased premises is_________square meters (gross size).

三、 租赁期限 lease term

租赁期限自_______年___月___日起至_______年___月___日止，为期___年，甲方应于_______年___月___日将房屋腾空并交付乙方使用。

the lease term will be from _____(month) _____(day) _______(year) to ________(month) _____(day) _______(year). party will clear the premises and provide it to party for use before _____(month) _____(day) _______(year).

四、 租金 rental

1. 数额：双方商定租金为每月人民币_____________元整, 乙方以___________形式支付给甲方 。

amount: the rental will be ____________per month. party will pay the rental

to party in the form of ____________in ________________.

2. 租金按_____月为壹期支付;第一期租金于_______年_____月_____日以前付清;以后每期租金于每月的______日以前缴纳，先付后住(若乙方以汇款形式支付租金，则以汇出日为支付日，汇费由汇出方承担)。甲方收到租金后予书面签收。

payment of rental will be one installment everymonth. the first installment will be paid before_______(month)______(day)__________(year). each successive installment will be paid_____________each month.

party will pay the rental before using the premises and attached facilities (in case party pays the rental in the form of remittance, the date of remitting will be the day of payment and the remittance fee will be boe by the remitter.) party will issue written receipt after receiving the payment.

3. 如乙方逾期支付租金超过十天，则每天以月租金的0.5%支付滞纳金;如乙方逾期支付租金超过十五天，则视为乙方自动退租，构成违约，甲方有权收回房屋，并追究乙方违约责任。

(sample letter of intent form)

letter of intent for possible

contract for sale of assets

possible seller: ____________

possible buyer: ___________

business: ______________

date: ______________, 20_____

this is a non-binding letter of intent that contains provisions that are being discussed for a possible sale of the business named above from the possible seller named above to the possible buyer named above. this is not a contract. this is not a legally binding agreement. this is merely an outline of possible contract terms for discussion purposes only. this is being signed in order to enable the possible buyer to apply for financing of the purchase price. this letter of intent is confidential and shall not be disclosed to anyone other than the parties and their employees, attorneys and accountants and the possible lenders of the possible buyer. the terms of the transaction being discussed are attached hereto, but the terms (and the possible sale itself) are not binding unless and until they are set forth in a written contract signed by possible seller and possible buyer. the word "shall" is used in the attached terms only as an example of how a contract might read, and it does not mean that the attached terms are or ever will be legally binding.

____________________________ ________________________

____________________________

witnesses

____________________________ ________________________

____________________________

witnesses

(合同意向书范本)

潜在资产出让合同意向书

潜在卖方：_______________

潜在买方：_____________

交易事项：____________

日期：______________, 20_____

本意向书不具有约束力，所包含之条款有待上述潜在卖方与买方就可能发生之交易(本处应指“资产出让”)进行磋商。本意向书不应被视为任何合同、或具有法律约束力的协议，而应视作仅为磋商之目的而订立的有关本意向书项下可能达成之合同的条款概述。签署本意向书之目的是为了能够便于潜在买方就购买价格筹措资金。双方应对本意向书之内容保密，且除了本意向书项下双方及其雇员、律师、会计师和潜在买方之潜在贷款方之外，不得向任何其他第三方透露。本次磋商之交易条款随附其后，但是除非且直到潜在的买卖双方签署书面协议，这些条款(及潜在卖方自身)将不具有约束力。随附条款中“应该”一词仅为合同阅读之惯例，并不意味随附之条款具有或将要具有法律约束力。

____________________________

签字

____________________________

签字

对外贸易合同范本中英文

贸易合同又称契约或合约，是进口出口双方当事人依照法律通过协商就各自的在贸易上的权利和义务所达成的具有法律约束力的协议。今天第一范文网小编要与大家分享的是：中英文对照版的对外贸易合同相关范本，具体内容如下，欢迎参考阅读!

CONTRACT

NO.:

DATE:

THE BUYERS:

ADDRESS :

TEL: FAX:

买方：

地址：

THE SELLERS:

ADDRESS:

TEL: FAX:

This Contract is made by and between the Buyers and the Sellers, whereby the Buyers agree to buy and the Sellers agree to sell the under mentioned commodity according to the terms and conditions stipulated below:

买方与卖方就以下条款达成协议：

1. COMMODITY:

2. COUNTRY AND MANUFACTURERS:

原产国及造商：

3. PACKING:制

To be packed in standard airway packing. The Sellers shall be liable for any damage of the commodity and expenses incurred on account of improper packing and for any rust attributable to inadequate or improper protective measures taken by the sellers in regard to the packing.

包装：标准空运包装。如果由于不适当的包装而导致的货物损坏和由此产生的费用，卖方应对此负完全的责任。

4. SHIPPING MARK:

The Sellers shall mark on each package with fadeless paint the package number, gross weight, net weight, measurement and the wordings: "KEEP AWAY FROM MOISTURE" "HANDLE WITH CARE" "THIS SIDE UP" etc. and the shipping mark:

唛头：卖方应用不褪色的颜料在每个箱子外部

刷上箱号、毛重、净重、尺寸，并注明“防潮”、

“小心轻放”、“此面向上”等，唛头为:

5. TIME OF SHIPMENT(装运期)：within days after receipt of L/C

6. PORT OF SHIPMENT(装运港)：

7. PORT OF DESTINATION(目的港)： , CHINA

8. INSURANCE(保险)：To be covered by sellers for 110% invoice value against All Risks.

9. PAYMENT(付款方式)The buyer open an irrevocable 100% L/C at sight in favor of seller

信用证付款：买方给卖方开出100%不可撤销即期信用证。

银行资料：

10. DOCUMENTS:

1. Full set of Air waybill in original showing “Freight Prepaid” and consigned to applicant. 空运提单一套

2. Invoice in three copies. 发票一式叁份

3. Packing list in three copies issued by the Sellers. 装箱单一式叁份

4. Certificate of Quality issued by the Sellers. 制造厂家出具的质量证明书

5. Insurance Policy. 保险单一份

6. Certificate of origin issued by the Sellers. 原产地证书

7. Manufacturer’s certified copy of fax dispatched to the applicant within 24 hours after shipment advising

flight No., B/L No., shipment date, quantity, Gross weight, Net weight, and value of shipment.

制造厂家通知开证申请人有关货物装运的详细资料传真复印件壹份

8. The seller’s Certificate and waybill certifying that extra documents have been dispatched according

to the contract terms by express airmail.

卖方有关另外用特快邮寄壹套单据给开证申请人的证明书及邮寄底单.

9. Certificate of No Wooden Packing or Certificate of Fumigation.非木包装声明或熏蒸证.

In addition, the Sellers shall, within three days after shipment, send by express airmail one extra sets of

the aforesaid documents directly to the Buyers.

另外，卖方应于货物发运后三天内，用特快专递寄送一套上述的单据给买方。

11. SHIPMENT:

The Sellers shall ship the goods within the shipment time from the port of shipment to the destination. Transshipment is allowed. Partial shipment is not allowed.

运输：卖方应于交货期内将合同货物从装货港运到目的港，不许分批，允许转运。

12. SHIPPING ADVICE:

The sellers shall, immediately upon the completion of the loading of the goods, advise by fax the buyers of the Contract No., commodity, quantity, invoiced value, gross weight, name of vessel and date of delivery etc. In case due to the sellers not having faxed in time, all losses caused shall be borne by the sellers.

装运通知：卖方应于装货后，立即用传真将有关合同号、货物、数量、发票价值、毛重、运输工具名称、交货日期、货物预计抵达日等资料通知买方。如果由于卖方未能通知买方而造成的所有损失均由卖方承担。

13. GUARANTEE OF QUALITY:

The Sellers guarantee that the Commodity hereof is made of the best materials with first class workmanship, brand new and unused, and complies in all respects with the quality and specification stipulated in this Contract. The guarantee period shall be 12 months counting from the date of signing the Acceptance Report of this machine at the end-users site.

质量保证：卖方保证合同货物采用最好的材料、精湛的做工、全新、未使用过、质量和技术规格均符合合同的要求。质保期为最终用户签定验收报告后12个月内。

14. CLAIMS:

Within 90 days after the arrival of the goods at destination, should the quality, specification, or quantity be found in unconformity with the stipulations of the Contract except those claims for which the insurance company or not the owners of the vessel are liable, the Buyers shall, on the strength of the Inspection Certificate issued by the State Administration for Entry-Exit Inspection and Quarantine of P.R.C. or the site inspection report issued by the seller’s engineer, have the right to claim for replacement with new goods, or for compensation, and all expenses (such as inspection charges, freight for returning the goods and for sending the replacement, insurance premium, storage and loading and unloading charges etc.) shall be borne by the Sellers. As regards quality, the Sellers shall guarantee that if within 12 months from the date of signing the acceptance report of this machine, damages occur in the course of operation by reason of inferior quality, bad workmanship or the use of inferior materials, the Buyers shall immediately notify the Sellers in writing and put forward a claim supported by Inspection Certificate issued by the State Administration for Entry-Exit Inspection and Quarantine of P.R.C. .The Certificate so issued shall be accepted as the base of a claim. The Sellers, in accordance with the Buyers claim shall be responsible for the immediate elimination of the defect(s), complete or partial replacement of the commodity or shall devaluate the commodity according to the state of defect(s), . If the Sellers fail to answer the Buyers within one month after receipt of the aforesaid claim, the claim shall be reckoned as having been accepted by the Sellers.

索赔：货物抵达目的地后90天内，如果质量、技术规格或数量发现与合同的规定不符(除过保险公司和运输公司的责任所负)，买方应该依据中华人民共和国出入境检验检疫局的检验报告或者是卖方的调试人员在安装调试时出具的报告，有权要求替换或补偿，所有的费用(包括商检费、替补件来回的运费、保险费、仓储费、货物装货卸货费等)均由卖方承担。卖方的质量保证为签定关于此批货物的验收报告后12个月内;由于货物内在的质量、差的做工、选材不当而造成操作中的货物损坏，买方应立即书面通知卖方，并同时随附中国商检局出具的检验报告作为索赔依据。卖方在接到买方的索赔后，有责任立即解决相应的质量问题、全部或部分地替换货物或根据货物损坏的程度进行折价; 如果卖方在收到买方的上述索赔后一个月内未能作出答复，则视为索赔已为卖方所接受。

15. FORCE MAJEURE:

The Sellers shall not be held responsible for the delay in shipment or non-delivery of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The Sellers shall advise the Buyers immediately of the occurrence mentioned above and within fourteen days thereafter, the Sellers shall send by airmail to the Buyers for their acceptance a certificate of the accident issued by the Competent Government Authorities where the accident occurs as evidence thereof. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the delivery of the goods. In case the accident lasts for more than 10 weeks, the Buyers shall have the right to cancel the Contract.

不可抗力：对于制造或装船运输过程中可能产生的不可抗力而造成的迟交货或不能交货，卖方可以不承担责任。卖方应立即在不可抗力产生的十四日内将有关情况通知买方，并且卖方应用航空邮件将有关政府当局部门出具的证明不可抗力产生的文件寄送给买方。在此情况下，卖方仍应尽最大努力采取各种措施促使货物的发运。如果事故持续十周，买方有权取消该合同。

16. LATE DELIVERY AND PENALTY:

Should the Sellers fail to make delivery on time as stipulated in the Contract, with exception of Force Majeure causes specified in Clause 15 of this Contract. The Buyers shall agree to postpone the delivery on condition that the Sellers agree to pay a penalty which shall be deducted by the paying bank from the payment. The Penalty, however, shall not exceed 5% of the total value of the goods involved in the late delivery. The rate of penalty is charged at 0.5% for every seven days. Odd days less than seven days should be counted as seven days. In case the Sellers fail to make delivery ten weeks later than the time of shipment stipulated in the Contract, the Buyers shall have the right to cancel the contract and the Sellers, in spite the cancellation, shall still pay the aforesaid penalty to the Buyers without delay.

迟交货和罚金：如果卖方未能按合同规定及时交货(除了本合同15条款所言的不可抗力)，买方同意在卖方付罚金的前提下迟交货。罚金的金额不超过迟交货的合同货物部分的价值的5%，罚金按每7日0.5%计算，少于7日的增加天数按7日计。如果卖方未能于合同规定的交货期之后的十周内发运，买方有权取消该合同，除此之外，卖方仍要将有关罚金不加拖延地付给买方。

17. ARBITRATION:

Any dispute arising from or in connection with this Contract shall be submitted to China International Economic and Trade Arbitration Commission for arbitration which shall be conducted in accordance with the Commissions arbitration rules in effect at the time of applying for arbitration. The arbitral award is final and binding upon both partied. Arbitration fee shall be borne by the losing party.

仲裁：与此合同有关的争议应通过友好协商解决。如果协商无法解决，提交中国国际经济贸易仲裁委员会进行仲裁。按照申请仲裁时该会现行有效的仲裁规则进行仲裁。仲裁裁决是终局的，对双方均有约束力。仲裁费用由败诉方承担。

18.BANK CHARGES: All bank charges outside China will be on the account of the Sellers.

银行费用：所有中国之外的银行费用均由卖方承担。

19.OTHER: This contract signed in three copies, the seller holds one copy and the buyer hold two copies.

其它：本合同一式叁份，卖方执壹份, 买方执贰份。

合同编号：___________

甲方：______________________________

住所地：____________________________

法定代表人：________________________

乙方：______________________________

住所地：____________________________

法定代表人：________________________

甲方作为本合同附件所列产品（以下简称“该产品”）中国独家总分装、销售商，与乙方在平等团结的基础上经充分协商达成一致意见如下，以资双方共同遵守执行。

1.乙方为签订、履行本合同已对该产品及甲方与本合同有关的信息、资料进行了充分调查了解，并在此基础上结合自身实际情况对该产品的市场前景作出预测，且愿意承担本合同约定的一切责任、风险。

2.甲方于本合同有效期内在_______________地区（以下简称“本地区”）将只向乙方销售该产品，而不向本地区任何第三人销售该产品。

3.乙方获取本合同第二条约定的权利，应自本合同签订之日起日内一次性向甲方支付初期货款人民币__________元用于购买该产品__________吨。乙方未能按期足额支付该初期货款的，逾期__________日本合同自动解除。

4.乙方应于本合同有效期内每年向甲方购货总额不少于人民币__________元。乙方未能达到该购货总额的，甲方有权解除合同并向乙方主张__________元的违约金；乙方于合同有效期内每年向甲方购货总额__________元以上的，甲方将给予乙方__________的返利。

5.本地区该产品的售价由甲方统一确定。

6.乙方向甲方购买该产品，应至少于计划表载明的到货日期提前六十日向甲方报送计划表。甲方应于收到计划表之日起七日内作出是否同意的答复。甲方同意接受该计划的，乙方应于收到答复之日起三日内，将该计划所欲购买该产品的全部价款预先支付给甲方。否则，甲方有权拒绝向乙方发售该计划所列产品，因此给甲方造成损失，乙方应承担全额赔偿责任。

乙方向甲方购进该产品的价格，应为乙方报送计划表时甲方认可的价格。因履行本合同所产生的运费由__________承担。

7.乙方承诺其从甲方购进的该产品均在本地区销售，而不能超出该地域范围，只有经销权，没有任何分装和改动包装权。否则，应向甲方支付违约金__________元且甲方有权解除合同。但经甲方书面许可的除外。

8.乙方为开拓该产品销售市场，应进行必要的广告、宣传。乙方确保每年用于广告宣传的费用不少于人民币__________元。广告宣传的具体形式应与甲方进行协商，并征得甲方同意。

9.乙方应尽力维护该产品的信誉。其就该产品向任何人所作承诺及说明均应实事求是，并以产品质量说明书、甲方认可的销售业绩表等相关资料所载内容为限，并不得违反法律规定。否则，因此产生的法律责任由乙方全部承担。

10.乙方应将产品销售过程中所掌握的与该产品相关的各种信息及时向甲方通报。并根据甲方的要求提供详细资料。

11.本合同所称“年度”，为合同签订之日与此后年度对应日之间的期间，本合同有效期自______年______月______日起至_______年______月______日止。

12.因本合同产生的纠纷，由甲方所在地人民法院管辖。

13.本合同一式四份，甲、乙双方各执二份。

甲方：____________________

乙方：____________________

_______年______月_______日

附件：（略）

本协议于  年  月  日签订，协议双方为：（卖方名称），系根据a国法律正式组成并存在的公司，设于某地（卖方地址）（以下称“卖方”）和b国x股份有限公司，系根据b国法律正式组成并存在的公司，设于某地（地址），（以下称x商）。

鉴于“卖方”愿意发展他在某地（生产地）和其他国家制造的、并以他的商标和专名销售的产品的出口业务；

鉴于“卖方”愿委任x商作为他的独家经销商，按照本协议中的条款销售此种产品；

为此，考虑到双方在本协议中所作的诺言和所商定的各条款，并考虑到下面所提出的，双方声明已经同意的，相互之间的其他有效对价，特订立协议如下：

第一条 定义

一、产品：本协议中所称“产品”，系指“卖方”制造并以其商标和专名销售的产品（产品名称）。

二、地区：本协议中所称“地区”，系指某地（地区名）和随时经双方以书面同意的其他地区。

三、商标和专名：本协议中所称“商标”和“专名”，系分别指（商标的全称和专名的全称）。

第二条 经销权

“卖方”兹给予x商以独家进口，并以“商标”和“专名”向“地区”内客户销售“产品”的权利。

第三条 专营权

一、交易：“卖方”不得将“产品”售予、让予或以其他方式使“地区”内x商以外的任何个人、行号或公司取得“产品”。

二、委任：“卖方”不得委任“地区”内x商以外的其他个人、行号或公司作为其经销商、代表人或代理人，以进口和销售“产品”。

三、询购：“卖方”收到“地区”内任何客户有关“产品”的询购，均应交给x商。

四、再进口：“卖方”应采取适当措施防止他人在“地区”内出售“产品”，并不得将“产品”卖给“卖方”知道的或有理由据信拟在“地区”内再进口或同售“产品”的第三者。

第四条 价格、条件

一、价格：给予x商的价格和条件，应随时由“卖方”和x商商定，此项价格和条件的确定应考虑到正常贸易惯例及经常存在的市场竞争情况，使双方从销售中获得相当利润。

二、单独合同：在每次具体购买产品时，双方应缔结单独合同。

三、最惠条款“卖方”声明，本协议中各项条款是“卖方”现在给予经销商和制造商最优惠的条款，今后如“卖方”向任何其他经销商或制造商销售“产品”时提供比本协议更有利于买方的条件时，“卖方”应立即以书面通知x商，并向x商提供此项更有利的条件。

第五条 “卖方”的责任

“卖方”同意在下列方面协助x商：

一、自费供应样品和一切可以供应的广告资料。

二、提供现行的国内价目表，并将价目表内任何预期的变更迅速通知x商。

三、经常提供有助于推销“产品”的意见。

第六条 x商的责任

一、为在“地区”内推销“产品”并为客户服务，应自费提供和保持一个有经营能力的机构，并尽一切努力争取达到有利于“卖方”为利用“地区”内各种销售机会而制定的销售指标。

二、供给“卖方”有关销售“产品”的详细报告，以及尽可能多的有关“地区”内各种销售机会和竞争者推销活动的情报。

第七条 双方关系

根据本协议所建立的“卖方”和x商在协议有效期内的关系仅属卖方和买方的关系。任何一方均无权对某一第三者代表另一方，或以另一方的名义签订合同。本协议并不产生代理权，如果任何一方以另一方的名义或以另一方代理人的名义行事，以致另一方遭受损失时，该导致损失的一方，应使受害的一方不负担由此而发生的损失和费用。双方并未也无意建立任何代理、合伙、合营企业或雇主和雇员的关系。

第八条 “卖方”名称等的使用

一、特许：x商得为商业上目的使用“商标”和“专名”或他们的简称或变称，并得标明自己为“地区”内“产品”的经销商。

二、注册：如x商提出要求，“卖方”应自费负责为“商标”和“专名”在“地区”内办理申请、正式注册并保持其效力。

第九条 期限、终止

本协议自 年 月 日起生效，有效期为 年。从生效日起 年后，双方应协商按照当时双方同意的条款和条件将本协议按原来所订  年的期限延长一期或数期，如双方未能就延长期限达成协议，除任何一方在九十天前以书面通知另一方撤销或终止本协议外，则本协议应视为自此以一年为期限延长或更新一次。如遇下列情况和条件，本协议也应终止：

一、如任何一方有违背本协议的实质性行为，另一方得以书面通知该方，叙述此种违约行为，并说明除非该方对此种违约行为按本节规定加以纠正，否则另一方将按照本节规定终止本协议。如该通知发出后九十天内仍未得到纠正，则本协议根据这一事实在上述九十天期终时即行终止，或

二、如任何一方根据破产法或债务人救济法提出或同意提出破产申请或其他救济申请，或被裁定破产，或解散，或清理，或对债权人作任何转让，或对该方指定了产业管理人或类似人员，则在上述任何情况下，另一方得在任何时候以书面通知立即终止本协议，或

三、如遇本协议所规定的某种不可抗力事由，以致协议一方在超过×天期限后尚无法履行其义务时，则另一方可在任何时候以书面通知立即终止本协议。

第十条 解约的影响

凡在本协议终止前双方间已发生而尚未了结的任何债务，或在本协议终止前由于一方违约而发生的另一方的损害赔偿请求权，均不受本协议终止的影响。

第十一条 保证

一、标准：“卖方”向x商保证，所有“产品”均符合“地区”内的标准，可以出售，并适合销售目的。“卖方”并保证“产品”在原料和制造工艺方面均符合质量标准。

二、免受损失：凡因“产品”被指称质量低劣，或因侵犯专利、商标，或因在“地区”内销售或使用产品而引起的其他任何类似的责任事由，“卖方”应保护x商，使之不受损失。

三、质量：如x商发现任何“产品”质量低劣，并将此事实通知“卖方”，“卖方”应按x商提出的要求，立即予以调换或对x商给予补偿，其费用由“卖方”自行负担。对由于上述调换或补偿而引起的损害，x商不丧失其索赔权。

第十二条 一般条款

一、不可抗力

本协议任何一方如遇到非所能控制的事由，以致直接或间接地造成任何延迟或无法履行本协议及（或）各个单独合同的一部或全部条款时，则在此范围内得以免除其责任，此类事由包括但不限于：火灾、水灾、海啸、地震、雷（电）击、台风、飓风、旋风、瘟疫或其他疫博 爆炸、意外事故或机械故障、天灾、战争、封锁、禁运、劫持、战争威胁、战争性情况、扣押、暴动、动员、暴乱、非暴力骚乱、革命、制裁、抢劫、罢工、劳动纠纷、封闭工厂、工业干扰、动力供应不足、缺乏正常运输工具、金融恐慌、交易所关闭、禁止进口或出口、拒发政府命令、敌对行动或其他类似或不类似上述原因而非该方或双方所能控制者。如由于立法或政府行政命令以致任何一方或双方失去根据本协议应得的利益时，双方应重新审查本协议的条款，以便恢复任何一方或双方根据本协议原已取得的同样的相应的地位。

租赁合同书

出租方(甲方)Lessor (hereinafter referred to as Party A)：

承租方(乙方)Lessee (hereinafter referred to as Party B)：

根据国家有关法律、法规和有关规定，甲、乙双方在平等自愿的基础上，经友好协商一致，就甲方将其合法拥有的物业出租给乙方使用，乙方承租使用甲方厂房事宜，订立本合同。

In accordance with relevant Chinese laws、decrees and pertinent rules and regulations ,Party A and Party B have reached an agreement through friendly consultation to conclude the following contract.

一、 物业地址Location of the premises

甲方将其所有的位于合肥经济技术开发区__________的厂房及其附属设施在良好状态下出租给乙方______ _____使用。具体见附件厂房平面图。

Party A will lease to Party B the premises and attached facilities all owned by Party A itself, which is located at _______________________________________ __________________________ and in good condition for_____________ .Concrete details in planimetric mapin contractschedule.

二、 物业状况

出租厂房的登记面积为_________平方米(建筑面积)。房屋结构为钢结构。

The registered size of the leased premises is_________square meters (Gross size).Thestructureofpremisesis stealstructure;

三、 租赁期限Lease term

租赁期限自_______年___月___日起至_______年___月___日止，为期___年，甲方应于_______年___月___日将厂房腾空并交付乙方使用。

The lease term will be from _____(month) _____(day) _______(year) to ________(month) _____(day) _______(year). Party A will clear the premises and provide it to Party B for use before _____(month) _____(day) _______(year).

四、 租金Rental

1.数额：双方商定租金为每月人民币_____________元整,乙方以___________形式支付给甲方 。

Amount: the rental will be ____________per month. Party B will pay the rental

to Party A in the form of ____________in ________________.

2.租金按_____个月为一个支付周期;第一期租金于_______年_____月_____日以前付清;以后每期租金于每一支付周期______日以前缴纳，先付后住(若乙方以汇款形式支付租金，则以汇出日为支付日，汇费由汇出方承担)。甲方收到租金后予书面签收。

Payment of rental will be one installment everymonth(s). The first installment will be paid before_______(month)______(day)__________(year). Each successive installment will be paid_____________each month.

Party B will pay the rental before using the premises and attached facilities (In case Party B pays the rental in the form of remittance, the date of remitting will be the day of payment and the remittance fee will be borne by the remitter.) Party A will issue a written receipt after receiving the payment

3.如乙方逾期支付租金超过十天，则每天以月租金的0.5%支付滞纳金;如乙方逾期支付租金超过十五天，则视为乙方自动退租，构成违约，甲方有权收回厂房，并追究乙方违约责任。

In case the rental is more than ten working days overdue, Party B will pay 0.5 percent of monthly rental as overdue fine every day, if the rental be paid 15 days overdue, Party B will be deemed to have with drawn from the premises and breach the contract. In this situation, Party A has the right to take back the premises and take actions against party B’s breach.

五、 保证金Deposit

1.为确保厂房及其附属设施之安全与完好，及租赁期内相关费用之如期结算，乙方同意于______年_____月_____日前支付给甲方保证金人民币_________元整，甲方在收到保证金后予以书面签收。

Guarantying the safety and good conditions of the premises and attached facilities and account of relevant fees are settled on schedule during the lease term, party B will pay _________to party A as a deposit before _____(month) _____(day) _______(year). Party A will issue a written receipt after receiving the deposit.

2.除合同另有约定外，甲方应于租赁关系消除且乙方迁空、点清并付清所有应付费用后的当天将保证金全额无息退还乙方。

Unless otherwise provided for by this contract, Party A will return full amount of the deposit without interest on the day when this contract expires and party B clears the premises and has paid all due rental and other expenses.

3.因乙方违反本合同的规定而产生的违约金、损坏赔偿金和其它相关费用，甲方可在保证金中抵扣，不足部分乙方必须在接到甲方付款通知后十日内补足。

In case party B breaches this contract, party A has right to deduct the default fine, compensation for damage or any other expenses from the deposit . In case the deposit is not sufficient to cover such items, Party B should pay the insufficiency within ten days after receiving the written notice of payment from Party A.

六、 甲方义务Obligations of Party A

1.甲方须按时将厂房及附属设施(详见附件)交付乙方使用。

Party A will provide the premises and attached facilities (see the appendix of furniture list for detail) on schedule to Party B for using.

2.厂房设施如因质量原因、自然损耗或灾害而受到损坏，甲方有修缮并承担相关费用的责任。

In case the premise and attached facilities are damaged by quality problems, natural damages or disasters, Party A will be responsible to repair and pay the relevant expenses.

3.甲方应确保出租的厂房享有出租的权利，反之如乙方权益因此遭受损害，甲方应负赔偿责任。

Party A will guarantee the lease right of the premises. Otherwise, Party A will be responsible to compensate Party B’s losses.

4.

七、 乙方义务Obligations of Party B

1.乙方应按合同的规定按时支付租金及保证金。

Party B will pay the rental, the deposit and other expenses on time.

2.乙方经甲方同意，可在厂房内添置设备。租赁期满后，乙方将添置的设备搬走，并保证不影响厂房的完好及正常使用。

Party B may decorate the premises and add new facilities with Party A’s approval. When this contract expires, Party B may take away the added facilities which are removable without changing the good conditions of the premises for normal use.

3.未经甲方同意，乙方不得将承租的厂房转租，并爱护使用该厂房，如因乙方过失或过错致使厂房及设施受损，乙方应承担赔偿责任。

Party B will not transfer the lease of the premises without Party A’s approval and should take good care of the premises. Otherwise, Party B will be responsible to compensate any damages of the premises and attached facilities caused by its fault and negligence.

4.乙方应按本合同规定合法使用该厂房，不得擅自改变使用性质。乙方不得在该厂房内存放危险物品。否则，如该厂房及附属设施因此受损，乙方应承担全部责任。

Party B will use the premises lawfully according to this contract without changing the nature of the premises and storing hazardous materials in it. Otherwise, Party B will be responsible for the damages caused by it

5.乙方应承担租赁期内的水、电、煤气、电讯等一切因实际使用而产生的费用，并按单如期缴纳。

Party B will bear the cost of utilities such as communications, water, electricity, gas, management fee etc. on time during the lease term.

6.乙方自行委托物业管理公司对承租的物业进行管理并签订《物业管理协议》，物业管理费自行承担。

Party B will signe The Agreement of premises Management with the management company which was employed by Party B itself,and bear the management itself.

7.乙方若需要对租赁物业进行装饰装修、制作外墙广告等，必须经过甲方的同意。

Without the approval of Party A,Party B can’t decorate the premises ,make advertisement etc.on the outwall.

八、 合同终止及解除的规定Termination and dissolution of the contract

1.乙方在租赁期满前如需退租或续租，应提前两个月通知甲方，由双方另行协商退租或续租事宜。在同等条件下乙方享有优先续租权。

Within two months before the contract expires, Party B will notify Party A if it intends to extend the leasehold. In this situation, two parties will discuss matters over the extension.

2.租赁期满后，乙方应在当天将厂房交还甲方;任何滞留物，如未取得甲方谅解，均视为放弃，任凭甲方处置，乙方决无异议。

When the lease term expires, Party B will return the premises and attached facilities to Party A within days. Any belongings left in it without Party A’s previous understanding will be deemed to be abandoned by Party B. In this situation, Party A has the right to dispose of it and Party A will raise no objection.

3.本合同一经双方签字后立即生效;未经双方同意，不得任意终止，如有未尽事宜，甲、乙双方可另行协商。

This contract will be effective after being signed by both parties. Any party has no right to terminate this contract without another party’s agreement. Anything not covered in this contract will be discussed separately by both parties

九、 违约及处理Breach of the contract

1.甲、乙双方任何一方在未征得对方同意的情况下，不履行本合同规定条款，导致本合同中途中止，则视为该方违约，双方同意违约金为人民币___________元整，若违约金不足弥补无过错方之损失，则违约方还需就不足部分支付赔偿金。

During the lease term, any party who fails to fulfill any article of this contract without the other party’s approval will be deemed to breach the contract. Both parties agree that the default fine will be________________. In case the default fine is not sufficient to cover the loss suffered by the faultless party, the party in breach should pay additional compensation to the other party.

2.乙方未按合同约定的用途使用租赁物或擅自转租的，甲方可解除合同，并有权扣除保证金作为乙方违约金。

十、争议解决Dispute Resolve

若双方在执行本合同或与本合同有关的事情时发生争议，应首先友好协商;协商不成，可向合同履行地人民法院提起诉讼。本合同一经双方签字后立即生效;未经双方同意，不得任意终止，如有未尽事宜，甲、乙双方可另行协商。

Both parties will solve the disputes arising from execution of the contract or in connection with the contract through friendly consultation. In case the agreement cannot be reached, any party may summit the dispute to the court that has the jurisdiction over the matter.

十一、免责条件exception clause

1、因不可抗力原因致使本合同不能继续履行或造成的损失，甲、乙双方互不承担责任。

In the event of the reason caused byforce majeuremake the contract not perform or probuct any loss,Party A or Party B will not bear the obligations each other.

2、因国家政策需要拆除或改造已租赁的房屋，给甲、乙双方造成损失的，互不承担责任。If the loss of both parties caused by remove or recontructive the premies due to national policies, Party A or Party B will not bear the obligations each other.

3、因上述原因而终止合同的，租金按照实际使用时间计算，不足整月的按实际天数计算。

In the event of the reason mentioned above, Payment of rentalwill becounted at the actual months or actual days if it don’t reach a full month.

十二、其他others

1.本合同附件是本合同的有效组成部分，与本合同具有同等法律效力。

Any annex is the integral part of this contract. The annex and this contract are equally valid.

2.本合同壹式贰份，甲、乙双方各执一份。

There are 2 originals of this contract. Each party will hold 1 original(s).

3.本合同中英文内容相同，若有不同之处，以中文为准。

The Chinese language version and the English language version of this Agreement shall have equal legal effect. In the event of conflict, the Chinese language version of this Agreement shall prevail.

4.甲、乙双方如有特殊约定，可在本款另行约定：

Other special terms will be listed bellows:

__________________________________________________________________________________

__________________________________________________________________________________

甲 方：

Party A

证件号码：

ID No

联络地址：

Address

电 话：

Tel:

代 理 人：

Representative:

日 期：

Date:

室内装修设计协议(中英文)

室内装修设计协议

agreement of house interior design

this agreement of interior design made this date of between a (hereinafter called "the client" which expression includes their legal representatives, successors in title an assigns) of the one part and b practicing as design consultant at c (hereinafter called “the designer" which expression includes his/legal representatives, successors in titles and permitted assigns) of the other part.

whereas the client intends to construct and complete. (hereinafter called the project);and whereas the client is desirous of appointing the designer to provide professional design services for the project on the terms and conditions hereinafter appearing

it is hereby agreed between the parties hereto as follows:

本设计协议由甲方(客户)和乙方(设计顾问)及丙方(设计公司)于 日签订。

鉴于客户意欲建设并完成本工程;鉴于客户愿意指定设计公司依照以下条款为本工程提供专业设计服务。

因此，双方达成协议如下：

1.0 scope of work 服务范围

1.1 interior layout and spatial re-planning of all areas.

室内布局和所有领域的空间重新规划。

1.2 interior design conceptualization and design implementation.

室内设计构思和设计实施。

1.3 interior finishes advice, specification and implementation.

室内饰面咨询，规范和实施。

1.4 interior lighting conceptualization, selection and implementation.

室内灯具构思、选择和实施。

1.5 interior fixtures specification and design for custom made & built in furniture or doors not already in the architectural schedule.

为客户制作或建造于不包括建筑物内已有的家具或门上的室内固定物或附着物的规范和设计

1.6 loose furniture consultation and selection.活动家具的咨询和选择

1.7 preparation of all necessary documents for the implementation for the project.

本项目实施所需全部必要文件的准备

1.8 coordination with appointed contractors, suppliers, specialists and other consultants.

与指定承建商、供应商、专家和其他顾问的协商

1.9 periodical project supervision of items 1.1 to 1.8 during construction.

施工期间对条款1.1至1.8的履行进行阶段性项目监督

1.10 sketches followed by computerized 3d perspectives (in house) of main areas.

室内主要领域的三维电脑视觉效果的草图

2.0 exclusions 除外方面

2.1 areas not included in the design consultant’s scope of work are external building works, civil and structural engineering, external landscape, mechanical and electrical engineering, plumbing & air conditioning engineering, quantity surveying & computer 3d animation.

不包含在设计咨询服务范围的领域是室外建造工程，土木及结构工程，外部景观，机电工程，水暖和空调系统工程，工料测量和电脑三维动画。

2.2 while the scope of works includes supervision and installation, it does not cover the maintenance or defects liability period following the award of the ‘practical completion certificate’ to the contractor if any.

尽管服务范围包括监督和安装，但它不包含提交(如有，)承建商“实际完成证书”以后期间的维护或者缺陷责任。

2.3 while the designer will provide intent drawings of typical finishes and fixtures, all shop drawings for specialists tradesmen and propriety systems or products must be submitted by the respective sub contractors appointed for this project. they may include:

尽管设计方将提供典型饰面及固定物的意向图，但为专业施工人员和配套系统或产品的所有施工图纸必须由各自为该项目指定的分包商提交，他们应该包括：

2.3.1 stone works石材工程

2.3.2 external windows or doors (including pocket doors)外部窗户或门(包括小型的门)

2.3.3 elevators and lift drawings电梯和升降机图纸

2.3.4 mechanical & electrical drawings (should there be no m&e consultant appointed)

机电图纸(如果没有指定的机电咨询顾问)

2.3.5 audio visual & it related equipment视听及与计算机相关的设备

2.3.6 imported wardrobes or kitchens进口衣柜或厨房

3.0 fees 费用

the fee for the conceptual design phase through project construction phase shall be charged based on unit rate us dollar per square foot and designable area of square foot. the lump sum of us dollars: dollars only (excluding any local governing withholding taxes). the fee shall be payable by the client as addressed below in the payment schedule.

在项目建设阶段的概念性设计阶段的费用以每英尺 美元和 英尺有效设计面积来计算。包干费用总计 元整(不包括任何政府预扣税)。客户应按以下付款进度支付相应款项。

4.0 terms of payment 支付条款

4.1 payments are due and payable upon presentation of the design consultant’s invoice upon certifying of fees according to paragraph 3.2. an interest of 1% shall be charged on delinquent payments past 30 days.

根据设计方出示并依据3.2条要求的费用证明资料认证的款项是到期可支付的款项。超过三十天的延迟支付款项，设计方有权收取逾期款项1%的利息。

4.2 payments during construction phase shall be made monthly, in proportion to the length of the construction period as define in the work program chart.

建设阶段应按月支付，根据工作计划表规定的建设进度，按比例支付。

4.3 payments for additional services and for reimbursable expenses shall be made monthly upon presentation of design consultants statement of services rendered, or expenses incurred.

额外服务和可报销费用应根据设计方出示的关于相关服务或发生的费用的凭据按月支付。

5.0 definition of services 服务的定义

5.1 conceptual design phase 概念性设计阶段

understanding of client’s need and formulation of concept design for client’s approval. includes advising of the need for authority submissions and additional consultants where appropriate. concept illustrations will be prepared for the client’s understanding of the design intent. no detailing is done at this stage. subsequent changes after the approval of concept design are deemed additional services and shall be chargeable according to paragraph 7.0 unless otherwise stated.

了解客户的需求，制作经客户同意的概念型设计。包括咨询相关管理当局和其他合适的咨询顾问的需求。概念插图是为客户理解设计意图而准备的。该阶段不进行任何细节设计。在客户批准概念性设计后的后续变更应该被视为额外的服务，应根据第7条收取相应款项，除非双方另有约定。

5.2 design development phase 深化设计阶段

development of the approved concept design for client’s approval. includes preparation of working drawings for construction, and selection of materials and finishes.

对经客户批准的概念性设计进行深化。包括为建设施工用的工作图纸的准备，材料和饰面的选择。

appointed consultants shall be coordinated to produce a complete design.

制定顾问应协调制作出一个完整的设计。

necessary detailing will be produced at this stage. 必要的细节设计将在该阶段完成。

project cost increment can be implemented at this stage if client desire for better quality material/finishes that is not provided for in the original budget or additional services.

该阶段客户可以要求获得质量比最初商谈提供或额外服务中约定的质量更好的材料或饰面，相应调增相关项目费用。

adjusted project fee shall propose by design consultant in the ‘fee amendment schedule’ upon client’s request for project fee increment.

调整的项目费用应有设计咨询单位在“费用变更单”中根据客户要求而导致项目费用的增量提议。

the ‘fee amendment schedule’ shall supercede paragraph 3.2.changes requested by the client after the approval of production drawings are deemed additional services and shall be chargeable according to paragraph7.0 unless otherwise stated.

客户要求的对施工图的设计变更被批准后，“费用变更单”将取代第3.2条的约定，被视为额外的服务，应根据第7条收取相应款项，除非双方另有约定。

5.3 project documentation phase 项目文件阶段

preparation of all necessary technical specifications for the project.

准备该项目所需的所有必要的技术性规定。

all necessary design coordination with other consultants shall be completed by this stage.

与其他设计单位协调所有的设计必须在该阶段完成。

relevant authority approval for commencement of work shall be awarded by this stage, when appropriate.

该阶段合适时间应获得相关部门同意开工的批示。

client shall be notified upon completion of this stage. 完成该阶段时应通知客户。

any changes requested by client at this stage shall be deemed additional services and shall be chargeable according to paragraph7.0 unless otherwise stated.

客户在该阶段要求的任何变更应被视为额外的服务，除非双方另有约定，应根据第7条收取相应款项。

5.4 construction phase建设施工阶段

implementation of the approved design. 经批准同意的设计的实施

design consultant shall supervise site installation, review all selected materials in the approved documentation delivered to site, for size quality and conditions, and to reject materials that is not according to specification.

设计方应监督现场安装，检查所有批准文件中选定的被运至现场的材料，包括规格、质量和品质，拒收不符合规范的材料。

the design consultant shall provide final inspection and a practical completion certificate shall be awarded upon consultant’s satisfaction that all works has been completed accordance to approved drawings.

设计方应提供最终的检验以及提交表明咨询方认为所有工作根据批准图纸已经完成的实际完成证明。

changes by client at this stage are considered additional services and shall be chargeable according to paragraph 7.0.

客户在该阶段要求的任何变更应被视为额外的服务，除非双方另有约定，应根据第7条收取相应款项。

in addition, a delay fee shall be charged for additional cost of labour, overheads, warehousing, and material cost in accordance to the schedule in the specifications as the result of delays and cost incurred by such request.

此外，设计方有权收取因延误施工工期而导致的人工费用、间接成本、仓储和材料费用等逾期费用，以及因此而导致的的其他损失。

6.0 amendment of approved drawings by design consultant

设计终稿的变更

6.1 the design consultant reserved the right to change approved design, detailing, materials, finishes and specification due to unforeseen circumstances that is not within the control of the design consultant. such changes shall be commuted to the client and no additional service charge shall be payable by the client. however additional cost incurred to labour and material shall be reimbursed by the client.

由于不可预见即设计方无法掌控的情况，设计方保留对设计终稿的设计、细节设计、材料、完成和规范的修改权。此等设计修改应减轻客户的义务，即客户无需就该等设计的修改向设计方支付额外的费用。但额外的人工费和材料费应由客户承担。

7.0 compensation for additional services 额外服务费用

7.1 for project representation beyond that is already mentioned, compensation shall be computed as follows: dollars per hour (s$100.00/hour)

对于上述提到的额外服务的补偿费，应按每小时 元计算

7.2 this service shall be approved by client in writing before the design consultant provides such services.

设计方在提供额外服务前应获得客户事先的书面许可。

7.3 in cases which design consultant wavered or lowered charges of additional services of a particular request, they are deemed one off provision of the subject matter concern, and do not render this paragraph void for subsequent request arising, even if they are similar requests.

除非设计方同意对某项特定的额外服务给予优惠或降低收费，否则他们对于每一特定主题的收费是单独收费，不会因为之后而来设计要求是相似的而放弃收取费用。

8.0 reimbursable expenses 可补偿费用

8.1 reimbursable expenses are in addition to compensation for basic and additional services. it shall include cost incurred by the design consultant and its employees in the interest of the project, as identified in the following clauses.

可补偿费用是指除基本和附加服务外的费用。包括设计方及其工作人员为了项目利益而发生的费用，具体由以下条款确认。

8.2 expenses for all travel related cost including business class airfares with singapore airlines or equivalent, 5 star hotel accommodation, surface transportation and luggage handling or courier services.

包含新加坡航空商务舱或其他等价机票、五星级酒店住宿费、地面交通费、包裹搬运费或快递服务费在内的相关差旅费。

8.3 expense for professional and perspective drawings and/or scale models at the request of the client, plus 10% handling charge.

客户要求的专业效果图纸和/或测绘模型的费用以及10%的手续费。

8.4 expense for courier services, postage and handling of drawings, specification and other documents.

快递服务费，图纸、说明书和其他相关文件的邮费及包装费

8.5 expense for colour prints or colour slides when requested by client.

客户要求的彩印或者彩色幻灯片费用。

8.6 professional fees and reimbursable expenses of supporting consultants.

辅助顾问的专业费用和可补偿费用。

8.7 documentation and lithography cost, and fees payable to authorities where relevant.

文件及印刷费用，以及支付给相关政府部门的费用。

8.8 site staffs appointed and will act under the direction of the relevant consultants. client shall reimburse the consultant all expenses incurred by such appointment.

任命工地人员且在相关顾问的指导下工作。客户应当补偿该顾问在此任命下发生的所有花费。

9.0 payment withheld 支付扣留

9.1 no deductions shall be made from design consultant’s compensation due to penalty, liquidated damages, or due to the cost of changes in the works other than those, which the design consultant has been found liable due to, be liable. the design consultant’s work shall be deemed to be complete upon the implementation of the work based on the approved working drawings under the design development phase.

以下费用不得被抵扣：(1)设计方由于罚金、违约金而获得的赔偿金;(2)除了被确认的由于设计方的责任而导致的设计变化而产生的费用。基于在设计开发阶段被批准的设计图纸开始施工时设计方的工作即被视为已完成。

10.0 damage or destruction of works 工程毁损

10.1 if at anytime before the completion of the project, the works, or equipment or any part thereof shall be damaged, or destroyed by operation of war, riot, civil commotion, natural catastrophe, or any other circumstances beyond the control of the design consultant, the client may require the design consultant to resume work on the project. the design consultant may do so upon notification in writing by the client. however, the remedial work and subsequent additional works relating to the project shall be subjected to a mutually agreed fee, before the work is resumed.

在项目竣工前的任何时间，如若发生由于战争，动乱，内乱，自然灾害或者其他任何不在设计方控制内的事件而导致工程、设备或者其他设施毁损灭失的，客户有权要求设计方重新开始工程的相关工作。设计方应当在收到客户的书面通知后开始工作。在工作重新开始前，双方应当确认好补救工作和随后的附加工作的具体费用。

11.0 care and diligence 谨慎勤勉义务

11.1 the design consultant shall exercise all skill, care and diligence, and shall discharge his obligations under appointment in accordance to sound professional practice.

设计方应该运用专业技能勤勉谨慎地履行合同，并且按照约定根据合理的专业实践履行义务。

12.0 termination 合同终止

12.1 the obligation to provide further services under this agreement may be terminated by either party upon 14 days written notice in the event of substantial failure by the other party to perform in accordance to the term through no fault of the terminating party.

如若发生导致合同实际履行不能的事件，一方在无过错的前提下提前14日书面通知另一方后合同义务即告终止。

12.2 the client upon may terminate this agreement not less than 14 days written notice to the design consultant in the event that the project is permanently abandoned. if the client abandons the project for 90 consecutive days, the design consultant may terminate the agreement by written notice.

如若工程被永久废弃，客户需提前14日书面通知设计方以终止合同。如果客户持续90日废弃该工程，设计方可书面通知终止合同。

12.3 the agreement may be terminated if either party commits a breach of agreement and fails to remedy within 14 days after the notification in writing specifying the breach and requiring its remedy.

一方违约后，另一方可以通知对方采取补救措施。违约方在收到对方的书面通知后14日内未能成功补救的，未违约方可以终止合同。

12.4 this contracts shall terminate with immediate effect if either party commits an act of bankruptcy of commerce proceeding of winding up (other than for reason of amalgamation or reconstruction of the company), or if an administrator, liquidator or receiver is appointed for the whole or part of the business of the party.

一方进入破产程序(公司合并或者重组除外)后，或者清算人或破产管理人被指派接管其全部或部分事务，本合同即告终止。

12.5 in the event of any termination, the design consultant shall be paid for all services rendered to the dated of termination, including any reimbursable expenses and termination expenses. the design consultant shall submit his account for the balance of payment with 30 days of termination. the client shall pay all outstanding fees within 30 days upon the receipt of the account. a monthly interest of 1% is chargeable if payment due to the design consultant is not received after 30 days upon issuance of the final account.

合同终止事由发生时，客户须支付设计方包括可补偿费用以及合同终止费用在内的合同终止前发生的所有服务费用。设计方须提交合同终止30日前的收支帐户明细。客户须支付30日内帐户中列明的应付未付款项。最终账户确认后30日内没有付清的，设计方有权按每月1%收取利息。

13.0 opinion of cost 成本建议

13.1 as the design consultant has no control over the cost of labor, materials, equipment or services furnished by others, as well as the contractor’s method of pricing, and/or market conditions. the preliminary estimates of construction cost are made on the basis of experience and qualifications; they represent the best judgement as experience professionals, familiar with the construction industry. however, the design consultant does not guarantee that such estimates will not vary from the actual construction cost, and, or fee of services quoted by the relevant party. services to modify contract documents to bring the construction cost within any limitation established by the client may be considered additional services and paid for as such by the client at a mutually agreed fee.

设计方不能控制由其他方提供的劳务、材料、设备和服务费用，以及施工方的定价方法和/或市场情况。初步的建设成本预估是基于经验和资历的，设计方熟悉建筑行业，代表有经验专业人员作出最好的判断。但是设计方并不确保其所做的预估一定与由相关方提供的实际的建筑成本或者服务费用相一致。在客户设立的限制下提供的修改施工成本合同文件服务将被视为附加服务，相关费用应以双方一致同意为准。

14.0 settlement of dispute 纠纷处理

本约定书的所有方面均应适用新加坡国的法律进行解释并受其约束。与本约定书有关的任何纠纷或争议，双方均可提交 进行仲裁;

all of the agreement shall be interpreted and governed by the laws of singapore. any disputes in connection with the agreement shall be settled through friendly negotiation. if negotiation fails, the disputes can be submitted to for arbitration.

(签署 略)

室内装修设计协议(中英文)

室内装修设计协议

AGREEMENT OF HOUSE INTERIOR DESIGN

This AGREEMENT OF INTERIOR DESIGN made this date of between A (hereinafter called "the Client" which expression includes their legal representatives, successors in title an assigns) of the one part and B practicing as design consultant at C (hereinafter called “the Designer" which expression includes his/legal representatives, successors in titles and permitted assigns) of the other part.

WHEREAS the Client intends to construct and complete. (hereinafter called the project);AND WHEREAS the Client is desirous of appointing the Designer to provide professional design services for the Project on the terms and conditions hereinafter appearing

IT IS HEREBY AGREED BETWEEN THE PARTIES HERETO AS FOLLOWS:

本设计协议由甲方(客户)和乙方(设计顾问)及丙方(设计公司)于 日签订。

鉴于客户意欲建设并完成本工程;鉴于客户愿意指定设计公司依照以下条款为本工程提供专业设计服务。

因此，双方达成协议如下：

1.0 SCOPE OF WORK 服务范围

1.1 Interior layout and spatial re-planning of all areas.

室内布局和所有领域的空间重新规划。

1.2 Interior design conceptualization and design implementation.

室内设计构思和设计实施。

1.3 Interior finishes advice, specification and implementation.

室内饰面咨询，规范和实施。

1.4 Interior lighting conceptualization, selection and implementation.

室内灯具构思、选择和实施。

1.5 Interior fixtures specification and design for custom made & built in furniture or doors not already in the architectural schedule.

为客户制作或建造于不包括建筑物内已有的家具或门上的室内固定物或附着物的规范和设计

1.6 Loose furniture consultation and selection.活动家具的咨询和选择

1.7 Preparation of all necessary documents for the implementation for the project.

本项目实施所需全部必要文件的准备

1.8 Coordination with appointed contractors, suppliers, specialists and other consultants.

与指定承建商、供应商、专家和其他顾问的协商

1.9 Periodical project supervision of items 1.1 to 1.8 during construction.

施工期间对条款1.1至1.8的履行进行阶段性项目监督

1.10 Sketches followed by computerized 3D perspectives (in house) of main areas.

室内主要领域的三维电脑视觉效果的草图

2.0 EXCLUSIONS 除外方面

2.1 Areas not included in the Design Consultant’s scope of work are External Building Works, Civil and Structural Engineering, External Landscape, Mechanical and Electrical Engineering, Plumbing & Air Conditioning Engineering, Quantity Surveying & Computer 3D animation.

不包含在设计咨询服务范围的领域是室外建造工程，土木及结构工程，外部景观，机电工程，水暖和空调系统工程，工料测量和电脑三维动画。

2.2 While the scope of works includes supervision and installation, it does not cover the maintenance or defects liability period following the award of the ‘Practical Completion Certificate’ to the contractor if any.

尽管服务范围包括监督和安装，但它不包含提交(如有，)承建商“实际完成证书”以后期间的维护或者缺陷责任。

2.3 While the Designer will provide intent drawings of typical finishes and fixtures, all shop drawings for specialists tradesmen and propriety systems or products must be submitted by the respective sub contractors appointed for this project. They may include:

尽管设计方将提供典型饰面及固定物的意向图，但为专业施工人员和配套系统或产品的所有施工图纸必须由各自为该项目指定的分包商提交，他们应该包括：

2.3.1 Stone works石材工程

2.3.2 External windows or doors (including pocket doors)外部窗户或门(包括小型的门)

2.3.3 Elevators and lift drawings电梯和升降机图纸

2.3.4 Mechanical & Electrical drawings (should there be no M&E consultant appointed)

机电图纸(如果没有指定的机电咨询顾问)

2.3.5 Audio visual & IT related equipment视听及与计算机相关的设备

2.3.6 Imported wardrobes or kitchens进口衣柜或厨房

3.0 FEES 费用

The fee for the conceptual design phase through project construction phase shall be Charged based on unit rate US Dollar Per Square Foot and designable area of Square Foot. The lump sum of US Dollars: Dollars Only (excluding any local governing withholding taxes). The fee shall be payable by the client as addressed below in the payment schedule.

在项目建设阶段的概念性设计阶段的费用以每英尺 美元和 英尺有效设计面积来计算。包干费用总计 元整(不包括任何政府预扣税)。客户应按以下付款进度支付相应款项。

4.0 TERMS OF PAYMENT 支付条款

4.1 Payments are due and payable upon presentation of the Design Consultant’s invoice upon certifying of fees according to paragraph 3.2. An interest of 1% shall be charged on delinquent payments past 30 days.

根据设计方出示并依据3.2条要求的费用证明资料认证的款项是到期可支付的款项。超过三十天的延迟支付款项，设计方有权收取逾期款项1%的利息。

4.2 Payments during construction phase shall be made monthly, in proportion to the length of the construction period as define in the Work Program Chart.

建设阶段应按月支付，根据工作计划表规定的建设进度，按比例支付。

4.3 Payments for additional services and for reimbursable expenses shall be made monthly upon presentation of Design Consultants statement of services rendered, or expenses incurred.

额外服务和可报销费用应根据设计方出示的关于相关服务或发生的费用的凭据按月支付。

5.0 DEFINITION OF SERVICES 服务的定义

5.1 Conceptual Design Phase 概念性设计阶段

Understanding of client’s need and formulation of concept design for client’s approval. Includes advising of the need for Authority submissions and additional consultants where appropriate. Concept Illustrations will be prepared for the client’s understanding of the design intent. No detailing is done at this stage. Subsequent changes after the approval of concept design are deemed additional services and shall be chargeable according to paragraph 7.0 unless otherwise stated.

了解客户的需求，制作经客户同意的概念型设计。包括咨询相关管理当局和其他合适的咨询顾问的需求。概念插图是为客户理解设计意图而准备的。该阶段不进行任何细节设计。在客户批准概念性设计后的后续变更应该被视为额外的服务，应根据第7条收取相应款项，除非双方另有约定。

5.2 Design Development Phase 深化设计阶段

Development of the approved concept design for client’s approval. Includes preparation of working drawings for construction, and selection of materials and finishes.

对经客户批准的概念性设计进行深化。包括为建设施工用的工作图纸的准备，材料和饰面的选择。

Appointed consultants shall be coordinated to produce a complete design.

制定顾问应协调制作出一个完整的设计。

Necessary detailing will be produced at this stage. 必要的细节设计将在该阶段完成。

Project cost increment can be implemented at this stage if client desire for better quality material/finishes that is not provided for in the original budget or additional services.

该阶段客户可以要求获得质量比最初商谈提供或额外服务中约定的质量更好的材料或饰面，相应调增相关项目费用。

Adjusted project fee shall propose by Design Consultant in the ‘Fee Amendment Schedule’ upon client’s request for project fee increment.

调整的项目费用应有设计咨询单位在“费用变更单”中根据客户要求而导致项目费用的增量提议。

The ‘Fee Amendment Schedule’ shall supercede paragraph 3.2.Changes requested by the client after the approval of production drawings are deemed additional services and shall be chargeable according to paragraph7.0 unless otherwise stated.

客户要求的对施工图的设计变更被批准后，“费用变更单”将取代第3.2条的约定，被视为额外的服务，应根据第7条收取相应款项，除非双方另有约定。

5.3 Project Documentation Phase 项目文件阶段

Preparation of all necessary technical specifications for the project.

准备该项目所需的所有必要的技术性规定。

All necessary design coordination with other consultants shall be completed by this stage.

与其他设计单位协调所有的设计必须在该阶段完成。

Relevant authority approval for commencement of work shall be awarded by this stage, when appropriate.

该阶段合适时间应获得相关部门同意开工的批示。

Client shall be notified upon completion of this stage. 完成该阶段时应通知客户。

Any changes requested by client at this stage shall be deemed additional services and shall be chargeable according to paragraph7.0 unless otherwise stated.

客户在该阶段要求的任何变更应被视为额外的服务，除非双方另有约定，应根据第7条收取相应款项。

5.4 Construction Phase建设施工阶段

Implementation of the approved design. 经批准同意的设计的实施

Design Consultant shall supervise site installation, review all selected materials in the approved documentation delivered to site, for size quality and conditions, and to reject materials that is not according to specification.

设计方应监督现场安装，检查所有批准文件中选定的被运至现场的材料，包括规格、质量和品质，拒收不符合规范的材料。

The Design consultant shall provide final inspection and a Practical Completion Certificate shall be awarded upon Consultant’s satisfaction that all works has been completed accordance to approved drawings.

设计方应提供最终的检验以及提交表明咨询方认为所有工作根据批准图纸已经完成的实际完成证明。

Changes by client at this stage are considered additional services and shall be chargeable according to paragraph 7.0.

客户在该阶段要求的任何变更应被视为额外的服务，除非双方另有约定，应根据第7条收取相应款项。

In addition, a delay fee shall be charged for additional cost of labour, overheads, warehousing, and material cost in accordance to the schedule in the specifications as the result of delays and cost incurred by such request.

此外，设计方有权收取因延误施工工期而导致的人工费用、间接成本、仓储和材料费用等逾期费用，以及因此而导致的的其他损失。

6.0 AMENDMENT OF APPROVED DRAWINGS BY DESIGN CONSULTANT

设计终稿的变更

6.1 The Design Consultant reserved the right to change approved design, detailing, materials, finishes and specification due to unforeseen circumstances that is not within the control of the Design Consultant. Such changes shall be commuted to the client and no additional service charge shall be payable by the client. However additional cost incurred to labour and material shall be reimbursed by the client.

由于不可预见即设计方无法掌控的情况，设计方保留对设计终稿的设计、细节设计、材料、完成和规范的修改权。此等设计修改应减轻客户的义务，即客户无需就该等设计的修改向设计方支付额外的费用。但额外的人工费和材料费应由客户承担。

7.0 COMPENSATION FOR ADDITIONAL SERVICES 额外服务费用

7.1 For project representation beyond that is already mentioned, compensation shall be computed as follows: Dollars Per Hour (S$100.00/Hour)

对于上述提到的额外服务的补偿费，应按每小时 元计算

7.2 This Service shall be approved by client in writing before the Design Consultant provides such services.

设计方在提供额外服务前应获得客户事先的书面许可。

7.3 In cases which Design Consultant wavered or lowered charges of additional services of a particular request, they are deemed one off provision of the subject matter concern, and do not render this paragraph void for subsequent request arising, even if they are similar requests.

除非设计方同意对某项特定的额外服务给予优惠或降低收费，否则他们对于每一特定主题的收费是单独收费，不会因为之后而来设计要求是相似的而放弃收取费用。

8.0 REIMBURSABLE EXPENSES 可补偿费用

8.1 Reimbursable Expenses are in addition to compensation for basic and additional services. It shall include cost incurred by the Design Consultant and its employees in the interest of the project, as identified in the following clauses.

可补偿费用是指除基本和附加服务外的费用。包括设计方及其工作人员为了项目利益而发生的费用，具体由以下条款确认。

8.2 Expenses for all travel related cost including business class airfares with Singapore Airlines or Equivalent, 5 star hotel accommodation, surface transportation and luggage handling or courier services.

包含新加坡航空商务舱或其他等价机票、五星级酒店住宿费、地面交通费、包裹搬运费或快递服务费在内的相关差旅费。

8.3 Expense for professional and perspective drawings and/or scale models at the request of the client, plus 10% handling charge.

客户要求的专业效果图纸和/或测绘模型的费用以及10%的手续费。

8.4 Expense for courier services, postage and handling of drawings, specification and other documents.

快递服务费，图纸、说明书和其他相关文件的邮费及包装费

8.5 Expense for colour prints or colour slides when requested by client.

客户要求的彩印或者彩色幻灯片费用。

8.6 Professional fees and reimbursable expenses of supporting consultants.

辅助顾问的专业费用和可补偿费用。

8.7 Documentation and lithography cost, and fees payable to authorities where relevant.

文件及印刷费用，以及支付给相关政府部门的费用。

8.8 Site Staffs appointed and will act under the direction of the relevant consultants. Client shall reimburse the consultant all expenses incurred by such appointment.

任命工地人员且在相关顾问的指导下工作。客户应当补偿该顾问在此任命下发生的所有花费。

9.0 PAYMENT WITHHELD 支付扣留

9.1 No deductions shall be made from Design consultant’s compensation due to penalty, liquidated damages, or due to the cost of changes in the Works other than those, which the Design Consultant has been found liable due to, be liable. The Design Consultant’s work shall be deemed to be complete upon the implementation of the work based on the approved working drawings under the Design Development Phase.

以下费用不得被抵扣：(1)设计方由于罚金、违约金而获得的赔偿金;(2)除了被确认的由于设计方的责任而导致的设计变化而产生的费用。基于在设计开发阶段被批准的设计图纸开始施工时设计方的工作即被视为已完成。

10.0 DAMAGE OR DESTRUCTION OF WORKS 工程毁损

10.1 If at anytime before the completion of the project, the works, or equipment or any part thereof shall be damaged, or destroyed by operation of war, riot, civil commotion, natural catastrophe, or any other circumstances beyond the control of the Design Consultant, the client may require the Design Consultant to resume work on the project. The Design Consultant may do so upon notification in writing by the client. However, the remedial work and subsequent additional works relating to the project shall be subjected to a mutually agreed fee, before the work is resumed.

在项目竣工前的任何时间，如若发生由于战争，动乱，内乱，自然灾害或者其他任何不在设计方控制内的事件而导致工程、设备或者其他设施毁损灭失的，客户有权要求设计方重新开始工程的相关工作。设计方应当在收到客户的书面通知后开始工作。在工作重新开始前，双方应当确认好补救工作和随后的附加工作的具体费用。

11.0 CARE AND DILIGENCE 谨慎勤勉义务

11.1 The Design Consultant shall exercise all skill, care and diligence, and shall discharge his obligations under appointment in accordance to sound professional practice.

设计方应该运用专业技能勤勉谨慎地履行合同，并且按照约定根据合理的专业实践履行义务。

12.0 TERMINATION 合同终止

12.1 The obligation to provide further services under this agreement may be terminated by either party upon 14 days written notice in the event of substantial failure by the other party to perform in accordance to the term through no fault of the terminating party.

如若发生导致合同实际履行不能的事件，一方在无过错的前提下提前14日书面通知另一方后合同义务即告终止。

12.2 The client upon may terminate this agreement not less than 14 days written notice to the Design Consultant in the event that the project is permanently abandoned. If the client abandons the project for 90 consecutive days, the Design consultant may terminate the agreement by written notice.

如若工程被永久废弃，客户需提前14日书面通知设计方以终止合同。如果客户持续90日废弃该工程，设计方可书面通知终止合同。

12.3 The agreement may be terminated if either party commits a breach of agreement and fails to remedy within 14 days after the notification in writing specifying the breach and requiring its remedy.

一方违约后，另一方可以通知对方采取补救措施。违约方在收到对方的书面通知后14日内未能成功补救的，未违约方可以终止合同。

12.4 This contracts shall terminate with immediate effect if either party commits an act of bankruptcy of commerce proceeding of winding up (other than for reason of amalgamation or reconstruction of the company), or if an administrator, liquidator or receiver is appointed for the whole or part of the business of the party.

一方进入破产程序(公司合并或者重组除外)后，或者清算人或破产管理人被指派接管其全部或部分事务，本合同即告终止。

12.5 In the event of any termination, the Design Consultant shall be paid for all services rendered to the dated of termination, including any reimbursable expenses and termination expenses. The Design Consultant shall submit his account for the balance of payment with 30 days of termination. The client shall pay all outstanding fees within 30 days upon the receipt of the account. A monthly interest of 1% is chargeable if payment due to the Design Consultant is not received after 30 days upon issuance of the final account.

合同终止事由发生时，客户须支付设计方包括可补偿费用以及合同终止费用在内的合同终止前发生的所有服务费用。设计方须提交合同终止30日前的收支帐户明细。客户须支付30日内帐户中列明的应付未付款项。最终账户确认后30日内没有付清的，设计方有权按每月1%收取利息。

13.0 OPINION OF COST 成本建议

13.1 As the Design Consultant has no control over the cost of labor, materials, equipment or services furnished by others, as well as the contractor’s method of pricing, and/or market conditions. The preliminary estimates of construction cost are made on the basis of experience and qualifications; they represent the best judgement as experience professionals, familiar with the construction industry. However, the Design Consultant does not guarantee that such estimates will not vary from the actual construction cost, and, or fee of services quoted by the relevant party. Services to modify Contract Documents to bring the construction cost within any limitation established by the client may be considered additional services and paid for as such by the client at a mutually agreed fee.

设计方不能控制由其他方提供的劳务、材料、设备和服务费用，以及施工方的定价方法和/或市场情况。初步的建设成本预估是基于经验和资历的，设计方熟悉建筑行业，代表有经验专业人员作出最好的判断。但是设计方并不确保其所做的预估一定与由相关方提供的实际的建筑成本或者服务费用相一致。在客户设立的限制下提供的修改施工成本合同文件服务将被视为附加服务，相关费用应以双方一致同意为准。

14.0 SETTLEMENT OF DISPUTE 纠纷处理

本约定书的所有方面均应适用新加坡国的法律进行解释并受其约束。与本约定书有关的任何纠纷或争议，双方均可提交 进行仲裁;

All of the agreement shall be interpreted and governed by the laws of Singapore. Any disputes in connection with the agreement shall be settled through friendly negotiation. If negotiation fails, the disputes can be submitted to for arbitration.

(签署 略)

建设工程委托监理合同（中英文）

contractregistration no: ______    _____

合 同  登 记  号:

supervision contract

for construction project

建设工程委托监理合同

project name:

工程项目名称:

entrustor (client):

委托方:  (业主)

service provider: shanghai tongji project management       (supervisor)        and consulting co. ltd.

服务方:    (监理人)

place of signing:

签订地点:

date of signing:

签订时间:

valid period:

有效日期:

shanghai, p. r. china

中国，上海

XX年  月  日

supervision contract for constructionproject

建设工程委托监理合同

part iagreement

第一部分 建设工程委托监理合同

this agreement is signed between                                 (hereinafter referred to as "theclient") and shanghai tongjiproject management and consulting co. ltd. (hereinafter referred toas the "supervisor") through mutual consultation.

委托人      与监理人---------    经过双方协商一致,签订本合同.

i.    brief information of the project for which the client desires thosesupervision services should be performed by the supervisor (hereinafterreferred to as "the project") is as follows:

委托人委托监理人监理的工程(以下简称"本工程")概况如下:

project name:

工程名称:               908新基地建设项目

projectlocation:

工程地点:          重庆北部黄茅坪组团经开园b04地块

project size:        about  185252 m2

工程规模:             约185252 m2

totalinvestment:     about           yuan rmb

总投资:           约       万元人民币

ii.    in this agreement words shall have the same meanings as areassigned to them in part ii of this supervision contract (hereinafter referredto as “the contract”) - standard conditions.

本合同的有关词语含义与本合同第二部分>中赋予它们的定义相同.

iii.       the following documents shall be deemed to form part of thisagreement:

下列文件均为本合同的组成部分:

(1)        this agreement;

此协议书;

(2)        standard conditions of the contract;

本合同标准条件;（条款）

）

(3)        conditions of particular application;

本合同专用条件;（ 条款）

(4)        supplementary documents and amendments jointly signed by the twoparties during the execution of the contract.

在实施过程中双方共同签署的补充与修正文件.

⑸  监理人在报价时确定的的拟派现场监理人员名单和现场监理人员进场计划作为本合同附件。

iv.     in consideration of the payment to be made by the client to thesupervisor as hereinafter mentioned, the supervisor hereby covenants with theclient to perform supervision services in the scope as stated in the conditionsof particular application in conformity with the provisions of the contract.

考虑到以下提到的委托人向监理人的付款，监理人向委托人承诺,按照本合同的规定,承担本合同专用条件中议定范围内的监理业务.

v.      the client hereby covenants to pay the supervisor, inconsideration of the performance of the supervision services, such amount asmay become payable under the provisions of the contract at the times and in themanner and currency type prescribed by the contract.

考虑到监理人提供的监理服务，委托人向监理人承诺按照本合同注明的期限,方式,币种,向监理人支付报酬.

inwitness whereof the parties hereto have caused this agreement to beexecuted from april, to october, . if for any reasons the project stops for more than one month uninterrupted, the ending date will be postponedwith same periods.

本合同自施工单位进场时开始, 至整个工程竣工验收止完成. 如果项目进行中，被停止连续时间超过一个月，完成时间应该被顺延。

this agreement has sixsets of original copies, they have the same legal effect, and each party shallhold three copies.

本合同一式 陆 份,具有同等法律效力, 双方各执 叁 份.

the client:

委托人:

(seal)

(签章))

the supervisor:     shanghai tongji project                                   management and                                      consulting co. ltd.

监理人:

(seal)

(签章)

address:

住所:

address:     73 chifeng road

shanghai, XX92

住所:             上海市赤峰路73号,XX92

legal representative: (signature)

法定代表人: (签章)

legal representative: (signature)

法定代表人: (签章)

principal bank:

开户银行:

principal bank:

开户银行: 交行赤峰路支行

bank account no.:

10017215-09300007736

帐号:

bank account no.:

帐号: 310066344010141052919

tel.

电话:

tel.           8621 65989931

电话:        8621 65989931

this contract is signedon   ,

本合同签订于: XX年 -- 月  日

part ii    standardconditions

第二部分    标准条件

definitions,applicable languages and laws词语定义, 适用语言和法规

article 1  the following words and expressions shall havethe meanings assigned to them except where the context otherwise requires:

第一条 下列名词和用语，除上下文另有规定外，具有如下所赋予的含义:

(1)          "project" means the projectfor which the supervision services are to be provided.

"工程" 是指实施委托人委托监理人监理的工程。

(2)          "client" means the party whois responsible for the direct investment and who employs the supervisor, andlegal successors to the client.

"委托人"是指承担直接投资责任和委托监理人的一方,以及其合法继承人。

(3)     "supervisor" means the party whois employed by the client to perform supervision services and assumesupervision liabilities, and legal successors to the supervisor.

"监理人"是指受委托人委托承担监理业务和监理责任的一方,以及其合法继承人.

(4)                 "supervision team"means the group of staff sent by the supervisor to carry out supervision on thesite of the project.

"监理机构"是指监理人派驻本工程现场实施监理业务的组织.

(5)                 "chief supervisionengineer" means the person certificated by the local authority as  chief supervision engineer and designated bythe client and supervisor to be fully responsible for supervising the executionof the contract.

"总监理工程师"是指经当地政府部门认证为的总监理工程师并且由委托人及监理人指定对监督履行本合同全权负责的人.

(6)                 "contractor" meansthe person(s) other than the supervisor with whom the client signs contract inrelation to the construction of the project.

"承包人"是指除监理人以外,委托人就本工程的建设有关事宜签订合同的当事人.

(7)                 "normal services"means the scope of supervision work prescribed in the conditions of particular application.

"正常工作"是指双方在专用条件中约定的监理工作的范围.

(8)                 "additional services"means: 1) works outside of the scope of supervision work, and added to thecontract by written agreement of the parties; 2) additional works as a resultof addition to the scope of construction work or program delay on the part ofthe client or the contractor.

"附加工作"是指: 1)监理工作范围以外,通过双方书面协议另外增如本合同的工作;2)建设工作范围的增加或者由于委托人或承包人原因致使进度的延误,而造成的附加的工作.

(9)                 "exceptionalservices" means the works other than the normal services and theadditional services, but which are necessarily performed by the supervisor inaccordance with article 33.

"额外工作"是指正常工作和附加工作以外，根据第三十三条规定监理人需要完成的工作。

(10)        "day" means the period betweenany one 0:00 a.m. and the next.

"日"是指任何一个零时至第二天零时的时间段.

(11)               "month" means a periodof one month according to the gregorian calendar commencing with any day of themonth.

"月"是指根据公历从一个月份中任何一天开始的一个月的时间段.

article2  this supervision contract shall begoverned by chinese laws, statutes, administrative regulations, anddepartmental rules & regulations, local laws, rules & regulationsspecified in the standard conditions and conditions of particular application.

第二条   本建设工程委托监理合同适用的法律是中国的法律，条例,行政法规，以及标准条件及专用条件中载明的部门规章或地方法规，地方规章。

article 3  the contract shall be written in both englishand chinese, both of which shall be equally binding.

第三条   本合同应以中文和英文记载，中英文应具有同等效力。

obligations of the supervisor监理人的义务

article 4 the supervisor shall designate the supervision team andsuperintendents necessary for carrying out the supervising works; provide tothe client a name-list of the chief supervision engineer, main staff of thesupervision team and a supervision plan and perform the supervision serviceswithin the scope of work as stated in the conditions of particular application.during the execution of the contract, the supervisor shall submit supervisionreport to the client at regular interval as stated in the contract.

第四条 监理人应派出监理工作需要的监理机构及监理人员，向委托人报送委派的总监理工程师及其监理机构主要成员名单，监理规划，完成监理合同专用条件中约定的监理工程范围内的监理业务。在履行本合同义务期间，应按合同约定定期向委托人报告监理工作。

article5  thesupervisor shall exercise reasonable care and diligence, provide advice at anappropriate level in the performance of the obligations under the contract tothe client and indemnify the lawful rights and interests of various parties.

第五条   监理人应认真，勤奋地工作，在履行合同义务时为委托人提供与其水平相应的咨询意见，公正维护各方的合法权益。

article6  any facilities and articles supplied by theclient for use by the supervisor shall be properly used and maintained andremain the property to the client . when the services are completed orterminated the supervisor shall deliver to the client such facilities andunconsumed articles in good working order.

第六条   监理人使用委托人提供的设施和物品属委托人的财产，应恰当使用和维护。在监理工作完成或中止时，应将其设施和剩余的物品完好地移交给委托人。

article7  during thecontract period or after the contract is terminated, without the consent of theclient, the supervisor shall not disclose the confidential information inrelation to the project and the contract.

第七条   合同期内或本合同终止后，未征得委托人同意，不得泄露与本工程和本 合同有关的保密信息。

obligationsof the client

委托人的义务

article 8  the client shall pay anadvance payment to the supervisor prior to the commencement of the services ofthe supervisor, if such advance  payment is stated in the conditions ofparticular application.

第八条       委托人在监理人开展监理业务之前应向监理人支付预付款,如果该预付款在专用条件中陈述。

article 9  the client shall beresponsible for all coordination of external relationships in relation to theconstruction of the project. if the client assigns part or all of suchcoordination works to the supervisor as is necessary, then the work to beassigned and relevant terms of remuneration shall be specified in thesupplemental clauses.

第九条       委托人应当负责本工程建设的所有外部关系的协调（监理人所属协调关系除外）。根据需要，如需将 部分或全部协调工作委托监理人承担，则需在补充条款中明确委托的工作和相应的报酬条款。

article 10  theclient shall, within the agreed time, provide to the supervisor free of chargeall information pertaining to the project and necessary for the supervisionservices.

第十条       委托人应当在双方约定的时间内免费向监理人提供与本工程有关的并为监理工作需要的所有信息。

article 11 on all matters properly referred to him in writing bythe supervisor, the client shall give his decision in writing within the timespecified in the conditions of particular application of the contract.

第十一条   委托人应当在专用条件约定的时间内就监理人向委托人以恰当的书面形式提交的一切事宜作出书面决定。

article 12  the client shall appoint aclients representative (to be specified in the conditions of particularapplication) who is familiar with the project and able to make decision withinspecified time for the purpose of contacting the supervisor. should theclients representative be replaced, the client shall notify the supervisor inadvance.

第十二条   委托人应当授权一名熟悉本工程情况，能在规定时间内作出决定的委托人的代表(将在专用条件中明确)负责与监理人联系，更换委托人代表要提前通知监理人。

article13  the client shall timely notify theawarded contractor, in writing, of the power of the supervisor, roles andauthorities of main staff of the supervisor. such information shall be madeclear in the contract signed by the client and any third party.

第十三条      委托人应当将授予监理人的监理权利，以及监理人主要成员的职能分工及监理权限及时书面通知已选定的合同承包商，并在与任何第三方签订的合同中予以明确。

article14  the client shall notify to contractorto provide the following information to the supervisor within such a time thatthe supervisors work will not be hampered:

第十四条      委托人应通知承包人在不影响监理人开展监理工作的时间内向监理人提供如 下资料：

(1)   listof suppliers & manufacturers of the raw materials, components and parts,mechanical equipment etc. to be used in the project;

与将用于本工程的原材料，构配件，机械设备等的供应和生产厂家名录；

(2)     list of coordinators, cooperators inrelation to the development of the project.

提供与本工程有关的协作人，配合人的名录。

article15  the client shall furnish free ofcharge (including utility fees ) to the supervisor the site office,telecommunication connection, accommodation and other facilities specified in the conditions of particular application.

第十五条      委托人应免费（包括使用费）向监理人提供办公场所、通讯接口，网路接口住宿及合同专用条件约定的其他设施。

article16  given certain circumstances, if thetwo parties agree that the client shallarrange at his own expense for the provision of other personnel to thesupervisor, such agreement shall be reflected in the conditions of particularapplication.

第十六条      根据情况需要，如经双方同意委托人将可以自费向监理人提供其他人员， 应在合同专用条件中予以反映。

rights of the supervisor

监理人的权利

article 17  the supervisor should  havethe following rights within his scope of work. it is hereby understood that anyand all of the following activities shall also be considered as the obligationof the supervisor, who shall perform the following activities whenever it isneeded in order to ensure completion of the project in the best possible mannerand according to the relevant contractual documents and applicable laws:

第十七条      监理人在委托的工程范围内应具有以下权利， 而且在此双方确认任何如下活动也应作为监理人的义务，即其有义务在有必要的情况下为了以最好的方式并以符合全部合同文件和适用的法律的方式完成本项目的目的而进行如下活动。

(1) the right andobligation to make recommendations on the selection of the general contractor

(1)        选择工程总承包人的建议权和义务；

(2) the right andobligation to make recommendations on the selection of the sub-contractor

(2)        选择工程分包人的建议权和义务；

(3)the right and obligation to make recommendations to the client in the respectsof the project including project size, design standard, planning design,technological design and performance requirements.

(3)对工程建设有关事项包括工程规模、设计标准、规划设计、生产工艺设计和使用功能要求，向委托人的建议权和义务；

(4)the right and obligation to advise, in the principles of safety and optimum,the client on the technical problems in the design. if the design is found tobe not in conformity with the quality standards promulgated by the state orspecified in the design contract, the supervisor shall report to the client inwriting.

(4)对工程设计中的技术问题,按照安全和最优化的原则,有权利和义务向委托人提出建议.当发现工程设计不符合国家颁布的建设工程质量标准或设计合同约定的质量标准时,监理人应当书面报告委托人. 并提供处理方案

(5)the right and obligation to review the construction management plan and thetechnical proposal and to  makerecommendation to the client for changes that the contractor could implement toensure quality, on-time completion and cost reduction.

(5)对审查工程施工组织和技术方案, 按照保质量、保工期和降低成本的原则, 并就承包人有可能采取的变化监理人有权利和义务向委托人提出建议并提供处理意见.

(6)   conduct appropriate arrangement andco-ordination with relevant organisations, which can exert beneficial influenceto the development of the project. for all such matters the supervisor shallfirst report to the client in advance and seek the authority of the client tomake such arrangements and co-ordination.

(6)主持工程建设有关协作单位的组织协调, 对于所有协调项应当事先向委托人报告,并要求委托人授权以进行组织协调工作.

(7)   having obtained the consent of the client,the supervisor has the right to give command with regards to commencement,suspension and resumption of the works. but before doing so, he shall report tothe client.  the client’s representativewill be available for contacting in phone to discuss emergency and other matters.

(7)征得委托人同意,监理人有权发布开工令,停工令,复工令,但应当事先向委托人作出书面报告.委托人代表将可以随时电话联系到以就紧急情况和其他事宜与监理人进行研究.

(8)   right and obligation to check and inspect thematerials to be used in the project and quality of construction and to advisethe contractor immediately of any non-conformities. should the contractorcontinue to use the materials after the non-conformity has been identified,then the supervisor must advise the client that the contractor should stopusing them. for materials, components and parts, equipment that are not in conformitywith the design requirements, provisions of the construction contract andnational quality standards, the supervisor has the right to notify the clientthat the contractor should stop using them; for working sequence, divisionaland sub-divisional works that are not in conformity with relevant codes andquality standards, and construction operations that pose safety concerns, thesupervisor has the right to notify the client that the contractor should  stop and make corrections or redo the works.the contractor can resume construction only after he has received the workresumption command from the supervision team via the client..

(8)工程上使用的材料和施工质量的检验权和义务.发现不合格材料应通知承包方，如果承包人在接到通知后仍继续使用该不合格材料, 监理人必须及时通知委托人, 让承包人不得继续使用. 对于不符合设计要求和合同约定及国家质量标准的材料,构配件,设备, 监理人有义务通知委托人让承包人停止使用;对于不符合规范和质量标准的工序,分部分项工程和不安全的施工作业, 监理人有义务及时通知委托人，监理人有权让承包人停工整改,返工. 承包人只有通过委托人收到监理机构发出复工令后才能复工.

(9)rights and obligation to check, supervise the progress of theconstruction.  right to ratify that theactual completion is ahead or behind the completion date specified in theconstruction contract.

(9)工程施工进度的检查、监督权和义务，以及工程实际竣工日期提前或超过工程施工合同规定的竣工期限的签认权和义务；

(10)right and obligation to check and certify by signature that the payment to theconstruction contractor is within the scope of the construction contract, torecheck, confirm, and negate to the settlement of the accounts. without thesignature and confirmation from the chief supervision engineer, the client willnot make payment to the construction contractor.

(10)在工程施工合同约定的工程价格范围内，工程款支付的审核和签认权和义务，以及工程结算的复核确认权与否定权。未经总监理工程师签字确认，委托人不支付工程款。

article 18 during supervision, if theemployee(s) of the contractor is found to be incapable of his job, thesupervision team shall notify the client of the views of the supervision teamon this matter.

第十八条在监理过程中如发现工程承包人员工作不力, 监理机构应将其对此事的观点告知委托人.

article 19 within the scope of work,if the client and the contractor have any dissent and requirement (includingclaim) to each other, and where such dispute is being mediated by an administrativedepartment in charge of construction or being arbitrated by arbitration body(china international economic and trade arbitration commission, shanghai), thesupervisor shall provide relevant proof.

第十九条 在委托的工程范围内，当委托人和承包人对对方有任何意见和要求(包括索赔要求),双方争议由政府建设行政主管部门调解或仲裁机关（中国国际经济贸易仲裁委员会－上海[h1] ）仲裁时，监理人应当提供相关证明。

rightsof the client

委托人的权利

article20  the client has the right to appointthe  contractor and enter into a contractwith that contractor.

第二十条      委托人有选定工程承包人，以及与其签订合同的权利。

article21  the client has the right to decidethe project size and agree the design standard, planning design, technologicaldesign and designed performance requirements; and the right to approveconstruction cost, programme and design variation.

第二十一条         委托人享有对工程规模、设计标准，规划设计、生产工艺设计 和设计使用功能要求的认定权，以及对工程造价、进度计划和设计变更的审批权。

article 22  in the event that the supervisor want to replace the chief supervisionengineer, he shall obtain the client’s consent in advance during the contractconducting period.

第二十二条         在履行本合同期间,监理人调换总监理工程师须事先经委托人同意。

article23  the client has the right to requirethe supervisor to submit  supervisionreport and specific report in each discipline within the supervisor’s scope ofwork..

第二十三条 委托人有权要求监理人提交监理工作报告及监理人业务范围内的专项报告。

article 24  in the event that the client find the supervisor’s staff fails to performduties under the contract, or cause any loss to the project or the clientthrough collusion with the contractor, the client shall be entitled to requirethat such staff be replaced by the supervisor or even terminate the contractand demand the supervisor to assume responsibilities or contiguousresponsibilities in paying compensation.

第二十四条 当委托人发现监理人的职员不按本合同履行监理职责，或与承包人串通给本工程或委托人造成任何损失的，委托人有权要求监理人更换该职员，直到终止合同并要求监理人承担相应的赔偿责任或连带赔偿责任。

liabilities of the supervisor监理人的责任

article25  the supervisor’s liability period isthe valid period of the contract (contract period), including the maintenanceperiod. in the event that the project programme is postponed or delay whichresults in the contract period to be extended, the two parties shall makefurther negotiation to agree an extension of the contract period.

第二十五条         监理人的责任期即本合同有效期（合同期），包括维护期。如果因工程进度的推迟或延误而导致合同期将要延长，双方应进一步协商约定的延长合同期。

article26  the supervisor shall perform hisduties during the contract period. should any financial loss be caused by thefault of the supervisor, he shall pay compensation to the client. accumulatedamount of compensation (except for the compensation specified in article 24)shall not exceed the total payment by the client to the supervisor (excludingincome tax).

第二十六条         监理人在合同期内，应当履行约定的责任。如果因监理人过失而造成了委托人的任何经济损失，其应当向委托人赔偿。累计赔偿总额（除第二十四条规定的赔偿以外）不应超过委托人向监理人支付的报酬总数（除去税金）。赔偿按相关法律执行[h2]

article27  the supervisor shall be notresponsible for any contractor’s nonconformity in quality requirements andcompletion time (for submitting drawings or delivery of goods). in the event ofany force majeure which cause part or all of the execution of the contract tobe impossible, the supervisor shall not be held responsible. but for anyinfringement to article 5, the supervisor shall pay compensation to the client.

第二十七条         监理人对承包人违反施工合同规定的质量要求和完工(交图、交 货)时限，因监理人失责应承担相应的责任，因不可抗力导致本合同不能全部或部分履行，监理人不承担责任。但对违反第五条规定引起的与之有关的事宜，应向委托人承担赔偿责任。

article28  if the claim made by the supervisorto the client cannot be justified, the supervisor shall be responsible for anycost incurred by the client in relation to the claim.

第二十八条       监理人向委托人提出赔偿要求不能成立时，监理人应当补偿由 于该索赔所导致委托人的任何费用支出。

liabilities of the client委托人的责任

article29  the client shall carry out his dutiesas stated in the contract. the client shallbe liable to the supervisor if a breach of his duty to the supervisor isestablished against the client, and shall pay compensation for the supervisor’sdirect financial loss.

第二十九条 委托人应当履行本合同约定的义务，如有违反则应当承担违约责任，赔偿给监理人造成的直接经济损失。

article30 if the claim made by the client to thesupervisor cannot be justified, the client shall be responsible for any costincurred by the supervisor in relation to the claim.

第三十条 委托人如果向监理人提出赔偿的要求不能成立，则应当补偿由该索赔所引起的监理人的各种费用支出。

commencement, alteration and termination of the contract本合同的开始、变更与终止

article 31 if  the normal services are impeded or delayed bythe client or the contractor so as to incur additional services or increase theduration of the normal services, the supervisor shall timely inform the clientof the circumstances and probable effects. the time for completion of theservices shall be increased accordingly and the supervisor shall be remuneratedfor such additional services.

第三十一条  由于委托人或承包人的原因使正常的监理工作受到阻碍或延误，以致发生了附加工作或延长了正常监理工作的持续时间，则监理人应当将此情况与可能产生的影响及时通知委托人。完成监理业务的时间相应延长，并得到附加工作报酬。

article 32 if circumstances arise which make it legally or physically impossible forthe supervisor to perform in whole or in part the services in accordance withthe contract he shall promptly dispatch a notice to the client. the time forthe completion of the services shall be extended. when the services are resumed,a reasonable period not exceeding 42 days for resumption shall be added and theclient shall pay the supervisor as agreed between them.

第三十二条         如实际情况发生变化，使得监理人由于法律原因或实际原因不能根据本合同全部或部分执行监理业务时，监理人应当立即通知委托人。经委托人认可，该监理业务的完成时间应予延长。当恢复执行监理业务时，应当增加不超过42日的时间用于恢复执行监理业务，并按双方约定的数量支付监理报酬。

article 33 after the supervisorhas finalized the acceptance check or handover procedures with the client, andthe contractor has signed a defect liability agreement with the client, thesupervisor has received all the payments due from the client, this contractshall be deemed to come to an end, except for any clauses referring to theparties’ liabilities, which may be used, according to statute of limitationsstipulated by the law, for claiming compensation. as to liabilities during thedefect liability period, the two parties can make provisions in the conditionsof particular application.

第三十三条  监理人向委托人办理完竣工验收或工程移交手续，承包人和委托人已签订工程保修责任书，监理人收到所有监理报酬，本合同即终止，除了有关双方的责任的条款，其应可按照相关法律的时效期限用以索赔。保修期间的责任，双方在专用条件中约定。

article 34 if either party hereto wishes to alter or abandon thecontract, he shall notify the other party in 42-day advance. if loss is causedto the other party as a result of the abandonment of the contract, theresponsible party shall pay compensation except for circumstance where hisresponsibility can be remitted in accordance with laws.

第三十四条         当事人一方要求变更或解除合同时，应当在42[h3] 日前通知对方，因解除合同使另一方遭受损失的，除依法可以免除责任的外，应由责任方负责赔偿，

article 35 if the supervisor has not received a paying voucher within 30 days fromthe due date of payment and nor has he received any written explanation fromthe client, or the supervision services has been suspended for more than sixmonths, the supervisor can notify the client to terminate the contract. ifwithin 14 days from the date of notice the supervisor still has not receivedany response from the client, he can make further notice. if within 42 daysfrom the date of the second notice the supervisor still has not received anyresponse from the client, the supervisor can terminate the contract or suspendor continue suspending from performing all or part of his services at hisdiscretion. the client shall assume the responsibility for breach of contract.

第三十五条       监理人在应当获得监理报酬之日起30日内仍未收到支付单据，而委托人又未对监理人提出任何书面解释时，或根据第三十三条及三十四条已暂停执行监理业务时限超过六个月的，监理人可向委托人发出终止合同的通知，发出通知后14日内仍未得到委托人答复，可进一步发出终止合同的通知，如果第二份通知发出后42日内仍未得到委托人答复，可终止合同或自行暂停或继续暂停执行全部或部分监理业务。委托人承担违约责任。

article 36 if the supervisionservices are suspended or terminated due to causes not on the part of the supervisor, works required to resume services orpost-termination settlement works shall be deemed as exceptional services. theperformance of exceptional services shall entitle the supervisor to payment forperforming them.

第三十六条       监理人由于非自己的原因而暂停或终止执行监理业务，不可抗力除外，其善后工作以及恢复执行监理业务的工作致使监理工期延长，经委托人认可，应当视为额外工作，有权得到额外的报酬。

article 37 if in the opinion of theclient that the supervisor is not discharging his rights without justifiablereasons, he can inform the supervisor of such opinion. if within 21 days from the date of notice the client has not receivedany response from the supervisor, he can, within 35 days from the date of thefirst notice, inform the supervisor by notice to terminate the contract. thesupervisor shall assume the responsibility for breach of contract.

第三十七条       当委托人认为监理人无正当理由而又未履行监理义务时，可向监理人发出指明其未履行义务的通知。若委托人发出通知后21日内没有收到答复，可在第一个通知发出后35日内发出终止委托监理合同的通知，合同即行终止。监理人承担违约责任。

article 38 termination of the contract shall not prejudice or affectthe accrued rights and liabilities of the parties.

第三十八条       合同协议的终止并不影响各方应有的权利和应当承担的责任。

payment监理报酬

article 39  the remuneration for normal services,additional services and exceptional services shall be calculated in accordancewith article 9 of the conditions of particular application. the client shallpay the supervisor in accordance with the time and amount stated in thecontract.

第三十九条 正常工作、附加工作和额外工作的报酬，按照监理合同专用条件中第九条的方法计算，并按约定的时间和数额支付。

article 40  if the supervisor does not receive payment within the time specified heshall be paid compensation calculated from the last day of the specified payingperiod.

第四十条   如果委托人在规定的支付期限内未支付监理报酬，自规定之日起，还应向监理人支付滞纳金。滞纳金从规定支付期限最后一日起计算。

article 41  the currency, exchange rate applicable to thecontract is that stated in the conditions of particular application.

第四十一条 本合同适用的货币币种、汇率在专用条件中陈述。

article 42  if any item or part of an item in a paymentapplication submitted by the supervisor is contested by the client, the clientshall give notice with reasons within 24urs from receiving the application andshall not delay payment on the remainder of the invoice.

第四十二条 如果委托人对监理人提交的支付通知中报酬或部分报酬项目提出异议，应当在收到支付通知书24内向监理人发出表示异议理由的通知，但委托人不得拖延其他无异议报酬项目的支付。

others其他

article 43 under the consent of theclient, cost necessarily incurred by the supervisor for visits to cities otherthan shanghai on investigation purpose, testing of materials and equipment canbe reimbursed by the client, within the budget scope, as it actually happens.

第四十三条         委托人根据建设工程需要邀请的建设工程监理所必要的监理人员出外考察、材料设备复试，其费用支出经委托人同意的，在预算范围内向委托人实报实销。

article 44  within the scope of supervision services, if expert is needed to beemployed for consulting or assistance purposes, the supervisor shall bear suchcost when the expert is employed by him, the client shall bear such cost whenthe expert is employed by him.

第四十四条       在监理业务范围内，如需聘用专家咨询或协助，由监理人聘用的，其费用由监理人承担；在监理业务范围外由委托人聘用的，其费用由委托人承担。

article 45 if profit is generated forthe client as a result of recommendations made by the supervisor, the clientmay give bonus to the supervisor.

第四十五条       监理人在监理工作过程中提出的合理化建议，使委托人得到了经济效益，委托人在可以给予监理人经济奖励。

article 46 the on-site supervisionteam or its staff shall not accept any remuneration or money provided by thecontractor.

第四十六条       监理人驻地监理机构及其职员不得接受监理工程项目施工承包人的任何报酬或者经济利益。

the supervisor shall not take part inany activity that may have conflict with the interests of the client and withthe work to be performed according to this contract.

监理人不得参与可能与合同规定的与委托人的利益相冲突的任何活动。

article 47  the supervisor shall notdisclose any information that is declared by the client to be confidential. thesupervisor shall not disclose any information provided and declared to be confidentialby the designer or the contractor either.

第四十七条     监理人不得泄露委托人申明的秘密，监理人亦不得泄露设计人、 承包人等提供并申明的秘密。

article48  the supervisorretains copyright of all documents prepared by him.  the client shall be entitled to use them orcopy them only for the project.

第四十八条       监理人对于由其编制的所有文件拥有版权，委托人仅有权为本工程使用或复制此类文件。

settlement ofdisputes争议的解决

article 49  anyclaim for loss or damage arising out of breach or termination of the contractshall be agreed between the client and the supervisor or failing agreement shallbe referred to a governmental department in charge of construction formediation. if agreement still cannot be reached, the dispute shall be referredto the arbitration body agreed by the parties or start a prosecution in thepeople’s court.

第四十九条     因违反或终止合同而引起的对对方损失和损害的赔偿，双方应当协商解决，如未能达成一致，可提交主管部门协调，如仍未能达成一致时，根据双方约定提交仲裁机关仲裁，或向人民法院起诉。

part iii conditions of particular application第三部分 专用条件

article 1 laws applicable to the contract andrules & regulations and reference standard on which the supervision isbased are:

第一条 本合同适用的法律及监理依据的法规和标准：

1.      the construction contract

2.      this supervision contract

3.      the national and shanghai municipal laws,regulations and policies on the construction

4.      complete sets of constructiondrawings and related documents.

5.       current national regulations for constructioncode and the quality inspection, acceptance, and assessment standard/codes

6.      the specifications on theproject

7.      the supervision documents andprocedure on the project

8.      applicable laws and regulations

1、  工程施工承包合同。

2、  本工程施工监理合同。

3、  国家和上海市重庆市有关工程建设方面的法律、法规、政策和规定。

4、  设计图纸和其它有关文件

5、  现行的国家工程建设规范和质量检验评定标准。

6、  为本工程制定的有关技术文件及规定。

7、  为本工程制定的有关监理文件和程序。

8、相关法律法规。

article 2 the scope of supervision

第二条 监理工作内容

tosupervise the construction quality, progress, contract, and project information,to coordinate between the client and the general contractor, and to urge thegeneral contractor to construct in a safety and civilized manner. the detail ofthe supervision service is the follows,

负责本项目的建筑质量、进度、合同、项目信息管理，协调委托人与总承包方的关系，督促并检查施工单位安全文明施工, 监理工作具体有：

1. to assist the client to sign theconstruction contract

1.      协助委托人签订施工承包合同；

2. to assist the client and thecontractor to draw up the construction commencement report

2.      协助委托人与施工单位编写开工报告；

3. to organize the meeting on theconstruction drawing explanation and check

3.      组织设计交底与图纸会审；

4. to review the construction plan,scheme and the master schedule of the contractor

4.      审核承建单位提出的施工组织设计, 施工技术方案和施工进度计划；

5.to supervise the contractor to execute the construction contract and thenational technical and construction code, as well as the documents referred toat article 1 hereof, to deal with the contractor’s violation against theregulation or the code;

5.      对承建单位执行工程承包合同和国家工程技术规范标准，以及第一条所规定的文件的情况进行督促,检查,参与承包方违约事件的处理；

6.tocheck the list of the material and equipment of the contractor’s; to inspectthe raw material, semi-product, and parts which will be used in the project; toreject the disqualified material, parts and equipment against the constructioncontract and standard.

6.      审查承建单位提出的材料和设备清单, 对工程使用的原材料、半成品、构件、设备进行检查,有权拒绝使用不符合合同要求和标准规定的材料,构件,设备；

7.toinspect the construction progress and quality; to inspect and accept thedivisional, sub-divisional and concealed works; to evaluate the constructionprogress

7.      检查工程进度和施工质量,验收分部分项工程和各项隐蔽工程, 对工程进度进行评估。每周书面向委托人报告工程进度，每周组织召开施工例会。

8.toorganize the client, the designer and the contractor to handle the qualityaccident; to supervise the execution of the technical scheme for the qualityaccident; to inspect, accept and issue the certificate after the qualityaccident is settled.

8.      组织委托人、设计、施工单位处理工程质量事故并提供处理方案和责任划分方案, 监督质量事故技术处理方案的实施, 并对事故处理进行验收和签证；

9. to compile the supervisiondocuments and specifications for filing

9.      整理监理文件和技术档案资料；

10. to organize the designer and theconstruction contractor to pre-inspect and pre-accept for the constructioncompletion

10.  组织设计单位和施工单位进行工程竣工初步验收；

11. to assist the client to executethe completion acceptance.

11.  协助委托人进行竣工验收工作;

12. to submit the supervisionevaluation report for the project to the client .

12.  向委托人提交项目监理评估总结报告；

13.   to organize hse site service:safety strategy, site safety supervision, health control, security of site office.

13. 负责提供安全策略，现场安全监督，现场健康控制，以及现场办公室安全。

article 3 external conditionsinclude: the client is responsible for all the public relations andcoordination for the project including the local government and authorities

第三条   外部条件包括：委托人负责本工程建设的所有包括政府等在内的外部关系的协调；

article 4 project informationrequested by the supervisor should be provided by the client, where it isavailable, shall be issued beforehand.

第四条   对于监理人让委托人提供的工程资料，如果有，应事先提供。

article 5 on all matters properly referredto him in writing by the supervisor, the client shall give his decision inwriting within 5 days.

第五条   委托人应在5天内对监理人适当地书面提交并要求其作出决定的事宜作出书面答复。

article 6 the clientsrepresentatives are        。

第六条 委托人的常驻代表为      。

article 7 during the contract period, the client shall at his own cost provide, orarrange for the provision by others, of personnel to work within the client’sown site team.   the supervision teamshall co-operate with the client’s own team but shall not be responsible forthem or their performance or rely on them or their performance for any of theservices for which the supervisor is responsible.

第七条            在合同期间，委托人应自费提供或安排其他方提供人员组成委托人的现场工作组。监理机构应与委托人的现场工作组合作，但不对他们及其行为负责，也不依靠他们及他们的行为来开展监理人负责的工作。

第八条            监理人派驻现场的监理人员数量和人员资质，必须符合双方商定的人员表和分阶段专业人员进场计划表的规定。根据各阶段实际施工需要，监理人有义务根据委托人要求，在人员表人员的范围内调整和增加人员。委托人有权根据专业人员进场计划表进行人员资质检查和出勤考核。如发现有不符资质及缺员情况，将斟情扣发监理人报酬。

article 9 the supervisor agrees topay compensation if he fails to discharge his duties, [accumulated amount ofcompensation shall not exceed the total payment by the client to the supervisor(bar income tax ), except for the compensation specified in article 24 ofstandard conditions.

compensation fee =the direct loss xthe supervision fee’s charge rate (bar income tax). the supervision fee’scharge rate is equal to total supervision fee divided by total cost of theproject.

第九条            内如果失职，同意赔偿损失[累计赔偿额不超过监理报酬总数（扣税），本合同标准条件

第二十四款规定赔偿的情况除外。赔偿金=直接经济损失*报酬比率（扣除税金）报酬比率为监理费和项目总造价的比率。

article 10 the client agrees to pay thesupervisor for his normal services in an amount calculated in the following wayand at the following time:

第十条 委托人同意按以下的计算方法、支付时间与金额，就监理人提供的正常监理工作支付其报酬：

1.the supervision service period: start from the day, on which the supervisioncommencement notice is issued from the client, and the supervision serviceperiod (interim) is eighteen months

监理服务期：按委托人通知监理服务开始日起算，监理服务期（暂定）为18个月。

2. the supervision fee: fixed lumpsum during the above-said supervision service period（18months）is 1,480,000 rmb yuan.

监理服务费：在监理服务期(18个月)内的固定总价为： 148.0万元。

3. payment method:

支付时间与金额

1) the client should pay to the supervisor 15% of the fixed lumpsum within one week as of the signature date of this supervision contract.

1）合同签定日后一周内委托人向监理人支付监理费总价的15%；

2) then, the client shouldpay the supervisor another 15% of the fixed lump sum every two months (90days), and the number of the payment times is three (i.e. 75% of the fixed lumpsum fee).

2）随后,每三个月（90天），委托人向监理人另支付监理费总价的15%，共5次（计为监理费总价的75%）。

4) the client should paythe supervisor final 10% of the fixed lump sum within one week after theproject passes the completion acceptance examination.

4）工程竣工验收合格后一周内委托人向监理人支付最后的监理费总价的10%

4. the service fee beyond the above-said supervision service period:if the supervision service is beyond 18 months, the client will, on the monthlybase, pay the supervisor at the sum of 82,000 rmb yuan/month.

4. 监理服务期延长期的服务费用: 如果监理服务超过18个月，委托人要按工程内容和现场监理工作要求，合理支付费用，延长期监理费用由双方商定。

article 11 the parties hereto agree that the paymentshall be effected in rmb.

第十一条             双方同意用人民币支付报酬。

article 12 bonus clause; depending on mutualconsultation

第十二条             奖励办法：由双方协商解决

article 13 if a dispute arises betweenthe parties in connection with, or arising out of the contract, consultationshall be made promptly to find a solution. when consultation fails, the partiesagree to refer the dispute to an arbitration commission. the arbitration body shall be china international economic and trade arbitration center, shanghai branch.the arbitration language shall be chinese and english..

第十三条 本合同在履行过程中发生争议时，当事人双方应及时协商解决。协商不成时，双方同意由仲裁委员会仲裁。仲裁机构为中国国际经济贸易仲裁委员会上海分会，仲裁语言为中文和英文。

*

由法律部门定

[h2]由法律部门定

[h3]42天太长，由法律部门定

甲方：____________(以下简称“甲方”)

乙方：________________以下简称“乙方”)

甲乙双方遵循自 愿、平等、诚信、互惠的原则，就乙方产品在甲方单位进行 合作经营的具体事宜，达成如下协议：

一、双方合作投放的产品：TTSG-3讲解器

二、双方确定的产品投放地点：____________________________

三、自签订协议后，乙方将所需设备及交与甲方向景 点游客租 用，讲解器所有权属乙方

四、自协议签订后，中英文讲解词由甲方编写，并发 给乙方，乙 方负责免费制作中英文讲解语音，在一年内并可提供四 次的免费语音修改服务，乙方根据甲方需要，也可只制作其 中一种语音。

五、合作模式及结算方式：双方运营期间，由甲方全 权负责宣传、推广、服务等相关工作，乙方不参与经营，只 提供设备。合同期内按租用设备数量每单台每日租金(_____元/ 台)合作天数计算。甲方最底需要租用乙方台设备，最底 合作期限为一年。租金每季度结算一次，由甲方于每季度最 后一天直接汇入乙方帐号。

六、设备的经营、保管等均由甲方负责，乙方负责产品 的维修，如 设备出现故障，甲方应及时返回乙方，乙方另提供按租 用设备6： 1的比例免费提供备用机及耳机，方便故障机及 时更换。备用机乙方不收取租金。设备如有遗失，由甲方承 担，丢失设备甲方按 _______元/台赔偿甲方，乙方于每个季度 末清点机器数量。

七、合作时间：_______ 年 _____月 ____日至_______年____ 月____曰。合 作结束后，乙方有权全部收回投入的讲解器。如双方有 意继续合作(继续合作的形式，仍以本协议规定的主要规则 为核心)或采用其他方式延续合作，双方可另订协议。

八、此协议未尽事宜，双方可协商解决。

九、此协议一式四份，自双方签字盖章后生效，双方各 执二份。

甲方(公章)：________乙方(公章)：________

委托代理人：_______ 委托代理 人：_________

地址：_______________ 地址：___________

电话：______________ 电话： ____________

传真：_____________ 传真：___________

电子 邮箱：_________电子邮箱：____________

________年_____ 月____ 日_______年____ 月____曰

借款合同中文范本

借款单位：_______________

法定代表人：________

贷款单位：_____________

法定代表人：________

保证单位：____________

法定代表人：________

签约日期：________

根据《中华人民共和国民法典》的规定，借款方为保证施工生产正常进行，向贷款方申请建筑企业流动资金贷款，经贷款方审查同意发放，为明确各方权责，特签订本合同共同遵守。

第一条本合同规定____年贷款额为人民币（大写）____万元，用于____.

第二条借款方和贷款方必须共同遵守贷款办法，有关贷款事项按办法规定办理。

第三条贷款自支用之日起，按实际支用数计收利息，利率为月息____‰，超计划贷款的超过部分利率为月息____‰，逾期贷款加计利息20%，挪用贷款挪用部分加罚利息50%.

第四条贷款方保证按照本合同的规定供应资金，贷款方如因工作差错贻误用款，以致借款方遭受损失时，应按直接经济损失，由贷款方负责赔偿。

第五条贷款方有权检查贷款使用情况。检查时，借款方对调阅有关文件、帐册、凭证和报表，查核物资库存和施工生产情况等，必须给予方便。

第六条借款方如违反合同和贷款办法的规定，贷款方有权停止贷款，提前收回部分或全部贷款。

第七条担保方对借款方归还贷款本息承担责任，如果借款方未按期清偿贷款本息时，担保方应在接到贷款方还款通知后一个月内负责归还。

第八条本合同有效期：自____年____月____日起，至____年____月____日为止。

本合同正本一式三份，签章各方各执一份。

借款方：____________（盖章）________代表人____________

贷款方：____________（盖章）________代表人____________

担保方：____________（盖章）________代表人____________

借款合同英文范本