进口医疗器械委托申报合同书
合同编号:京典Y________号
甲方:____________________有限公司(以下简称甲方)
乙方:____________医药科技有限公司(以下简称乙方)
经友好协商,甲乙双方就提供进口医疗器械产品技术服务一事达成以下协议:
一、委托条款
1.甲方委托乙方代理下列进口医疗器械产品的技术服务。
2.甲方负责按医疗器械注册管理办法提供注册资料并附有中文译本。甲方承诺对所提供证明文件的真实性、有效性及合法性负完全的法律责任(具体要求见医疗器械注册管理办法)。
3.乙方负责资料文件送审,并协助甲方对文件资料(包括产品标准)进行整理,并保证在资料文件完整的情况下,自国家食品药品监督管理局医疗器械司受理该产品之日起,在其规定的工作日取得注册证,乙方有义务对甲方资料保密。
4.关于注册时间计划见合同附件。
5.乙方取得注册证书,在确定收到甲方全部应付款项后,应将注册证书及甲方提交的剩余资料退还甲方。
二、支付条款
1.甲方支付乙方上述产品____________注册技术服务费人民币________万元;检测技术服务费用人民币_______万元,标准技术服务费人民币________万元。
2.在合同签订5日内,甲方应该支付乙方80%的代理服务费;当乙方拿到上述产品SFDA的受理通知书后,甲方支付乙方15%的代理服务费;当乙方取得上述产品的注册证后,甲方支付乙方5%的代理服务费。
3.根据《医疗器械注册管理办法》,所有上报至SFDA的注册资料需要提供中文译本。甲方可自行翻译但需对翻译质量负责。如果甲方委托乙方进行资料翻译。乙方收取的翻译费用为人民币200元每千字。乙方保证翻译文档质量符合SFDA关于注册的要求,并承担相应责任。
三、附加的支付条款(国家收费)
1.根据《医疗器械注册管理办法》,国家食品药品监督管理局医疗器械司对每个注册证收取的审查费人民币3000元。甲方按照乙方书面通知,按时将款打入乙方指定的账户中。
2.根据《医疗器械注册管理办法》注册产品需要检测的,甲方应负责样机自发货地点与乙方检测中心的来往运输,并承担自己相应的样机运输和质量检测费用。质量检测费用由国家食品药品监督管理局指定的检测中心收取,甲方应在样机运送至SFDA指定的检测中心5日内支付检测中心质量检测费,由检测中心出具正式发票。
3.在产品SFDA检测过程中,如因甲方做出产品型号增加等重大调整而造成注册时间的延长,责任由甲方承担,所发生的额外费用由甲方承担。
四、注册失败和不可抗力
1.如确因无法抗拒原因(如国家注册法规发生重大变化等)未能取得产品注册证,乙方在扣除基本费用(代理费20%)后,将已收取的注册代理费退还甲方。
2.如甲方发生在送审资料、文件中有弄虚作假行为或产品质量检测不合格等单方面原因造成注册失败或甲方中途提出更换代理(或停止委托项目),乙方有权不退还已收取的代理费。
3.如因乙方在整理注册资料、申报过程中的错误等单方面原因造成注册失败,则需退还已收取的代理费。
五、一般条款
1.本协议不完备之处,甲乙双方可协商签署补充协议。
2.如在协议执行过程中或与本协议有关的一切争议应协商解决,无法协商解决的可提交人民法院进行解决。
3.本协议一式肆份,双方各持贰份,具有同等法律效力。
4.本协议由双方盖章签字后生效。
甲方单位盖章:__________ 乙方单位盖章:__________
甲方代表人签章:________ 乙方代表人签章:________
________年_____月_____日 ________年_____月_____日
更多相似范文
篇1:外贸进口合同范本_合同范本
外贸进口合同范本中英文对照
买方:
The Buyer:
地址:
Address:
电话(Tel):
传真(Fax):
电子邮箱(E-mail):
卖方:
The Seller:
地址:
Address:
电话(Tel):
传真(Fax):
电子邮箱(E-mail):
买卖双方同意按照下列条款签订本合同:
The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below:
1.货物名称、规格和质量(Name, Specifications and Quality of Commodity):
2. 数量(Quantity):
允许________的溢短装(________% more or less allowed)
3. 单价(Unit Price):
4. 总值(Total Amount):
5. 交货条件(Terms of Delivery) FOB/CFR/CIF________
6. 原产地国与制造商 (Country of Origin and Manufacturers):
7. 包装及标准(Packing):
货物应具有防潮、防锈蚀、防震并适合于远洋运输的包装,由于货物包装不良而造成的货物残损、灭失应由卖方负责。卖方应在每个包装箱上用不褪色的颜色标明尺码、包装箱号码、毛重、净重及“此端向上”、“防潮”、“小心轻放”等标记。
The packing of the goods shall be preventive from dampness, rust, moisture, erosion and shock, and shall be suitable for ocean transportation/ multiple transportation. The Seller shall be liable for any damage and loss of the goods attributable to the inadequate or improper packing. The measurement, gross weight, net weight and the cautions such as "Do not stack up side down", "Keep away from moisture", "Handle with care" shall be stenciled on the surface of each package with fadeless pigment.
8. 唛头(Shipping Marks):
9. 装运期限(Time of Shipment):
10. 装运口岸(Port of Loading):
11. 目的口岸(Port of Destination):
12. 保险(Insurance):
由________按发票金额110%投保________险和________附加险。
Insurance shall be covered by the ________ for 110% of the invoice value against _______ Risks and __________ Additional Risks.
13. 付款条件(Terms of Payment):
(1) 信用证方式:买方应在装运期前/合同生效后__日,开出以卖方为受益人的不可撤销的议付信用证,信用证在装船完毕后_____日内到期。
Letter of Credit: The Buyer shall, ______ days prior to the time of shipment /after this Contract comes into effect, open an irrevocable Letter of Credit in favor of the Seller. The Letter of Credit shall expire ____ days after the completion of loading of the shipment as stipulated.
(2) 付款交单:货物发运后,卖方出具以买方为付款人的付款跟单汇票,按即期付款交单(D/P)方式,通过卖方银行及________银行向买方转交单证,换取货物。
Documents against payment: After shipment, the Seller shall draw a sight bill of exchange on the Buyer and deliver the documents through Sellers bank and ______ Bank to the Buyer against payment, i.e D/P. The Buyer shall effect the payment immediately upon the first presentation of the bill(s) of exchange.
(3) 承兑交单:货物发运后,卖方出具以买方为付款人的付款跟单汇票,付款期限为________后____日,按即期承兑交单(D/A__日)方式,通过卖方银行及______银行,经买方承兑后,向买方转交单证,买方在汇票期限到期时支付货款。
Documents against Acceptance: After shipment, the Seller shall draw a sight bill of exchange, payable_____ days after the Buyers delivers the document through Sellers,ank and _________Bank to the Buyer against acceptance (D/A___ days). The Buyer shall make the payment on date of the bill of exchange.
(4) 货到付款:买方在收到货物后__天内将全部货款支付卖方(不适用于 FOB、CRF、CIF术语)。
Cash on delivery (COD): The Buyer shall pay to the Seller total amount within ______ days after the receipt of the goods (This clause is not applied to the Terms of FOB, CFR, CIF).
14. 单据(Documents Required):
卖方应将下列单据提交银行议付/托收:
The Seller shall present the following documents required to the bank for negotiation/collection:
(1) 标明通知收货人/受货代理人的全套清洁的、已装船的、空白抬头、空白背书并注明运费已付/到付的海运/联运/陆运提单。
Full set of clean on board Ocean/Combined Transportation/Land Bills of Lading and blank endorsed marked freight prepaid/ to collect;
(2) 标有合同编号、信用证号(信用证支付条件下)及装运唛头的商业发票一式_____份;
Signed commercial invoice in ______copies indicating Contract No., L/C No. (Terms of L/C) and shipping marks;
(3) 由______出具的装箱或重量单一式___份;
Packing list/weight memo in ______ copies issued by___;
(4) 由_________出具的质量证明书一式___份;
Certificate of Quality in _______ copies issued by______;
(5) 由_________出具的数量证明书一式___份;
Certificate of Quantity in ___ copies issued by______;
(6) 保险单正本一式___份(CIF 交货条件);
Insurance policy/certificate in ___ copies (Terms of CIF);
(7)_________签发的产地证一式___份;
Certificate of Origin in ___ copies issued by______;
(8) 装运通知(Shipping advice): 卖方应在交运后_____ 小时内以特快专递方式邮寄给买方上述第______项单据副本一式一套。
The Seller shall, within ____ hours after shipment effected, send by courier each copy of the above-mentioned documents No. ______.
15. 装运条款(Terms of Shipment):
(1) FOB交货方式
卖方应在合同规定的装运日期前30天,以____方式通知买方合同号、品名、数量、金额、包装件、毛重、尺码及装运港可装日期,以便买方安排租船/订舱。装运船只按期到达装运港后,如卖方不能按时装船,发生的空船费或滞期费由卖方负担。在货物越过船弦并脱离吊钩以前一切费用和风险由卖方负担。
The Seller shall, 30 days before the shipment date specified in the Contract, advise the Buyer by _______ of the Contract No., commodity, quantity, amount, packages, gross weight, measurement, and the date of shipment in order that the Buyer can charter a vessel/book shipping space. In the event of the Sellers failure to effect loading when the vessel arrives duly at the loading port, all expenses including dead freight and/or demurrage charges thus incurred shall be for the Sellers account.
(2) CIF或CFR交货方式
卖方须按时在装运期限内将货物由装运港装船至目的港。在CFR术语下,卖方应在装船前2天以____方式通知买方合同号、品名、发票价值及开船日期,以便买方安排保险。
The Seller shall ship the goods duly within the shipping duration from the port of loading to the port of destination. Under CFR terms, the Seller shall advise the Buyer by _________ of the Contract No., commodity, invoice value and the date of dispatch two days before the shipment for the Buyer to arrange insurance in time.
16. 装运通知(Shipping Advice):
一俟装载完毕,卖方应在______小时内以______方式通知买方合同编号、品名、已发运数量、发票总金额、毛重、船名/车/机号及启程日期等。
The Seller shall, immediately upon the completion of the loading of the goods, advise the Buyer of the Contract No., names of commodity, loading quantity, invoice values, gross weight, name of vessel and shipment date by_________ within________hours.
17. 质量保证(Quality Guarantee):
货物品质规格必须符合本合同及质量保证书之规定,品质保证期为货到目的港__个月内。在保证期限内,因制造厂商在设计制造过程中的缺陷造成的货物损害应由卖方负责赔偿。
The Seller shall guarantee that the commodity must be in conformity with the quatity, specifications and quantity specified in this Contract and Letter of Quality Guarantee. The guarantee period shall be______months after the arrival of the goods at the port of destination, and during the period the Seller shall be responsible for the damage due to the defects in designing and manufacturing of the manufacturer.
18. 检验(Inspection)(以下两项任选一项):
(1)卖方须在装运前______日委托_________检验机构对本合同之货物进行检验并出具检验证书,货到目的港后,由买方委托____________检验机构进行检验。
The Seller shall have the goods inspected by ______ days before the shipment and have the Inspection Certificate issued by____. The Buyer may have the goods reinspected by ________ after the goods,rrival at the destination.
(2) 发货前,制造厂应对货物的质量、规格、性能和数量/重量作精密全面 的检验,出具检验证明书,并说明检验的技术数据和结论。货到目的港后,买方将申请中国商品检验局(以下简称商检局)对货物的规格和数量/重量进行检验,如发现货物残损或规格、数量与合同规定不符,除保险公司或轮船公司的责任外,买方得在货物到达目的港后__日内凭商检局出具的检验证书向卖方索赔或拒收该货。在保证期内,如货物由于设计或制造上的缺陷而发生损坏或品质和性能与合同规定不符时,买方将委托中国商检局进行检验。
The manufacturers shall, before delivery, make a precise and comprehensive inspection of the goods with regard to its quality, specifications, performance and quantity/weight, and issue inspection certificates certifying the technical data and conclusion of the inspection. After arrival of the goods at the port of destination, the Buyer shall apply to China Commodity Inspection Bureau (hereinafter referred to as CCIB) for a further inspection as to the specifications and quantity/weight of the goods. If damages of the goods are found, or the specifications and/or quantity are not in conformity with the stipulations in this Contract, except when the responsibilities lies with Insurance Company or Shipping Company, the Buyer shall, within _____ days after arrival of the goods at the port of destination, claim against the Seller, or reject the goods according to the inspection certificate issued by CCIB. In case of damage of the goods incurred due to the design or manufacture defects and/or in case the quality and performance are not in conformity with the Contract, the Buyer shall, during the guarantee period, request CCIB to make a survey.
19. 索赔(Claim):
买方凭其委托的检验机构出具的检验证明书向卖方提出索赔(包括换货),由此引起的全部费用应由卖方负担。若卖方收到上述索赔后______天未予答复,则认为卖方已接受买方索赔。
The buyer shall make a claim against the Seller (including replacement of the goods) by the further inspection certificate and all the expenses incurred therefrom shall be borne by the Seller. The claims mentioned above shall be regarded as being accepted if the Seller fail to reply within ______days after the Seller received the Buyers claim.
20. 迟交货与罚款(Late delivery and Penalty):
除合同第21条不可抗力原因外,如卖方不能按合同规定的时间交货,买方应同意在卖方支付罚款的条件下延期交货。罚款可由议付银行在议付货款时扣除,罚款率按每__天收__%,不足__天时以__天计算。但罚款不得超过迟交 货物总价的____ %。如卖方延期交货超过合同规定__天时,买方有权撤销合同,此时,卖方仍应不迟延地按上述规定向买方支付罚款。
买方有权对因此遭受的其它损失向卖方提出索赔。
Should the Seller fail to make delivery on time as stipulated in the Contract, with the exception of Force Majeure causes specified in Clause 21 of this Contract, the Buyer shall agree to postpone the delivery on the condition that the Seller agree to pay a penalty which shall be deducted by the paying bank from the payment under negotiation. The rate of penalty is charged at______% for every ______ days, odd days less than _____days should be counted as ______ days. But the penalty, however, shall not exceed_______% of the total value of the goods involved in the delayed delivery. In case the Seller fail to make delivery ______ days later than the time of shipment stipulated in the Contract, the Buyer shall have the right to cancel the Contract and the Seller, in spite of the cancellation, shall nevertheless pay the aforesaid penalty to the Buyer without delay.
The buyer shall have the right to lodge a claim against the Seller for the losses sustained if any.
21. 不可抗力(Force Majeure):
凡在制造或装船运输过程中,因不可抗力致使卖方不能或推迟交货时,卖方不负责任。在发生上述情况时,卖方应立即通知买方,并在__天内,给买方特快专递一份由当地民间商会签发的事故证明书。在此情况下,卖方仍有责任采取一切必要措施加快交货。如事故延续__天以上,买方有权撤销合同。
The Seller shall not be responsible for the delay of shipment or non-delivery of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The Seller shall advise the Buyer immediately of the occurrence mentioned above and within_____ days thereafter the Seller shall send a notice by courier to the Buyer for their acceptance of a certificate of the accident issued by the local chamber of commerce under whose jurisdiction the accident occurs as evidence thereof. Under such circumstances the Seller, however, are still under the obligation to take all necessary measures to hasten the delivery of the goods. In case the accident lasts for more than _____ days the Buyer shall have the right to cancel the Contract.
22. 争议的解决 (Arbitration):
凡因本合同引起的或与本合同有关的任何争议应协商解决。若协商不成,应提交中国国际经济贸易仲裁委员会深圳分会,按照申请时该会当时施行的仲裁规则进行仲裁。仲裁裁决是终局的,对双方均有约束力。
Any dispute arising from or in connection with the Contract shall be settled through friendly negotiation. In case no settlement is reached, the dispute shall be submitted to China International Economic and Trade Arbitration Commission (CIETAC),Shenzhen Commission, for arbitration in accordance with its rules in effect at the time of applying for arbitration. The arbitral award is final and binding upon both parties.
23. 通知(Notices):
所有通知用______文写成,并按照如下地址用传真/电子邮件/快件送达给各方。如果地址有变更,一方应在变更后______日内书面通知另一方。
All notice shall be written in _____ and served to both parties by fax/courier according to the following addresses. If any changes of the addresses occur, one party shall inform the other party of the change of address within ____days after the change.
24.本合同使用的FOB、CFR、CIF术语系根据国际商会《2019年国际贸易术语解释通则》。
The terms FOB、CFR、CIF in the Contract are based on INCOTERMS 2019 of the International Chamber of Commerce.
25. 附加条款 (Additional clause):
本合同上述条款与本附加条款抵触时,以本附加条款为准。
Conflicts between Contract clause hereabove and this additional clause, if any, it is subject to this additional clause.
26. 本合同用中英文两种文字写成,两种文字具有同等效力。本合同共__份,自双方代表签字(盖章)之日起生效。
This Contract is executed in two counterparts each in Chinese and English, each of which shall deemed equally authentic. This Contract is in ______ copies, effective since being signed/sealed by both parties.
买方代表(签字):________________________
Representative of the Buyer
(Authorized signature):___________________
卖方代表(签字):_________________________
Representative of the Seller
(Authorized signature):______________
签订日期(Date):____________________
签订地点(Signed at):____________________
篇2:外贸出口合同样本[页13]_合同范本
2.3 付款:代理行应立即以电传或电报向各行通知付款日。各行应在付款日____ 时间上午____ 时,按照本合同规定的条件,向代理行提供与该贷款承诺相等的资金金额,其方式或通过____ 银行间清算系统结算的资金,或按照代理行其时决定的,为在____ 市用国际银行交易惯用的以美元结算的其他资金,存入其在____ 帐号为____ -____ 的帐户,或通知各行已经因此指定的其他帐户,代理行应按照本合同规定的条件,在付款日将所收资金贷记入借款人根据第2.2条指定的帐户。
第三条 还款
3.1 还款:除本合同另有明文规定外,借款人分____ 个半年期偿还贷款。每期的数额相等于贷款的____ 分之一,但头____ 期每期均应进位到1美元的完整倍数,最后一期为全部清偿尚未偿还的贷款余额所必要的数额,每期贷款应在自第____ 个付息日开始的连续付息日支付。
3.2 自愿提前还款:借款人得在付息日以____ 万美元的完整倍数全部或部分提前还款。如果不迟于借款人愿意提前还款之日前15个银行工作日____ 时间下午5时,借款人应向代理行发出有关上述日期和提前还款数额的不可撤销的通知。所定数额连同到付息日利息应在该日对各行按对其提前偿还数额0.5%支付。部分提前还款应按在贷款中的比例分摊,并按第3.1条规定的分期,按倒序偿还。提前偿还的数额不得根据本合同重新借用。
3.3 非法行为:如果任何银行在任何时间确定,任何法律、条款或条约或其中的任何变动,或其解释或适用的任何变动,使银行进行贷款或继续贷款或索取或收受任何应付数额的行为不合法时,该银行应将上述决定通知借款人,如果在上述贷款支付之后发送,则借款人应在紧接着通知日之后的付息日提前偿还全部贷款;或者,如果该银行确定,在付息日之前需要提前偿还贷款,则根据该银行的要求,应连同支付该贷款提前偿还之日应付的利息,以及借款人应付给该行的所有其他金额。
第四条 利息
4.1 基本利率:
(1)除第4.2条或4.3条另有明确规定外,每笔贷款在第一利息期应付利息,自利息期的第一天起(包括第一天在内),到该利息期最后一天,(不包括最后一天在内),年利相当于该利息期利差加____ 银行同业拆放利率的金额。
(2)除本合同另有明确规定外,贷款的应付利息应在每一付息日支付。
(3)代理行应在每次决定____ 银行同业拆放率后,立即通知借款人和各行。
4.2 延迟支付的利息:如果借款人应付的任何金额到期未付,上述金额在利息期内的利息应在适用的法律所允许的范围内支付,自支付日(包括该日在内)到上述金额支付日(不包括该日在内),年利数额相当于该利息期内每天(1)利差,(2)1%,以及(3)下述的最高额:(a)代理行在____ 银行同业市场上述金额美元存款的当日报价(以年率表示);(b)利息期内到期日为付息日的________银行同业拆放率(或者,如果到期日不是付息日,则为该利息日所在利息期内);(c)在该到期日(如果该到期日是利息期的首日)开始的利息期的________银行同业拆放率。
4.3 替代利率:如果代理行在与各行进行实际可行的协商之后,在任何时候确定(1)不可能确定下一利息期的________银行同业拆放率,或(2)该利息期内的________银行同业拆放率不能充分地反映利息期内多数贷款权银行在________银行同业市场获得的美元存款的费用,代理行应立即将这一决定通知借款人和各行,如果通知是在支付贷款之前发出,则银行在本合同项下的贷款义务应在通知发出之日终止。如果通知是在支付贷款之后发出,则每家银行应尽快将利率通知借款人,该利率由上述银行按给该行提供该利息期贷款的有效费用加1%(以年率表示)确定。银行贷款利息应在利息期内,以该行的通知所规定的利率计息。按照该行的请求,借款人应签署并提交为充分有效地实施本款规定所需的单据,包括但不限于为交换该行持有的票据而应由该行签署并交付的新票据。
共16页,当前第13页12345678910111213141516
篇3:技术转让和设备材料进口合同
中国_________产品进出口公司和_________产品生产厂(以下简称)与_________国_________公司(以下简投资人)和_________国_________有限公司(以下简称
第三方)签订本合同,其条款如下:
(1)为在_________生产投资人的甲型和乙型产品而引进必需的技术。这些产品以下简称为产品。
(2)投资人应要求按本合同提供其拥有的制造产品所需的技术和资料。
(3)产品的名称规格详见附件一。
(4)投资人应向提供制造产品所需的贸易秘密、制造技术和专有技术方面的资料。
(5)投资人向提供的资料详见附件二。
第二条 设备规划
(1)必须按照投资人的建议准备产品生产设施。
(2)为了帮助在_________准备生产设施,投资人应提供援助,包括供应下列资料: a.生产线计划。 b.生产劳动力安排计划。 c.设备布局计划。 d.基础设施计划,如水电供应、空调、运输、通讯等。 e.设备安装操作计划。 f.生产管理计划。 .推销计划。 上述资料应于本合同生效后_________天内由投资人提供。
(3)生产线必须按照附于本合同的生产细目表,即附件三。
(4)应自行准备生产计划,但必要时可要求投资人给予合作。
第三条 许可费的支付
(1)投资人向转让技术的许可费如下: a.向投资人购买产品生产权应交入门费_________元。 b.每件出售的产品应向投资人交付售价_________%的提成费。
(2)一切付款应按照本合同及本条款的有关约定事项办理。
(3)一切付款应通过中国XX办理。
(4)支付方式采用不可撤销的即期信用证,用美元支付。
(5)应在本合同生效后_________天内,开立不可撤销的信用证向投资人支付入门费。
(6)投资人应在收到上述信用证后_________天内提供合同规定的一切技术资料。
(7)每次向投资人订购合同规定的材料时,应在信用证的金额中加上_________%的提成费;也可在支付货款时,为提成费另开一份信用证。
(8)负责在中国发生的一切费用;投资人负责在国外发生的一切费用。
第四条 销售
(1)投资人应帮助兴趣办展销会、研讨会、广告宣传等,以推销生产的产品。但费用应由负担。
(2)在开展广告宣传等活动中,如有需要可以使用投资人的广告标识。但投资人既不参与盈亏,也不对此承担责任。
第五条 质量控制
(1)在_________制造产品的质量必须按照投资人的质量控制标准进行鉴定。
(2)_________制造产品的质量检验,在开始阶段应由双方工程是由联合进行,其细节详见附件四。
(3)_________制造产品的质量检验必要时应进行两次。如果
第二次检验未能达到规格指标而且原因又是在投资人方面,则投资人应自费解决存在的问题。
(4)如果品质检验合格,双方工程是由应签署品质检验证明书一式_________份,每方各执_________份。
第六条 设备交货
(1)应向投资人购买生产产品所需的设备。
(2)生产产品所需设备的品名、规格详见附件五。
(3)投资人购买设备的价格细节由双方商定,并另签设备购买合同。
(4)投资人运交的设备应该是新型的、未用过的。
(5)投资人向运交设备的价款应以不可撤销的即期信用证按cf中国口岸条件用美元支付。
(6)投资人应按本合同的交货计划表运交设备。
(7)投资人应按合同的规定,向提供与设备有关的技术资料。
(8)设备正式交货日期为提单的日期。投资人应将提单号码、装船日期、装箱单、抵达日期等及时通知。同时,投资人还应将上述资料单据副本寄给。
(9)合同规定的设备和技术资料如有遗失,得要求投资人补交。
(10)投资人运交设备应使用坚固的包装,能以经受长途运输。 (1
1)投资人的装箱单应写明: a.合同号码;b.收货人姓名;c.目的港;d.装船唛头;e.重量;f.箱号;.收货人标记。 (1
2)投资人应将装货内容清单的副本放入包装内。
第七条 接收设备
(1)应准备设施和场地以接收和保管投资人运来的设备。
(2)投资人应在提出对运到的设备进行安装和试车的要求后三周内派出工程师。应为此事向投资人提供翻译之类的必要帮助。
(3)投资人的工程师应为安装试车任务停留两周。
(4)运交设备的验收工作,应由双方工程师和中国检验官员一起进行,详细规则见附件六。
(5)如果初次检验不合格,应进行
第二次检验。如果
第二次检验仍不合格,则投资人应在_________个月内自费调换有关设备。但是应该认识和接受这一点,即换货所需的时间长短要看所换的设备而定。
(6)如果检验合格,双方应签署检验证明书一式_________份,每方各执_________份。
(7)投资人派行往安装调试的工程师的居留费用均由投资人负担。
第八条 设备操作和保养的培训
(1)投资人在派遣工程到安装调试设备时,应兴举办关于设备操作和保养的培训。应为此事对投资人提供诸如翻译之类的帮助。
(2)培训的时间,包括前款所讲的安装调试在内不得超过_________天。
(3)培训主要用英文进行,也用_________作为辅助语言。如有需要应自费准备翻译员。
(4)在进行设备操作保养培训的工程师的居留费用均由投资人负担。
第九条 对运交设备的保证
(1)按照国际习惯标准,运交设备的保证期为8个月,从完成验收工作起算。
(2)如果在保证期内发现运交的设备有缺点,投资人必须按要求,及时适当解决。
(3)在上述情况下,该缺点经鉴定是由操作经验不足、搬运不当或某一物品的消耗所致,则投资人应要求支付实际运输费用。
(4)投资人应向提供与运交设备有关的最大限度的服务。
(5)保证期以后的设备保养需要向收取费用。但投资人应努力提供最大的合作和收取最低的费用。
第十条 物资的采购
(1)应按本合同的规定向投资人采购生产产品所需的材料。
(2)投资人应按本合同的规定向运交所需的材料。
(3)投资人应力求以尽可能低的价格供应这些材料。
(4)采购材料的实际详细品名,另以购买合同规定。
(5)投资人应该供应的材料,并保证质量。
(6)应提前_________个月向投资人送交月度生产计划和月度材料采购数量,以便材料的交货能以得到保证。
(7)投资人应尽力按照交货计划运交采购的材料;但是,应当理解和接受这样的事实,即由于市场供求不平衡等不能预见和不可避免的原因会使投资人无法按计划交货。
(8)对投资人运交材料的付款,必须采用不可撤销的信用证,以美元支付。
第十一条 材料的出口方法
(1)材料正式交货日期为提单的日期。投资人应将提单号码、装船日期、装箱单、抵达日期等及时通知。同时,投资人还应将上述资料单据副本寄给。
(2)投资人运交材料如有任何遗失或缺点,应由投资人自费办妥。
(3)投资人运交材料应使用坚固的包装,能以经受长途运输。
(4)投资人的装箱单应写明: a.合同号;b.收货人姓名;c.目的港;d.装船唛头;e.重量;f.箱号;.收货人标记。
(5)投资人应将装货内容清单的副本放入包装内。
第十二条 接收材料
(1)应准备设施和场地以接收和保管投资人运交的材料。
(2)投资人应在材料经过品质检验之后发运。
(3)必须对运交的材料验收,如有缺陷或遗失,应及时通知投资人。如果投资人承认通知合理,应自费换货。但是,应当认识和接受这一点,即换货需要一段合理的时间。
(4)在上述情况下,该缺点经鉴定是由于错误操作所致,投资人应要求支付一切实际费用。
(5)如果运交材料的坏遗失是由于存放或搬运不当所致,投资人应在收到通知后及时换货;但是,有关费用应由负担。
第十三条 培训工程师
(1)投资人应接待_________名,并提供_________个月的技术培训。
(2)投资人对为此在_________国居留期间供给膳宿,但中_________之间的来回旅费除外。
(3)派出受训的应懂得实用的英语,具有电子工程学的基础知识。
(4)教学主要用英语进行,但以_________为辅助语言。投资人应按要求准备一名译员,费用由负担。
(5)投资人应立即编写教育计划并提前通知。有关技术教育计划项目详见附件七。
(6)
第三方应同时派遣一名工程师去照料上述培训事宜。
第十四条 派遣投资人的工程师
(1)投资人应两次派遣多名工程师去,
第一次派_________名去_________个月,以实施这项转让计划。
第二次派_________名去_________个月,以达到产品生产指标。
(2)投资人派往工程师主要用英语进行工作,但也以汉语为辅助语方。必要时应自费准备一名翻译员。
(3)应负担投资人的工程师为此而在中国国内居留和旅行的各种费用,但中之间的旅费除外。
(4)在投资人派遣工程师的任务完成以后,如有必要仍可要求投资人继续给予技术支持。但投资人应要求为这样增加的合作支付费用。合作的条款由双方将来讨论约定。
(5)要求投资人技术服务的细节,见附件八。
第十五条 将来的技术合作
(1)投资人应为将来的发展与进行合作,包括高分辩能力显示等在内。
(2)上述技术合的条款,包括它的费用,应由、投资人、
第三方三方面商定并另签合同。
第十六条
第三方的作用
(1)
第三方负责和投资人之间的信息传递、交往媒介等,并对提供必要的援助。
(2)
第三方应为此适当向收取报酬。
第十七条
第三方的责任
(1)
第三方应作为与投资人之间的桥梁。
(2)
第三方应协助用展销会、研讨会、技术培训等办法在中国销售产品。
(3)
第三方应在产品品质合格时考虑把这些产品销往欧洲和非洲(南除外)。
(4)
第三方应在派遣工程师到欧洲进行产品开发时,向他们提供使用的设施和工具。但应负担他们在欧洲的一切费用。
第十八条 仲裁
(1)和投资人应以合作的态度解决合同争端。如解决不成,则以仲裁方式最终解决。
(2)仲裁应在_________进行。
(3)和投资人都应受最终裁决的约束。
(4)仲裁费由败诉方负担。
(5)本合同如有某些问题仍在仲裁之中应该分开予以执行。
第十九条 税款 在合同有效期间,中国的税款由负责;欧洲的税款由投资人和
第三方负责。
第二十条 合同的生效
(1)不可预见的问题不应影响本合同的执行。
(2)、投资人、
第三方三方应向各自的政府申请允许有关商品的进口和出口。最后一方获知得批准之日即为本合同生效之日。三方应尽最大努力争取在_________天内取得批准。
第二十一条 合同的撤销
(1)如果在合同生效后_________个月没有见到效果,三方保留撤销本合同的权利。
(2)本合同从生效之日起有效________年,期满后可以延长________年。
第二十二条 使用的文字 本合同用中文和英文写成,两种文本具有同等效力。
第二十三条 合同附件
(1)如要修改合同,有关三方面应同意签订正式修改文件成为本合同的一部分。
(2)所有附件均属有效,并应成为本合同的一部分。(盖章):_________ 投资人(盖章):_________ 代表人(签字):_________ 代表人(签字):_________ ________年____月____日 ________年____月____日
第三方(盖章):_________ 代表人(签字):_________ ________年____月____日
返
篇4:英文求职信常用语句:起头_外贸信函_网
1. Shall you need an experienced desk clerk for your hotel next summer? 贵酒店明年暑期是否需要一名有经验的柜台部职员? 2. Because I am very desirous of receiving actual experience in accounting during July and August, I am writing to inquire whether you will need the services of a young man with three years of educational training and some part-time experience. Perhaps I could fill in for one of your office staff during the vacation period. 因我渴望在七、八月间获得会计实务经验,特备函问询你处是否需雇用受过三年训练略有经验的年轻人?在假期中我或可添补贵公司空缺。 3. Gentlemen: Attention of Personnel Manager I am looking for a postion asassistant shipping clerk. 人事部经理勋鉴:本人正在谋求一份助理船务职员的工作。 4. Perhaps there is a position in your organization for an young, experienced, and conscientious secretary stenographer. 请问贵公司是否需要一名年青、有经验、负责的女秘书兼速记员? 5. I want a job. Not any job with any company, but a particular job with your company. Here are my reasons. Your organization is more than just a busienss house. It is an institution in the minds of the local public. It has a reputation for fair play and honesty with both employees and customers alike. For the past four years, while specializing in accounting at colege, I have had a secret ambition to work for your organization in the accounting department. I graduate in June. As I write this letter, I do not know that there is an opening at persent, but here are my qualifications which prompt me to make application now. 本人需要一份工作,不是任何公司的任何工作,而是贵公司的一个职位。贵公司不只是商店,而是大众都知晓的机构。以公正、证实的美誉远近驰名。在大学主修会计四年来,内心早就想到贵公司会计部工作,今年七月即将毕业。写此信时,不知贵公司目前是否有空缺,但是下列的资历促使本人冒昧提出申请。 6. As it is nearing the Christmas season, it occurs to me that you many need additional assistance in selling gifts in your shop. I have a whole week before Christmas, from December 18-24, when I might assist you. I could aslo work evenings from six oclock on, before December 18. 圣诞节将届,想到贵公司可能需要销售礼物的助理,本人在圣诞节前一周(十二月十八日至二十四日)有空,可以帮忙。十八日以前每晚六时后也可以。 7. Gentlemen: Attention of Personnel Manager Like many other young men, I am looking for a position. I want to get stated, at the bottom, perhaps, but started. 人事部主任:本人和很多年青人一样正在寻找工作。本人想要有个开头,从基层做起。 来源:中青网
篇5:中国进出口银行出口卖方信贷借款协议书
(合同号:( )进出银(信合)字第_____号)于_____年____月____日由下述双方签订 借款人:_______________(以下称“借款人”)
法定代表人:______________________________
地址:____________________________________
邮编:____________________________________
电话:____________________________________
基本开户行:______________________________
账号:____________________________________ 贷款人:□中国进出口银行
□中国进出口银行________分行
□中国进出口银行总行营业部
(以下称“贷款人”)
法定代表人:羊子林
地址:____________________________________
邮编:____________________________________
电话:____________________________________
传真:____________________________________ □“借款人”为实施________项目(以下称“项目”)签订________合同(合同号:________)(以下称“项目合同”),向“贷款人”申请出口卖方信贷。经审查,“贷款人”同意根据本合同的条款和条件发放贷款。为明确双方的权利和义务,根据《中华人民共和国民法典》等有关法律、法规的规定,经双方协商一致,特签订本合同。
□“借款人”为实施________项目(以下称“项目”)签订________合同(合同号:________)(以下称“项目合同”),向“贷款人”申请出口卖方信贷。经中国进出口银行总行批准和授权,“贷款人”同意按照本合同的条款和条件发放贷款,签署并履行本合同。为明确双方的权利和义务,根据《中华人民共和国民法典》等有关法律、法规的规定,双方经协商一致,特签订本
合同。 第一章 贷款金额、用途及期限 第一条 “贷款人”同意按照本合同的约定向“借款人”提供出口卖方信贷项目贷款□¥________人民币((大写)_____________万元人民币)□$________美元((大写)______________万美元)(以下称“贷款”)。 第二条 按照中国人民银行有关金融政策和《中国进出口银行出日卖方信贷试行办法》的规定,本合同项下的“贷款”应专项用于“项目合同”项下的资金需要。未经“贷款人”事先书面同意,“借款人”不得变更本合同项下“贷款”用途。 第三条 本合同贷款期限为______个月,自提款计划约定的首次提款日起,到______年_____月_____日止(以下称“贷款期限”) 第四条 借款人应按本合同约定的提款计划提取本合同项下的“贷款”。
提款计划如下:
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
特殊约定:______________________________
_______________ 第二章 贷款利率和利息计收 第五条 按照中国人民银行的规定,本合同所执行的人民币“贷款”利率,每满一年确定一次。本合同第一年度的年利率为百分之________(________%)。从首次提款日起,每满一年后执行的年利率,应根据届时中国人民银行规定的同档次的贷款利率执行。
本合同美元“贷款”利率按《中国进出口银行外汇贷款利率、费用暂行规定》执行,按________个月浮动,本合同第一计息期的利率为百分之________(________%)。以后每个计息期执行的利率,由“贷款人”书面通知“借款人”。 第六条 “贷款人”按季计收人民币“贷款”利息。“借款人”应在“贷款人”处开立“贷款”账户,并在每季度末月 日以前将利息付至“贷款人”指定的账户。如“借款人”未能按期支付利息,“贷款人”对“贷款期限”内未按期支付的利息部分按本合同规定的利率按季计收复利;“贷款”逾期后改按中国人民银行规定的罚息利率计收复利。
“贷款人”按季计收美元“贷款”利息,如“借款人”未能按期支付利息,“贷款人”将按《中国进出口银行外汇贷款利率、费用暂行规定》计收罚息。 第七条 本合同规定的利息从“借款人”实际提款日起算,按实际提款额和用款天数计算,计算基数为一年360天。 第三章 贷款的提取 第八条 本合同的担保合同生效后,“借款人”才能申请提取本合同项下的“贷款”。 第九条 “借款人”提取本“贷款”,应事先向“贷款人”提交按照附二格式确定的提款通知书及贷款人要求的有关文件、材料,经“贷款人”审查同意后,向“借款人”发放“贷款”。 第十条 “借款人”在本合同项下,第一笔“贷款”的提取期限为6个月(自提款计划确定的首次提款日起算)。若在上述期限内没有提款,“贷款人”有权取消本合同所有“贷款”直至终止合同。 第十一条 第一笔提款以后各笔“贷款”的提取期限为3个月(自提款计划确定的相应提款日起算),若在此期间内,“借款人”未办理提款手续,“贷款人”有权取消该笔“贷款”直至全部未用“贷款”。 第十二条 未经“贷款人”同意,提款计划不得更改。 第四章 借款人的声明与承诺 第十三条 “借款人”向“贷款人”声明如下
(一)“借款人”是一家依法成立并有效存续的企业法人,具有独立的法人地位。
(二)“借款人”具有完全
资格和权利签署本合同和履行本合同项下的义务。
(三)“借款人”已仔细阅读本合同并完全理解和接受本合同的内容。“借款人”签署和履行本合同是自愿的,全部意思表示真实
(四)“借款人”签署本合同,履行其在本合同项下的义务并不违反其订立的任何其他协议或其公司章程。
(五)“借款人”为签署本合同所需的公司授权均已完成,本合同由“借款人”的有效授权代表签署。本合同对“借款人”具有法律约束力。
(六)“借款人”为本合同项下的“贷款”而向“贷款人”提供的所有文件、资料、报表和凭证等都是真实、完整、准确和有效的
(七)“借款人”未隐瞒下列任何事件:
1.“借款人”发生重大违纪、违法或被索赔事件或发生了与“借款人”有牵连的重大违纪、违法或被索赔事件;
2.“借款人”在与其他债权人的合同项下发生重大违约事件;
3.“借款人”承担的重大债务、或有债务或向第三人提供的抵押、质押担保;
4.与“借款人”有关的未结案的诉讼、仲裁事件;
5.“借款人”分立、合并、兼并、被兼并、重组、组建或改建为股份制公司,以租赁、承包、联营、托管等方式进行产权交易;
6.其他可能影响“借款人”财务状况和偿债能力的情况。 第十四条 “借款人”向“贷款人”承诺并保证,“借款人”应完成下列事项:
(一)“借款人”应按“贷款人”的要求每季向“贷款人”提供最新财务报表,每年 月底之前提供经审计的上年度财务报表;“借款人”应按“贷款人”要求随时提供有关(包括但不限于)“借款人”的经营状况、财务状况之报告、报表等文件和资料,并对其真实性、准确性和有效性负责。
(二)在“贷款期限”内,“借款人”应在每季度向“贷款人”报送一次本合同项下“贷款”的使用、“项目”的执行和“项目合同”项下的收结汇情况以及其他有关材料。
(三)“借款人”应接受“贷款人”的信贷检查与监督,并给予充分的协助和配合。
(四)“借款人”应在“贷款人”指定的银行开立专用于上述“项目合同”资金收付的专门账户,该账户中的资金应专款专用。
(五)在本合同项下“贷款”本金、利息及其他应付款项全部清偿前,“借款人”有以下任何减少注册资本、重大产权变动和经营方式调整的行为,均应事先征得“贷款人”的书面同意,包括但不限
于:
1.与外商、港澳台商签订合资、合作协议;
2.关闭、停产、转产、分立、合并、兼并、被兼并;
3.重组、组建或改建为股份制公司;
4.以房屋、机器设备等固定资产或商标、专利、专有技术、土地使用权等无形资产入股或投资于股份公司或有限责任公司;
5.以租赁、承包、联营、托管等方式进行产权交易。
(六)未经“贷款人”同意,“借款人”不得向任何人提供债务保证、抵押、质押或其他形式的担保。
(七)在法定期限内或“贷款人”要求的期限内,“借款人”应及时办理与“项目”有关的登记手续,并向“贷款人”提供登记文件复印件。
(八)“借款人”在本合同项下的有关结算业务应在“贷款人”指定的银行办理。
(九)“借款人”应根据“贷款人”的要求将与本合同或“项目合同”有关的文件正本(包括本票、承兑汇票等)存放在“贷款人”指定的银行处。
(十)如有“借款人”未按期偿还本合同项下的“贷款”本金。利息或其他应付款项的任何情形,则“借款人”不得以任何形式向其股东分配股息或红利。
(十一)一旦发生或可能发生本合同项下第九章中所述的任一违约事件,“借款人”应在得知该事件发生或可能发生之时 日内立即通知“贷款人”,并对所发生的违约事件采取合理、及时的补救措施。 第五章 代理行的参与 第十五条 为了保证本合同项下“贷款”的专款专用和按期偿还,“贷款人”委托_____________银行作为其在本合同项下的代理行(以下称“代理行”)。“贷款人”另与“借款人”和“代理行”签定委托代理协议(以下称“委托代理协议”,协议号:( )进出银(信代)字第________号)。经“贷款人”总行授权,“贷款人”另与“借款人”和“代理行”签定委托代理协议(以下称“委托代理协议”,协议号:( )进出银(信代)字第________号)。
“借款人”除应遵守和履行其在本合同项下的义务外,还应受“委托代理协议”的约束。如“委托代理协议”与本合同有任何不符,以本合同为准。 第十六条 “贷款人”将委托“代理行”负责本合同项下“贷款”的拨付、监督“贷款”的使用和“项目合同”的执行,以及将“借款人”的出口结汇资金及时划付至专门账户,用于偿还“贷款人”的“贷款”。 第六章 贷款的偿还 第十七条 “借款人”应在本合同规
定的“贷款期限”内严格按还款计划偿还本合同项下的“贷款”本金,还款计划如下
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元
_________年_______月_______日 __________________万元 第十八条 除本合同第十九条第二款所规定的情况外,“借款人”如提前还款,应提前________日向“贷款人”提出书面申请,并征得“贷款人”的同意。 第十九条 对于任何提前偿还的部分,“借款人”不得要求再次提用。“借款人”应确保“项目合同”项下的收结汇应专项用于偿还本合同项下的“贷款”。
“借款人”如提前收回“项目合同”项下的货款,应提前归还本合同项下的“贷款”。 第二十条 如“借款人”申请“贷款”展期,应在“贷款”到期日之前两个月内向“贷款人”提交书面展期申请和有关材料(包括但不限于担保人同意该“贷款”展期的证明文件)。经“贷款人”审查后,如“贷款人”批准“贷款”展期,“借款人”应与“贷款人”另行签定“贷款”展期协议。 第二十一条 “借款人”在还款时应按“贷款人”要求填写汇款单据的有关内容(包括但不限于注明本合
同的合同编号)。 第七章 担保 第二十二条 本合同项下的全部“贷款”采用如下担保方式
由________提供连带责任还款保证,并另行签订《保证合同》,编号为______________。
由________提供抵押担保,并另行签订《抵押合同》,编号为______________。
由________提供质押担保,并另行签订《质押合同》,编号为______________。 第八章 保险 第二十三条 “借款人”应将本“贷款”项下有关的设备、建设工程、出口货物货物运输以及“项目”运营期间的风险在“贷款人”认可的保险公司投保,投保险种应符合贷款人的要求,并且“借款人”应将或安排将保险权益转让给“贷款人”。在本合同项下“贷款”本金、利息和其他应付款项偿清之前,“借款人”不得以任何理由中断保险。如“借款人”中断保险,“贷款人”有权续保或代为投保,费用全部由“借款人”承担。 第二十四条 “借款人”应在知道或应当知道保险事故发生之日起 日内以书面形式通知“贷款人”,并根据保险单的有关规定及时向承保人索赔。由于没有及时通知或及时索赔或未履行保险单项下义务给“贷款人”造成的损失由“借款人”承担。 第二十五条 保险赔款应首先用于偿还本合同项下的“贷款”本息及其他应付费用,但“贷款人”可视“项目”情况决定保险赔款是否可以继续用于“贷款”支持的“项目”或贸易;保险赔款不足以支付所欠“贷款”本息不构成对“借款人”应偿付债务的免除。 第九章 违约事件与处理 第二十六条 以下任一事件,均构成本合同项下的违约事件
(一)“借款人”未按本合同规定按期支付利息或归还本金。
(一)“借款人”未按本合同规定的用途使用“贷款”。
(三)“借款人”未按本合同约定的时间、数额提取“贷款”。
(四)“借款人”违反了“委托代理合同”中约定的对“借款人”的有关规定。
(五)“借款人”在本合同项下作出的声明或担保人在有关担保合同项下作出的声明被证明是不真实的,或是具有误导性的。
(六)“借款人”或担保人违反了在本合同或有关担保合同中作出的承诺或保证。
(七)“借款人”自筹资金未及时到位。
(八)“项目”建设进度严重滞后。
(九)“项目”产品质量被认定为不符合“项目合同”规定的标准。
(十)“借款人”在其为一方的其他合同项下严重违约。
(十一)“借款人”或担保人经营、财务状况严重恶化。
(十二)与本合同项下“贷款”有关的抵押物或质物贬值、毁损或灭失。
(十三)“借款人”或担保人被合并、分立或进行股份制改造时,未能做出令“贷款人”满意的偿还安排或债务重组。
(十四)“借款人”或担保人破产。被解散、关闭或撤销。
(十五)“借款人”未将以下情况及时通知“贷款人”:
1.其“项目合同”的重大变更;
2.其章程的任何修改及其经营活动的任何实质性变化;
3.其会计原则的重大修改;
4.其及其主要子公司的财务、经济和其他方面的任何重大变化(包括但不限于涉及“借款人”的,且在“贷款人”看来可能对“借款人”履行其在本合同项下,义务能力造成严重不利影响的任何诉讼、仲裁或行政程序)。
(十六)“借款人”违反了本合同的任何其他条款。 第二十七条 上述违约事件是否发生,由“贷款人”作出判断并通知“借款人”。上述任何违约事件发生后,“贷款人”有权采取以下任何一项或多项措施
(一)要求“借款人”限期纠正;
(二)取消“借款人”尚未提取的“贷款”额度;
(三)宣布所有已发放的“货款”立即到期,并要求“借款人”立即偿还全部已发放“贷款”的本金、利息或其他应付费用;
(四)要求“借款人”追加或更换保证人、抵押物、质物;
(五)从“借款人”在“代理行”或其他银行境内外的分支机构开立的任何币种的任何账户中直接扣划本合同项下“借款人”应付而未付的任何款项(包括但不限于“贷款”本金和利息);
(六)宣布实施或实现有关“贷款”的任何担保项下的权利。 第二十八条 针对“借款人”违反本合同约定,包括但不限于上述第二十六条中的第1和2项,除“贷款人”在上述第二十七条项下的权利外,“贷款人”有权进一步行使下列权利:
(一)对所有逾期金额按中国人民银行公布的逾期罚息利率计收罚息。
篇6:中国深圳对外贸易货物进口合同[页3]_合同范本
_________% more or less in quantity and value allowed.
2、terms: _________(□fob□ cfr□cif□ ddu□_________)
3、country of origin and manufacturers :_________
4、packing:_________
5、shipping marks:_________
6、delivery port :_________
7、destination:_________
8、tran shipment:□allowed□not allowed;partial shipments: □allowed □not allowed
9、shipment date:_________
10、insurance:to be covered by the_________for 110% of the invoice value covering_________additional
11、terms of payment:_________
the buyers shall open a letter of credit at _________ sight through _________ bank in favour of the sellers prior to _________.
documents against payment:(d/p)the buyers shall duly make the payment against documentary draft made out to the buyers at _________sight by the sellers.
documents against acceptance:(d/p)the buyers shall duly make the payment against documentary draft made out to the buyers at _________ sight by the sellers.
cash on delivery (cod):the buyers shall pay to the sellers total amount within _________ days after the receipt of the goods .(this clause is not applied to the terms of fob,cfr,cif).
12、documents :the sellers shall present the following documents required to the banks for negotiation/collection.
(1)shipping bills :
in case by sea : full set of clean on board ocean bills of lading / combined transportation bills of lading made out to order blank endorsed / endorsed in favour of _________ or made out to order of _________ ,marked "freight prepaid / collected " notifying _________ at the port of destination.
in case by land transportation: full set of clean on board land transportation bills made out to _________ marked "freight prepaid / collected " notifying _________ at the destination.
in case by air : full set of clean on board awb made out to _________marked "freight prepaid/collected"notifying at _________the destination .
(2)singed commercial invoice in _________ copied indicating contract no, l/c no. and shipping marks.
(3)packing list / weight memo in_________copies issued by_________.
(4)certificate of quality in_________copies issued by_________.
(5)certificate of quantity in _________copies issued by_________.
(6)insurance policy / certificate in_________copies .
(7)certificate of origin in _________ copies issued by_________.
(8)hipping advice:_________
in addition , the sellers shall, within _________ hours after shipment effected , send each copy of the above-mentioned documents no. _________directly to the buyers by courier service.
共5页,当前第3页12345
篇7:广西壮族自治区机械进出口公司诉中国铁路对外服务上海公司_合同范本
上海市高级人民法院经审理查明:中铁上海公司系经国家主管部门批准成立的国际货运代理企业,其与华远船务公司订有协议,双方合作经营西伯利亚大陆桥的铁路集装箱运输和整车货运输,华远船务公司提供全程运输提单,承担全程经营人的责任。中铁上海公司负责签发提单,办理中国段的运输。
1992年9月17日,广西机械公司通过福州进出口公司上海办事处向中铁上海公司填写一份出口货运委托书,委托书注明发货人广西机械公司,收货人一栏为收货人的姓名、护照号码、电话号码。运输方式铁路列车。委托人要求出三份提单开送到指定地点。运费预付,上海至满洲里7951.20元人民币,满洲里至莫斯科2250美元。广西机械公司货物交付后,中铁上海公司在经营人为华远船务公司的苏联大陆桥运输提单上签章,并收取了全程运费,提单正面填写的内容与委托书基本相同,另有华远船务公司在莫斯科联系人的详细地址。
1992年11月10日,上海铁路桃浦站制作的国际货协运单上记明发货人为华远船务公司,收货人与委托书填写相同。根据《国际铁路货物联运协定》规定:国际货协运单关于地址的记载,不得没有收货人的名称及其通信地址;货物发生交付阻碍时应由发货人在限期内提出处理意见,未收到发货人的任何可行的指示,则货物应按发生阻碍铁路的现行国内规章处理;如果货物已经变卖,卖得的款项扣除必要费用后交付发货人。
上海市高级人民法院认为:上诉人广西机械公司通过福州进出口公司上海办事处提出的出口货运委托,因有被上诉人中铁上海公司代表全程经营人被上诉人华远船务公司签发提单而成立。华远船务公司是注册在香港的从事国际货运业务的企业,其通过境内代理人办理部分货运手续,与我国现行工商法规并不抵触。中铁上海公司是合法成立的国际货运代理企业,在本案中代表全程经营人缮制运输单证符合经营范围,且代理过程中并无错误,不应承担责任。上诉人关于华远船务公司违法经营,中铁上海公司双重代理的上诉理由不足,不予采信。上诉人交付货物后,从全程经营人手中获取正本提单,可据此主张权利。华远船务公司通过中铁上海公司向铁路承运企业办理国际联运手续,与其依据提单承担全程经营责任相符,上诉人据以认为华远船务公司向铁路企业办理托运侵犯其财产所有权的理由不足。华远船务公司出具提单后又以自己名义将货物交铁路企业承运,依据有关规定可以享受一定权利。华远船务公司未提供货物在到达站被处理的有效证据,应对提单持有人承担法律责任。本案系国际铁路联运纠纷,华远船务公司依据海运提单的背面条款,主张对上诉人(即发货人)承担限额赔偿责任,不符合公平的民事原则。一审法院依此适用法律失当,应予纠正。上诉人要求被上诉人(即承运人)赔偿其全部货物损失的上诉理由予以支持,但因其在办理委托运输手续时未详细写明收货人的通信地址,有一定的过错,有关货损利息的请求,不予支持。依照《中华人民共和国民法通则》第四条,《中华人民共和国民事诉讼法》第一百五十三条第一款第(二)项规定,于1996年4月30日判决如下:
一、撤销原审判决第一项。
二、华远船务公司在本判决生效后十日内赔偿广西机械公司货物损失9万美元,保险费损失792美元,运费损失2250美元和7951.20元人民币。
三、维持原审判决第二项。
宣判后,双方当事人服从判决。
「评析」
本案的国际铁路货物运输关系由两个环节组成:第一,广西机械公司通过福州进出口公司上海办事处向代表全程经营人华远船务公司的中铁上海公司办理托运;第二,华远船务公司经由中铁上海公司向铁路企业再办理国际联运货物的托运。这两个托运环节因承运人不同,出具运输单据不同,形成既有区别又有联系的两个运输法律关系:广西机械公司依据提单与华远船务公司设定了欧亚大陆桥国际铁路联运的契约承托关系;华远船务公司则依据运单与中俄铁路企业设定国际铁路联运实际的运输关系。华远船务公司是联结两个运输法律关系的中间链,起着承上启下的作用。广西机械公司持有svb的正本提单,欲主张托运人的权利,只能向中铁上海公司和华远船务公司提出。作为全程经营人的华远船务公司,既不依据运单向中俄铁路企业行使承运货物灭失索赔权,又提供不出货物去向的证据,对托运人的货损理应承担赔偿责任。而中铁上海公司的法律地位,则应根据它在本案运输过程中的具体作用以及与华远船务公司签订的协议来确认。从案件的事实看,广西机械公司经由福州进出口公司上海办事处向中铁上海公司办理托运手续时确有一份“出口货运委托书”。该委托书虽然是中铁上海公司的格式合同,但其中具体托运要求均是货主提出,需要填写的栏目内并未约定中铁上海公司履行代理义务,只能视为运输合同的意向书,不能视为是货主与其代理人之间的货运代理合同。中铁上海公司先代表华远船务公司接受广西机械公司提出的货运委托,后代表华远船务公司签发承运提单,最后代表华远船务公司向实际承运人铁路桃浦站办理出口货运手续,按照双边协议,中铁上海公司应是全程契约承运人即全程经营人的代理人。广西机械公司称中铁上海公司双重代理,与华远船务公司对其实施共同侵权,缺乏事实依据。
篇8:外贸年度工作总结
转眼之间,我们依依惜别了20x年,满怀热情的迎来了充满希望的20x年。在这年终之际,现对来公司一年时间里所作的工作汇报如下:
一.完成了100P圆筒、100P彩虹、60P共91个集装箱的出口到美国,14个托盘的100P彩虹出口到日本,10个托盘的60P和100彩虹到中国台湾,及2400套圆筒和600套60P(REPLACEMENT)到美国。
主要负责
1.签订合同后,催客户开信用证,并与收到后审核,有问题并通知及时修改。
2.按制定的出货计划及相关要求与货贷联系租船订舱。
3.与客户确认相关得出货资料后,整理单据,办理木托熏蒸。并准备熏蒸证书。
4.协调好生产部门,按客户不同的包装要求,安排拖车发货。
5.核算出相关的出口数据,制作单据,委托办理出口报关。
6.根据信用证要求,制作并准备相应的出口单据,去银行办理交单议付,有时办押汇。
7.登记相关的出口资料,并按客户要求,每周提供装箱图片、箱封号、船名航次等资料。
8.将资料整理归档,并随时与银行核对每笔货款得到帐情况。并将每月的出口资料提供给财务。
此项工作繁琐且重复率高(自七月份起,几乎每周重复一次),占去了近80%的精力。
期间因工作时间短,经验不足,也犯过不少错误:
1.拖车订晚了,害同事及工人加班装集装箱。
2.与车间及其他部门配合、协调不够好。打件时缠绕膜的包装方式出现错误,检查工作没做好。
3.车间加班不及时,常被叔叔点名。
通过这段时间的努力,使我个人的耐心、细心程度及对工作的合理安排得到了锻炼,
学会了在繁忙之中找条理,危难之中找希望。
二.与客户进行日常的邮件联系。
主要负责与韩国BESTSELECTION
公司联系关于此出口美国货物的细节内容,一般通过邮件来回确认。包括三种货物的包装、结算、出货期、产品质量、木托干湿度、法兰克福展位、新样品及相关产品的变动等等内容,其中大部分是协助王总来完成。
期间曾因业务经验少有过失误:在事情紧急、误解了韩国意思的情况下,与美国客户直接联系。结果给客户造成误解,给王总带来麻烦。
通过这项工作,使我原本欠缺的英语写作及口语得到了很大的提高,并学到了好多与客户交流的技巧及业务上的知识。但离一个成功国际贸易业务员的标准还差得很远,在今后工作中,定会多多注意,加以改善。
三.新产品的开发,为客户备样。
将王总与客户的谈判结果(有时旁听并记录)及产品要求、变化等内容传达给采购及生产部门,并负责监督并随时向领导汇报工作进度。按双方协商及客户要求,准备样品并负责发到美国或韩国。按不同要求,为客户提供图片、报价等,通过邮件反复确认。协助销售为B.S.
整理库存样品并报价;给B.S.准备从日本带回的新样品;给MORRIS准备美国展会样品并报价等。
通过对此业务的接触,使我对公司的产品有了更好地了解,但距离还差得很远。这对于业务员来讲是一大缺陷,希望公司以后有时间能定期为新员工组织学习和培训,以便于工作起来更顺手。
四.与韩国HAN KOOK SHARP订遥控铅芯;催GOODFELA生产并尽快发货;订EMICRO的细太空,并与收到货后,对于出现的质量问题进行邮件联系。由于出口美国货物的任务加重,后来都转给小毕负责。
五.处理日常工作,服从公司领导安排。
联系法兰克福展位的装修及邀请函的办理;为领导办理迁证准备资料;与车队、熏蒸、货贷、报关行、快递等搞好关系并与之定期结算费用;服从领导日常安排的各项工作;协助行政部制定部门职责;联系复印机维修,电脑维护等等日常工作。
总体说来,对于领导交给的各项任务都已比较顺利、较好的完成了。
展望20x年,我会更加努力、认真负责的去对待每一个业务,也力争赢的机会去寻求更多的客户,争取更多的订单,完善进出口部门的工作。相信自己会完成新的任务,能迎接新的挑战。
篇9:外贸工作计划
一、工作目标
1、充分利用一切资源,有计划、有安排地度过每一天;
2、对于刚入行的新人虽没有老顾客的资源及工作经验,但要对工作尽职尽责,迅速反应,热情,友善的对待每一个客户;
3、提高英语及业务能力水平,快速进入工作,不浪费公司注册的平台及各项资源;
二、具体内容
阶段一:熟悉产品及报价
阶段二:
①免费B2B平台,加大注册平台数量,详细记录注册的每个平台,注重每天对产品的展示及更新;
②学习同行业其他公司的产品介绍及网页展示情况;
③通过email、skype、国外期刊等方式主动开发客户;
④注册收费网站:网页制作、维护、美工、产品简洁、精美的展示及介绍、快速准确回复顾客的在线提问;
⑤联系国内外贸公司,拓大客户信息量的来源;
阶段三:回盘
A、免费网站:传递公司信息,加大对公司的宣传
B、国内收费网站:
1、保证全天在线,快速、准确回复客户的问题;
2、估计晚上上网购物人较多,因此,保证晚上至少10点前在线回复客人;
3、对于犹豫不决的客户,主动打电话咨询。比如:客户是谁、地点、家装还是工装、采购标准、数量,然后,让客户将其采购产品类型、数量、尺寸写清楚并对其进行报价。
C、国外收费网站:
1、开发信
Dear
How are you
This is trade manager from *CO.,LTD.
Our company,which is set up in ,is a professional furniture supplier for hotel,club,villa,
apartment,custom-made and integrates furniture design,product,sale and service into a whole.
To know more about our company and view our newest products,welcome to visit our website Looking forword to your soonest reply and wish we can have friendly win-win cooperation in the future.
Thank you
2、回复国外客户
①咨询
a.项目名称 what’s project name? b.所在地 where c.采购标准 what kind of purchasing standard? d.工程进度 How about the project progress? e.房间数目 how many rooms do you have? f.你是谁 who are you?
②是否请设计公司为其设计,是否有施工图、效果图及喜欢的风格
Do you have own designer?
Would you like to give me CAD drawings or design sketches?And what kind of style woud you like?
③如果没有或者不满意,给出公司图册和资质文件,让客户从图册内选择
Pls check the attachment with our catalogue and quality document.
You can choose favorite furnitures from the catalogue,then tell me the page number.We will make at least two plans for u to REF.
④全面沟通过后,最后做出公司报价(对于不爱回答的客户,直接让自己盲目的配方案,适当的选择放弃)
⑤如果客户有效果图,什么都没说,直接让做报价,是先询问在报价,还是报价的同时询问情况
⑥确定付款方式
FOB T/T 30%deposite 70% before shipping
阶段四:确定生产:
阶段五:各类单证的制备
篇10:空运出口运输合同模板_合同范本
甲方:_________________
地址:_________________
电话:_________________
乙方:_________________
地址:_________________
电话:_________________
经过平等、友好协商,甲、乙双方就空运货物出口运输事宜,于_________年_________月_________日签订如下协议:
一、委托事项
甲方接受乙方委托,承接乙方委托的空运出口运输业务。乙方指定甲方作为其代理人,代为安排提货、办理出口报关和出口商品检验检疫等事务。
二、乙方应在每票货物出运之前五个工作日以书面形式(包括信函、传真、电报、电传)向甲方提交《出口运输委托书》(简称委托书或托单)。
委托书应包括但不限于以下内容:
1.托运人(shipper)名称、姓名、地址、联系方式;
2.收货人(consignee)名称、姓名、地址、联系方式;
3.通知方名称、姓名、地址、联系方式;
4.航班号、日期、始发港、目的港;
5.货物品名、件数、重量、体积、声明价值;
6.运费及其它费用的标准和支付方式;
7.托运人的签名、盖章、日期。
乙方提交的委托书没有签名盖章或乏上述部分或全部内容的,乙方应按照甲方要求进行补正,否则甲方有权拒绝接受委托。
三、乙方委托甲方代为办理货物出口报关和出口商品检验检疫等事务的,应及时向甲方提供办理上述事务所需的文件和单证。乙方应对其提供的文件和单证的真实性、合法性和完整性负责。
四、乙方在向甲方发出委托后要求撤销或变更委托事项、委托内容的,应采用书面形式并得到甲方的认可,乙方应补偿甲方由此付出的额外费用。
五、接收货物
如果甲方在收货时发现乙方的货物表面状况(包括外包装)不良,甲方有权拒绝接收货物。如果乙方不能在甲方要求的时间内对货物及其包装进行改良,甲方有权停止为乙方出运货物。由于甲方原因未能在乙方指定时间内将货物按排出港,乙方有权向甲方提出损失索赔。
六、对货物的要求
乙方不应在其托运的货物中夹带禁止运输、限制运输物品和危险物品。有关对禁止运输、限制运输物品和危险物品的规定以国际公约、相关国家法律法规规章、行业协会等的明文规定为准。如乙方谎报货物品名,夹带上述物品,乙方应对由此而造成的甲方的全部损失承担赔偿责任。
七、乙方应向甲方支付与货物运输有关的所有运杂费用。乙方应在货物起飞后30天内将相应款项支付给甲方。
八、本协议有关的任何事务,适用中华人民共和国法律、法规及相关国际公约的规定。
九、协议的修改和补充
对本协议的修改和补充应采用书面形式,并得到双方的书面确认。修改和补充从双方书面确认之日起生效。
十、本协议自双方盖章之日起生效。本协议的有效期至_________年_________月_________日止。
十一、本协议以传真形式签订确认,同具法律效力。
十二、签约地:_________________________。
甲方(盖章):_________
代表(签字):_________
_________年____月____日
乙方(盖章):_________
代表(签字):_________
_________年____月____日
篇11:皮革进料加工制品出口代理协议书_合同范本
甲方:_________
乙方:_________
甲乙双方经友好协商,就甲方委托乙方代理皮革进料加工,皮革制品出口业务达成如下协议:
一、甲方委托乙方代理皮革进料加工,皮革制品出口至_________业务,乙方接受甲方委托。
二、合同标的:_________
产品名称:_________
数量:_________
合同金额:_________
拟出运日期:_________
出运港:_________
到货港:_________
外方付款结算方式:_________
三、双方责任及义务:
(一)甲方职责:
1.负责与外商签订所有出口合同,并对合同的全部内容负责;
2.负责安排生产、出运、交货;
3.负责向乙方提供工厂开具的增值税发票、纳税缴款书及运费等正式发票;
4.承担业务的全部费用及风险,保证按合同条款(合同标的)的全部内容执行,并向乙方支付出口代理手续费(乙方收汇)。
(二)乙方职责:
1.负责按甲方提供的合同内容对外签订出口合同;
2.提供出口货物商检、报关、出运和结汇等工作所需的单据;
3.负责出口结汇;
4.结汇后一周内,将货款转付甲方帐户。
四、违约责任:
如因任何一方未履行本协议规定的责任而给对方造成的经济损失,由违约方承担。
五、甲方出具的担保函是本协议不可分割的一部分。
六、本协议一式两份,双方各执一份。自签字之日起生效,具有同等法律效力。
甲方(盖章):_________ 乙方(盖章):_________
代表(签字):_________ 代表(签字):_________
_________年____月____日 _________年____月____日
篇12:技术出口合同范本_合同范本
Contract for Equipment Sales and Technology Licensing
Contract No. ____________________
This Contract (hereinafter referred to as the “Contract”) is made and entered into as of ________ (the date of signature ) in ________ (the place of signature) through friendly negotiation by and between _____________, a company incorporated and existing under the laws of ____________ with its registered address at _________________________________, and with its principal place of business at _________________________________ (hereinafter referred to as the “Buyer”), and ____________________, a company incorporated and existing under the laws of the People’s Republic of China with its registered address at _________________________________, and with its principal place of business at _________________________________(hereinafter referred to as the “Seller”).
Whereas, the Buyer desires to engage the Seller to provide the Equipment, related design, Technical Documentation, Technical Service and Technical Training and to obtain from the Seller a license of Patent and/or Know-how in relation to the Erection, Test Run, Commissioning, Performance Test,operation and maintenance for the Equipment, as well as manufacture of the Contract Products. Now it is hereby mutually agreed as follows:
Article 1 Definitions
1.1 “Acceptance ”means the Buyer accepted the Equipment in accordance with Article 11.5.
1.2 “Commissioning” means the operation of the Equipment in accordance with Article 11.4 for the purpose of carrying out Performance Test.
1.3 “Contract” means this Contract signed by and between the Buyer and the Seller, including Appendices attached which shall form an integral part of this Contract.
1.4 “Contract Products” refers to all types of the products manufactured with Patent and/or Know-how under the Contract, details of which are specified in Appendix 1.
1.5 “Destination Airport” refers to _____________Airport.
1.6 “Effective Date of the Contract” means the date when the Contract enters into force upon fulfillment of all the conditions stated in Article 18.1.
1.7 “Equipment” means the equipment, machinery, instruments, spare parts and materials supplied by the Seller as listed in Appendix 3.
1.8 “Erection” means placing the Equipment to the positions according to the design drawings, and connecting it with relevant equipment and utilities.
1.9 “Improvement” refers to new findings and/or modifications made in the validity period of the Contract by either party on Patent and/or Know-how in the form of new designs, formulas, recipes, ingredients, indices, parameters, calculations, or any other indicators.
1.10 “Job Site” means the site where the Equipment shall be located and/or erected, namely ____.
1.11 “Know-how” refers to any valuable technical knowledge, data, indices, drawings, designs and other technical information, concerning the Erection, Test Run, Commissioning, Performance Test,operation and maintenance for the Equipment as well as manufacture of the Contract Products, developed and owned or legally acquired and possessed by the Seller and disclosed to the Buyer by the Seller, which is unknown to either public or the Buyer before the Date of Effectiveness of this Contract, and for which appropriate protection measures have been taken by the Seller for keeping Know-how in secrecy. The specific description of Know-how is set forth in Appendix 3.
1.12 “Last Shipment” means the shipment with which the accumulated invoice value of shipped goods has reached ____ ( ) percent of the total Equipment price.
1.13 “Patent” refers to any and all of the effective patent rights possessed by the Seller and licensed to the Buyer under the Contract in connection with the Erection, Test Run, Commissioning, Performance Test,operation and maintenance for the Equipment, as well as manufacture of the Contract Products, the No. and list of which are set forth in Appendix 3.
1.14 “Performance Test” means the tests for examining whether the Equipment is able to meet guarantee figures specified in Appendix 1.
1.15 “Technical Documentation” means the technical indices and data, specifications, drawings, processes, technical and quality standards, and other documents carrying the descriptions and explanations of Patent, Know-how and other technical information, in connection with the Erection, Test Run, Commissioning, Performance Test,operation and maintenance for the Equipment, as well as manufacture of the Contract Products, to be provided by the Seller as listed in Appendix 4.
1.16 “Technical Service” means the technical instruction, assistance and guidance rendered by the Seller as per Appendix 6.
1.17 “Technical Training ” means the training rendered by the Seller as per Appendix 7.
1.18 “Test Run” means the initial run of a single machine or the whole system of the Equipment without materials.
1.19 “Warranty Period” means the period of the warranty given by the Seller as specified in Article 12.2, during which the Seller is responsible for the defects of the Equipment as per Article 12.
Article 2 Scope of the Contract
2.1 The Seller’s Obligation
2.1.1 The Seller shall supply the Equipment, provide the design, Technical Documentation, and conduct the Technical Service and Technical Training, and grant the Buyer a right to use the Patent and/or Know-how as set forth in the Contract.
2.1.2 The Seller shall supply the Equipment which is listed in Appendix 3, the specification is detailed in Appendix 1.
2.1.3 The Seller shall provide design in accordance with Appendix 5, and submit to the Buyer the Technical Documentation listed in Appendix 4.
2.1.4 The Seller shall conduct the Technical Services at the Job Site as per Appendix 6.
2.1.5 The Seller shall conduct the Technical Training as per Appendix 7.
2.2 The Buyer’s Obligation
2.2.1 The Buyer shall at his own costs and expenses, provide the Seller with all information and data concerning the design as per Appendix 2. The Buyer shall ensure the completeness, correctness and accuracy of all such information and data.
2.2.2 The Buyer shall at his own costs and expenses, obtain all necessary import permits, undertake customs clearance, take delivery of the Equipment to be supplied by the Seller and transport them to the Job Site in time.
2.2.3 The Buyer shall at his own costs and expenses, perform all the civil works, construction, Erection, Test Run, Commissioning and Performance Test in accordance with the Technical Documentation under the Technical Services rendered by the Seller as per Appendix 6.
2.2.4 The Buyer shall at his own costs and expenses, supply all the equipments, spare parts and facilities required, except for the Equipment supplied by the Seller as per Appendix 3.
2.2.5 The Buyer shall at his own costs and expenses, provide the qualified and appropriate technical personnel, labor, tools, utilities and the Job Site in time for Erection, Test Run, Commissioning, and Performance Test as specified in Appendix 2.
2.2.6 The Buyer shall at his own costs and expenses, perform necessary administration and security guard at the Job Site.
Article 3 Grant of License
3.1 The Seller agrees to grant to the Buyer and the Buyer agrees to obtain from the Seller a license to manufacture the Contract Products as well as to conduct Erection, Test Run, Commissioning, Performance Test, operation and maintenance for the Equipment with Patent and/or Know-how as well as to use and sell the Contract Products. The name, model, specification, and technical data of the Contract Products are detailed in Appendix 1. The Buyer shall not make use of Patent and/or Know-how for any purposes other than those stipulated in the Contract without prior written approval from the Seller. The annual output of the Contract Products manufactured by the Buyer shall in no case exceed _______________.
3.2 (Option 1) The license granted under the Contract shall be an exclusive license. The Seller shall not retain its right to grant the licenses to any third parties, or to explore Patent and/or Know-how as well as to sell the Contract Products by itself within the territory specified in Article 3.4.
(Option 2) The license granted under the Contract shall be a non-exclusive license. The Seller shall retain its right to grant the licenses to any third parties, and to explore Patent and/or Know-how as well as to sell the Contract Products by itself within the territory specified in Article 3.4.
3.3 The license granted under the Contract shall be a non-transferable and non-sublicensing license, under which the Buyer shall neither be entitled to transfer nor grant sub-license to any third party without prior written approval from the Seller.
3.4 Territory
3.4.1 The Seller agrees to grant the license to the Buyer only within the territory of _________________ (country or region). The Buyer shall not explore Patent and/or Know-how in any place other than the Job Site without previous written consent of the Seller.
3.4.2 The Seller agrees to grant a license to the Buyer to use and sell the Contract Products only within the territory of ________________________ (Country or region). In case the Buyer fails to perform its obligations under this Clause, all the actual losses and damages thus incurred to the Seller shall be borne by the Buyer, and the Seller shall have the right to terminate the Contract without prejudice to any remedies specified in the Contract.
Article 4 Price
4.1 The Buyer agrees to pay the total Contract price, Technical Training and Technical Service fee to the Seller.
4.2 The total Contract price, including price of the Equipment, design, Technical Documentation and a license fee in a fixed amount, shall be __________(say _______________________ only).
The breakdown price is as follows:
The price for Equipment is __________(say _______________________ only).
Fee for design is __________(say _______________________ only).
Fee for Technical Documentations is __________(say _______________________ only).
License fee is __________________(Say: _________________ only)
4.2.1 The total Contract price for the Equipment is for delivery CIF_____ Port, and the Technical Documentations is for delivery CIP (by air) ______ Airport. CIF and CIP term shall be interpreted in accordance with INCOTERMS 2019, issued by the INTERNATIONAL CHAMBER OF COMMERCE (ICC).
4.2.2 The total Contract price includes the price for spare parts listed in Appendix 3. However, the total Contract price does not cover the supply of any other spare parts. At the Buyer’s request, the Seller may provide with any other spare parts. A separate agreement shall be signed between the parties.
4.2.3 The above price is fixed and firm.
4.3 The total Contract price does not cover the Technical Service fee and Technical Training fee specified in Appendix 6,7.
4.4 The total Contract price as well as the Technical Training and Technical Service fee shall not be regarded or in any way be explained or interpreted as covering any of the custom duties, taxes, or charges, fees, and expenses unless expressly listed in the Contract.
Article 5 Payment
5.1 Down Payment
Within ____ ( ) days after signing the Contract, the Buyer shall pay ____ ( ) percent of the total Contract price amounting ____ by T/T to the Seller.
5.2 [Option One: Payment by Sight L/C]
The balance of the total Contract price amounting ___ ( says ___ only ) shall be paid by an irrevocable Letter of Credit at sight, issued within ___ ( ) days after signing the Contract by a reputable bank in ___ acceptable to the Seller in favor of the Seller. The Letter of Credit shall be available upon the presentation of the following documents till ______(specific expiration date or a specific circumstance for the expiration of the Letter of Credit).
5.2.1 ____ ( ) percent of the total Contract price amounting ____ (say ___ only) shall be paid by the Buyer to the Seller within _______ days after the following documents have been submitted by the Seller:
(a) Bill of Lading in one (1) original and ___ ( ) copies;
(b) Commercial Invoice in one (1) original and ___ ( ) copies;
(c) Packing list in one (1) original and ___ ( ) copies;
(d) Certificate of Origin in one (1) original and ___ ( ) copies;
(e) Insurance Policy in one (1) original and ___ ( ) copies;
5.2.2 ____ ( ) percent of the total Contract price amounting ____ (say ___ only) shall be paid by the Buyer to the Seller within _______ days after the following documents have been submitted by the Seller:
(a) One (1) copy of the Acceptance Certificate signed by the Buyer as per Article 11.5, or the Seller’s written statement specifying the lapse of more than seven (7) days after the Seller’s notice requesting the Buyer to issue the Acceptance Certificate in accordance with Article 11.5;
(b)One ( 1 ) copy of commercial invoice.
5.2.3 ____ ( ) percent of the total Contract price amounting ____ (say ___ only) shall be paid by the Buyer to the Seller within _______ days after the following documents have been submitted by the Seller:
a) One (1) original Letter of Retention Guarantee in the form of Appendix 10;
b) One (1) copy of Commercial Invoice.
5.2 [Option Two: Payment under a L/G]
The balance of the total Contract price amounting ___ (say ___ only ), plus interest for deferred payment in the amount of ___ (say ___ only ), totaling ___ (say ___ only ) as detailed in Appendix 12 shall be paid by the Buyer by installments as specified in Appendix 12 and backed by an irrevocable Letter of Guarantee in favor of the Seller as per the Appendix 11, issued within ___ ( ) days after signing the Contract by the reputable bank in ____ acceptable to the Seller.
5.3 All the banking charges incurred in the Seller’s bank shall be borne by the Seller while those incurred outside the Seller’s bank shall be borne by the Buyer.
Article 6 Delivery of Equipment and Technical Documentation
6.1 The Delivery of the Equipment
6.1.1 The delivery of the Equipment listed in Appendix 3 shall be completed within ____ ( ) months from the Effective Date of the Contract.
6.1.2 Within ____ ( ) months after the Effective Date of the Contract, the Seller shall send to the Buyer a preliminary delivery schedule by fax.
Not later than ____ ( ) days before the first shipment, the Seller shall submit to the Buyer the final delivery schedule in three (3) copies indicating Contract number, dispatch number, name of the Equipment, quantity, approximate dimensions, volume of each package and time of each shipment.
6.1.3 The port of shipment is ____, while the port of destination is ____.
6.1.4 Advance shipment, partial shipment and transshipment are allowed, however, the Seller shall inform the Buyer thirty (30) days before such shipment.
6.1.5 The date of Bill of Lading for each shipment shall be considered as the actual delivery date.
6.1.6 The Seller shall notify the Buyer by fax of the following within five (5) working days after each shipment is effected:
(a) Contract number
(b) Name of the vessel and loading port
(c) Name of the Equipment shipped
(d) Number and date of Bill of Lading
(e) Total volume
(f) Total gross and net weight
(g) Total number of packages/cases
6.1.7 The Seller shall airmail the following documents in duplicate to the Buyer:
(a) Bill of Lading
(b) Commercial Invoice
(c) Packing List
(d) Certificate of Origin
(e) Insurance Policy.
6.2 The Late Delivery of the Equipment
6.2.1 If the Seller fails to deliver the Equipment in accordance with the final delivery schedule, the Seller shall pay to the Buyer liquidated damages for such delay at the following rates:
(a) From the first week to the fourth week, the liquidated damages shall be
____ ( ) percent of the value of the delayed portion of the Equipment per
week
(b) From the fifth week to the eighth week, the liquidated damages shall be
____ ( ) percent of the value of the delayed portion of the Equipment per week
(c) From the ninth week, the liquidated damages shall be ____ ( ) percent of
the value of the delayed portion of the Equipment per week
6.2.2 The fractions of four days or more shall be counted as one week and fractions of less than four days shall be omitted. The total aggregate amount of the liquidated damages shall not exceed ____ ( ) percent of the value of the delayed portion Equipment.
6.2.3 The Seller shall be released from the liability to the Buyer whatsoever in respect of the late delivery after his payment of liquidated damages in accordance with Article 6.2. Notwithstanding the Seller’s payment of the liquidated damages for the late delivery Equipment, the Seller shall not be released from his obligation to deliver the Equipment.
6.3 The Delivery of the Technical Documentation
6.3.1 The Technical Documentation listed in Appendix 4 shall be delivered CIP ____airport by air within ____ ( ) months after the Effective Date of the Contract.
6.3.2 The date of airway bill shall be regarded as the actual delivery date of the Technical Documentation.
6.3.3 Within ____ ( ) working days after sending each lot of the Technical Documentation, the Seller shall inform the Buyer of the Contract number, item number, number and date of airway bill and the flight.
6.3.4 In case of shortage, loss of or damage to the Technical Documentation due to the Seller’s reason, the Seller shall make supplement to the Buyer within ____ ( ) days after receiving the Buyer’s written notification without any further charge.
Article 7 Packing and Marking
7.1 The Equipment shall be packed to withstand long distance transportation, multiple handling.
7.2 The Seller shall mark the following on two opposite sides of each package with indelible painted English words:
(a) Destination
(b) Consignee
(c) Contract number
(d) Shipping mark
(e) Gross/net weight (kg)
(f) Case/ bale number
(g) Dimensions: L x W x H (cm)
7.3 Each package shall contain one (1) copy of packing list.
7.4 The Seller shall mark on the package, if necessary, “Handle with Care", “Right Side Up", “Fragile" or other indicative marks according to the characteristics and feature of the goods as well as different requirement for transportation, loading and unloading of the goods.
7.5 If the goods weigh three (3) or more than three (3) metric tons, gravity, hoisting position and illustrative marks shall be marked so as to facilitate loading, unloading and handing.
(a) Destination
(b) Consignee
(c) Contract number
(d) Gross/net weight (kg)
(e) Item number
(f) Dimensions: L x W x H (cm)
Article 8 Technical Service and Technical Training
8.1 The Seller shall dispatch technical personnel to Job Site to render Technical Service in accordance with Contract according to a time schedule agreed upon between both parties. The number, specialty, rank, treatment of the personnel, and payment as well as the contents, and requirements of Technical Service are specified in Appendix 6.
8.2 The Buyer shall have the right to send its technical personnel to the relevant factory selected by the Seller for training. The number, speciality, treatment of the personnel, and payment as well as the contents, time schedule, and requirement of training, are specified in Appendix 7.
8.3 Either party shall provide assistance to the other party’s technical personnel in their application for visa, working permit, and/or other necessary formalities for rendering Technical Service or training under the Contract in the other party’s factory.
8.4 Either Party’s technical personnel shall abide by the laws of the other party’s country and the regulations of the other party during their stay in the other party’s country.
Article 9 Standards and Inspection
9.1 The Seller shall carry out the design, manufacture, inspection and test of the Equipment according to the existing standards of the People’s Republic of China, namely GB.
9.2 The Seller or the manufacturer shall, at his own costs and expenses, inspect the Equipment and issue the ex-work quality certificate.
9.3 The open-case inspection of the Equipment shall be performed by the Buyer in the presence of the Seller’s representatives on the Job Site in days after the arrival of the Equipment at the Job Site. The open-case inspection fee shall be borne by the Buyer.
The Buyer shall inform the Seller of the date one (1) month before the date of open case inspection and shall also render assistance to the Seller’s representatives in their inspection work.
9.4 During the joint open-case inspection, a detailed inspection record shall be made and signed by the representatives of both parties.
In case the Seller is responsible for any defect or shortage of the Equipment, the inspection record shall be taken as an effective evidence for the Buyer to claim repair, replacement or supplement to the Seller. Any of such claims shall be lodged by the Buyer within month(s) after the arrival of the Equipment at the Job Site.
9.5 If any shortage, defect of or damage to the Equipment is found in open-case inspection not attributable to the Seller’s responsibility, the Seller shall make repair, replacement or supplement at the Buyer’s expenses in accordance with the separate agreement signed by both parties.
9.6 The Buyer is not entitled to open the case, assemble and/or disassemble the Equipment without the Seller’s prior written consent.
If there is no joint open case inspection due to the reasons not attributable to the Seller, the quantity and apparent quality of the Equipment shall be deemed correct and in perfect condition.
Article 10 Design and Design Liaison
10.1 The Buyer shall provide to the Seller within ____ ( ) days after the Effective Date of the Contract, all the design data which shall be taken as the design basis. The Seller shall not be liable to the Buyer for, and the Buyer shall indemnify the Seller and hold the Seller harmless from any damages or failure caused by the incompleteness, incorrectness and/or inaccuracy of any such information and data.
10.2 A design liaison meeting shall be held in the ____ ( ) month after receiving above mentioned design data, the Seller will dispatch his technical personnel to the Job Site to participate in the meeting. During the meeting period, the Seller will discuss with the Buyer the relevant design details. Both parties shall sign an agreement outlining the design details.
10.3 During the design liaison meeting, the Seller and the Buyer shall provide assistance to the other’s dispatched personnel in arranging entry visas to the respective countries. The expense incurred on the dispatched personnel shall be borne by the party respectively.
Article 11 Erection, Test Run, Commissioning, Performance Test and Acceptance
11.1 The Erection, Test Run, Commissioning, Performance Test shall be conducted by the Buyer.
11.2 Chief Representatives
11.2.1 Each party shall nominate one (1) Chief Representative to deal with the technical matters during the period from the start of the Erection to Acceptance of the Equipment.
11.2.2 Detailed arrangements shall be made through friendly discussions by the Chief Representatives of both parties. The Chief Representatives of both parties shall fully cooperate to carry out their duties stipulated in the Contract, however they have no right to revise, alter or amend the Contract without the written authorization of both parties.
11.2.3 The Chief Representatives of both parties shall communicate through Linking Sheet for the matters relative to opinions, suggestions and information. The linking sheet shall be countersigned by the other party.
11.3 Erection and Test Run
11.3.1 The Erection shall be completed by the Buyer in ____ ( ) days from the effective date of the Contract. The Seller’s Chief Representative shall arrive at the Job Site ____ ( ) days prior to the beginning of the Erection.
11.3.2 When Erection is completed and in full conformity with requirements of the Technical Documentation, a Certificate of Completion for Erection of the Equipment shall be signed by the Chief Representatives of both parties in two (2) originals, one for each party, within three (3) days. The date of signing said Certificate shall be deemed as the date of completion of Erection.
11.3.3 As soon as the completion of Erection, Test Run for single machine and the whole system of the Equipment shall be started.
11.3.4 When Test Run has been successfully performed, a Certificate of Completion for Test Run of the Equipment shall be signed by the Chief Representatives of both parties in two (2) originals, one for each party, within three (3) days. The date of signing the said Certificates shall be deemed as the date of completion of Test Run of the Equipment.
11.4 Commissioning and Performance Test
11.4.1 Within ____ ( ) days after the completion of the Test Run, the Buyer shall make available qualified operation and maintenance personnel, raw materials, spare parts, utilities and other matters required for the Commissioning. Detailed procedures such as instrument calibrating, items of recording, sampling methods and analyzing methods, which are necessary for the Commissioning shall be discussed and agreed upon by the Chief Representatives of both parties.
If in the opinion of both parties, the Equipment is ready for the Commissioning, both parties shall confirm the readiness for the Commissioning in writing.
11.4.2 The Commissioning of the Equipment shall be started immediately after the confirmation of the readiness for the Commissioning. The Commissioning period shall ____ ( ) days after commencement of the Commissioning.
11.4.3 When the Seller and the Buyer consider that stable operation of the Equipment has been achieved, the date of Performance Test shall be fixed by Chief Representatives of both parties.
11.4.4 The Seller shall have the right to access to the laboratory and testing facilities in order to take samples and make analytical tests. The sample taking and analytical test during the Commissioning period will be done in the presence of the Chief Representatives of both parties.
11.4.5 During the period of Commissioning until Acceptance of the Equipment, the Seller may use the Buyer’s stored spare parts. Should the Buyer’s stored spare parts be used by the Seller due to the Seller’s responsibility, the Seller shall replenish the stores with the same in time at Job Site; otherwise the Seller shall provide the same at the Buyer’s costs upon the Buyer’s timely request.
11.4.6 If the result of Performance Test has reached the guarantee figures as per Appendix 1, the Acceptance Certificate of the Equipment shall be signed by the Chief Representatives of both parties in two (2) originals, one for each party, within three (3) days.
11.4.7 If the Performance Test cannot meet guarantee figures specified in Appendix 1, both parties shall jointly make investigations so as to find out the reason for clarifying the responsibility.
11.4.8 If the guarantee figures are not met due to the Seller’s reason, the Buyer shall agree to give an extension of ____ ( ) months so that the Seller can make improvement or adjustment to the Equipment and conduct further Performance Test. All the costs and expenses for making improvement or adjustment to the Equipment shall be borne by the Seller.
11.4.9 During the extension period, if the guarantee figures are still not met due to the Seller’s reason, the Seller shall pay the liquidated damages as per Appendix 1 to the Buyer against the Acceptance Certificate signed by both parties.
The Seller’s aggregate liability to pay liquidated damages for failure to attain the performance guarantees shall not exceed ____ ( ) percent of the Equipment price. The Seller shall have no further liability whatsoever to the Buyer in respect of such failure after payment of the liquidated damages.
11.4.10 If the non-achievement of the guarantee figures is due to the reasons not attributable to the Seller, the Seller shall agree to give an extension of ____ ( ) months. During the extension period all costs thereto incurred for the adjustment of the Equipment, as well as the costs and expenses for the Seller’s technical personnel shall be borne by the Buyer. In case the guarantee figures still can not be achieved due to the reasons not attributable to the Seller in the extension period, the Equipment shall be accepted by the Buyer. Both parties shall sign the Acceptance Certificate.
11.5 Acceptance
11.5.1 Acceptance shall occur in respect of the Equipment when :
(a) Performance Test has been successfully completed as per the Article 11.4.6.; or
(b) The Performance Test has not been completed due to the reasons not attributable to the Seller such as delayed civil construction, lack of and/or any other inconformity of raw materials, spare parts of the Buyer’s scope of supply under Appendix 2, and utilities with the requirements of the Contract in the ____ ( ) months from the date of Bill of Lading of the Last Shipment; or
(c) The Seller has paid the liquidated damages as per Article 11.4.9; or
(d) The guarantee figures still can not be reached due to reasons not attributable to the Seller’s reason in the extension period as specified in Article 11.4.10; or
(e) The Buyer takes the single machine and the whole system of the Equipment into use without the Seller’s approval.
11.5.2 At any time after any of the events set out in Article 11.5.1 has occurred, the Seller may give a notice to the Buyer requesting the issuance of the Acceptance Certificate.
11.5.3 The Buyer shall within seven (7) days after receipt of the Seller’s notice, issue such Acceptance Certificate.
11.5.4 If within seven (7) days after receipt of the Seller’s notice, the Buyer fails to issue the Acceptance Certificate or fails to inform the Seller in writing, with convincing evidence, of the reason why the Buyer has not issued the Acceptance Certificate, the Equipment shall be deemed having been accepted on the seventh day of the Seller’s said notice.
11.5.5 After the Acceptance, the Seller’s responsibilities and obligations under the Contract shall be deemed having been fulfilled except those as stipulated in Article 12 and 14.
Article 12 Guarantee and Warranty
12.1 The Seller guarantees that:
(a) The Equipment supplied by the Seller shall be new and made of adequate materials, and in conformity with the technical requirements of the Contract;
(b) The Technical Documentation shall be complete, clear and correct.
12.2 The period of warranty given by the Seller under Article 12.1 shall be ____ ( ) months from the date of Acceptance or ____ ( ) months from the date of Last Shipment, whichever comes earlier.
12.3 Defect of the Equipment
12.3.1 During the Warranty Period, should any defect due to inferior materials or bad workmanship of the Equipment be found under normal operation, the Buyer shall give the Seller a notice stating the details, together with all available evidence.
The Seller shall take immediate action to eliminate the defect at the Seller’s expenses within the period agreed by both parties.
12.3.2 If certain defect can not be eliminated despite of several attempts, the Seller shall replace the defective parts with non-defective parts at the Seller’s costs and expenses.
12.3.3 If the defect is eliminated by the Buyer himself, subject to the Seller’s prior written consent, all the direct costs and expenses thus incurred shall be borne by the Seller.
12.3.4 The Seller may reduce the price of the defective Equipment according to the degree of inferiority or extent of damage as agreed by both parties. After the reduction the Seller shall be released from its obligations and liabilities.
12.3.5 During the Warranty Period, should any defect due to the Buyer’s improper operation or maintenance be found, the Seller will provide technical assistance to eliminate the defect or replace the defected parts upon Buyer’s requests. All the costs and expenses thus occurred shall be borne by the Buyer.
12.3.6 Subject to Article 12.3.1, The Seller shall not be responsible for any defect or damage to the Equipment arising out of any circumstances including but not limited to the following causes:
(a) Combination of the Equipment with any machinery, and/or component other than those supplied by the Seller; or
(b) Alteration, modification or repair without the Seller’s prior written consent; or
(c) Failure of the Buyer to follow the Technical Documentation and instructions of the Seller, including the Buyer’s improper operation and maintenance; or
(d) Normal wear and tear.
12.4 During the Warranty Period, should the Technical Documentation supplied by the Seller be found incomplete, unclear or incorrect due to the Seller’s reason, the Seller shall be liable to supplement, replace or correct the Technical Documentation free of charge.
12.5 The Seller shall in no respect be understood or interpreted as liable for the commercial development of the Contract Products. The Buyer shall undertake the risk of the commercial development of the Contract Products.
12.6 In no circumstances, whether as a result of breach of contract, warranty, indemnity, tort (including negligence), strict liability, or otherwise, shall the Seller or its subcontractors or suppliers be liable for loss of profit or revenues, loss of production, loss of use, loss of information or data, cost of capital, cost of substitute equipment, facilities, services or replacement power, downtime costs, claims of the Buyer’s customers for such damages, or for any special, consequential, incidental, indirect or exemplary damages.
12.7 Notwithstanding anything to the contrary provided in the Contract, the aggregate liability of the Seller to the Buyer , on all claims of any kind, whether in contract, warranty, indemnity, tort (including negligence), strict liability, or otherwise, arising out of the performance or breach of the Contract or use of any Equipment or exploration of the Patent and/or Know-how shall not exceed ____ ( ) percent of the total Contract price.
12.8 All Contractual obligations of the Seller shall be deemed as having been fulfilled upon the expiry date of the Warranty Period.
Article 13 Intellectual Property Right
13.1 The Seller represents that it is entitled or authorized to grant the license to the Buyer to use the Patent and/or Know-how for the purpose as specified in Article 3.
13.2 The Buyer shall not use such Patent and/or know-how received from the Seller for any purpose other than that as specified in this Contract.
13.3 Any intellectual property right or other technical information granted by the Seller to the Buyer shall remain the property of the Seller. In no circumstances shall any terms and conditions in this Contract be construed, deemed, or interpreted as transfer of title to the Buyer of any information which may be delivered to or accessed by the Buyer.
13.4 Registration of the Contract and Maintenance of Patent
13.4.1 The Buyer shall, after the Contract is signed between both parties, make sure that the Contract is registered with or filed to the competent authorities in the Buyer’s country if it is required by law.
13.4.2 The Seller shall, during the validity period of the Contract, make all reasonable efforts to maintain Patent in force in the territory as stipulated in Article 3.4.1 and bear the costs thus incurred. The Buyer shall not make any action or inaction which may lead to invalidation or compulsory licensing of the Patent.
13.5 Improvement and Grant-back
13.5.1 Should any Improvement be made by the Seller on Patent and/or Know-how within the validity period of the Contract, which shall be the exclusive property of the Seller, the Seller shall grant the Buyer a non-exclusive license to exploit such Improvement at latest __________months from its improving, provided that the license fee is agreed upon between both parties.
13.5.2 The Buyer shall be entitled to make Improvement on Patent and/or Know-how within the validity period of the Contract. The Seller shall have the right to obtain and make use of the Improvement. The license fee shall be discussed between both parties in due time.
13.5.3 Both parties shall keep Improvement confidential. Neither party shall be entitled to grant any third party a sub-license on Improvement made and provided by the other party without previous written consent of the other party.
Article 14 Confidentiality
14.1 After signing of the Contract, both parties shall keep secret all the contents, terms, conditions of the Contract.
14.2 The Buyer shall take proper measures to keep strictly confidential of Know-how, Technical Documentation, Improvement and any other secret information obtained or accessible to from the Seller. The Buyer shall not disclose any of them to any third party, and shall not make use of them without prior written consent of the Seller except otherwise stipulated in the Contract.
14.3 The Buyer may disclose the secret information as described in Article 14.2 to the personnel of its own, or of any related parties engaged in the performance of the Contract subject to Article 14.2, strictly to the extent as essential for the implementation of the Contract, provided that the individuals and/or parties accessing or may access such secret information are engaged to undertake in written form the same confidential liability of the Buyer to the Seller. Any breach of confidentiality obligations by any personnel from the Buyer or the Buyer’s related parties shall be deemed as breach of the Contract by the Buyer.
14.4 Notwithstanding this Article 14, the Seller may furnish to its sub-contractor such documents, data, and other information received from the Buyer to the extent required for performing the Contract, in which event the Seller shall obtain from such sub-contractor an undertaking of confidentiality similar to that imposed on the Seller under the Article 14.
14.5 This Article 14 shall survive the expiration or termination of the Contract.
14.6 The confidential obligation shall not apply to the information which:
A. now or hereafter enters the public domain; or
B. can be proved to have been in the possession of the Party at the time of disclosure and which was not previously obtained, directly or indirectly, from the other Party hereto; or
C. otherwise lawfully becomes available to either party from a third party under no obligation of confidentiality.
Article 15 Taxes and Duties
15.1 All taxes and duties in connection with the signing and performance of the Contract, levied by Governments of the People’s Republic of China, including but not limited to customs duties, income tax, sales tax, value-added tax etc., shall be borne and paid by the Seller.
15.2. All taxes and duties in connection with the signing and performance of the Contract levied on the Buyer and Seller by the Buyer’s Governments, including but not limited to customs duties, income tax, sales tax, value-added tax etc., shall be borne and paid by the Buyer. The Buyer shall pay in due time and full amount and hold the Seller harmless from any taxes and duties in case incurred to the Seller in the signing and performance of the Contract.
15.3 All import taxes and duties for tools and/or instruments, which the Seller or the Seller’s personnel may bring to the Buyer’s country for the execution of the Contract, shall be borne and paid by the Buyer.
15.4 Any and all taxes and duties in connection with the signing and performance of the Contract levied in any place except the cases as specified in Article 15.1 are not included in the Contract price. Should the Seller make the relevant payment directly as the case may be, both Parties agree to amend the Contract price to fully compensate the Seller for the payment, and the Buyer shall fully refund the Seller for the relevant amount within_______( ) days from the Seller’s payment.
Article 16 Force Majeure
16.1 If either of the Contract parties is prevented from executing the Contract due to the event of Force Majeure such as war, riot, coup, embargo, flood, typhoon, tornado, snowstorm, earthquake and other events which could not be foreseen, avoided and overcome, the affected party shall notify the other party by fax within the shortest possible time of occurrences of the Force Majeure and send a certificate issued by competent authorities or agency certifying the event of the Force Majeure by registered or express mail within fourteen (14) days following its occurrence.
16.2 The affected party shall not be liable for any delay or failure in performing any of its obligations due to the event of Force Majeure. However the affected party shall inform the other party by fax the termination or elimination of the event of Force Majeure as soon as possible.
16.3 Both parties shall proceed with their obligations immediately upon the cease of the event of Force Majeure or the removal of the effects and the term of the Contract shall be extended correspondingly. Should the effect of the event of Force Majeure last for more than one hundred and twenty (120) days, either party shall have the right to terminate the Contract by a written notice.
Article 17 Applicable Law and Settlement of Disputes
17.1 The applicable law of the Contract shall be the laws of the People’s Republic of China.
17.2 All disputes arising from or in connection with the Contract shall be settled through friendly consultation between both parties. In case no agreement can be reached, the dispute shall be submitted for arbitration.
17.3 The arbitration shall be conducted by China International Economic and Trade Arbitration Commission (CIETAC) in Beijing in accordance with Arbitration Rules of the Commission in effect at the time of applying for arbitration. The tribunal shall be composed of three arbitrators.
17.4 The arbitral award shall be final and binding upon both parties.
17.5 During proceedings of arbitration, the undisputed part of the Contract shall be performed continuously by both parties regardless of such arbitration proceedings.
Article 18 Effectiveness, Term and Termination of the Contract
(a) The Seller and the Buyer sign the Contract;
(b) The Contract shall be approved by the competent authorities and/or banks of both parties (if applicable);
(c) The Seller receives the Down Payment;
(d) The Seller duly receives the L/C (or L/G ) issued by the Buyers Bank.
18.2 Each party shall use its best efforts to fulfill the above conditions for which it is responsible as soon as practicable.
18.3 If the Contract has not become effective pursuant to Article 18.1 within ____ ( ) months after the date of signing this Contract, the Seller has the right to make an equitable adjustment to the total Contract price and the time for delivery and/or other relevant conditions of the Contract. Should no agreement is reached for the above mentioned adjustment within ____ ( ) days from the Seller’s request of adjustment, the Seller shall be entitled to cancel the Contract.
18.4 The Contract shall be valid and remain in force for_____ (_____) years from the Date of Effectiveness, during which period the Buyer shall be entitled to manufacture the Contract Products with Patent and/or Know-how and sell the Contract Products within the licensed territory as specified in Article 3.4.
(Option 1) The Buyer shall not be entitled to manufacture with patent and/or know-how or sell the contract products after the aforesaid period unless the Buyer agrees to pay additional license fees in the amount and with the payment schedules and methods as agreed upon between both Parties in due time.
(Option 2) The Buyer shall be entitled to manufacture with Patent and/or Know-how or sell the Contract Products after expiration of the Contract term specified above, provided that the Buyer shall not be released from its confidential obligations under the Contract.
(Option 3) The Buyer shall not be entitled to manufacture with Patent and/or Know-how or sell the Contract Products after the expiration of the Contract term specified above, and shall return to the Seller all the Technical Documentations specified in Appendix 4 without remaining any duplicate copies. Nevertheless the confidential obligations of the Buyer under Article 14 shall survive the Contract term.
18.5 Either party may, without prejudice to any other remedy for the other party’s following breach of the Contract, terminate the Contract in whole or in part by a written notice send to the other party, if the other party
A. fails to perform its payment obligation under the Contract and does not remedy for its failure within a period of ______ (____) days upon receipt of the written notice or a period agreed upon between the parties; or
B. fails to perform its confidentiality obligation under the Contract; or
C. fails to perform any other obligations under the Contract except minor parts thereof, and does not remedy for its failure within a period of ______ (____) days upon receipt of the written notice or a period agreed upon between the parties; or
D. becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration order made against him, compounds with his creditors, or carries on business under a receiver, trustee or manager for the benefit of his creditors, or dissolves, or ceases to do business, or be ordered to close down / to cease to do business / to dissolve, or has its business license revoked, or if any act is done or event occurs which (under applicable Laws) has a similar effect to any of these acts or events.
18.6 Either party may, without prejudice to any other remedy, terminate the Contract in whole or in part by a written notice send to the other party, if
A. The other party is prevented by the laws, statutes, rules or regulations of either country from performing its obligations under the Contract; or
B. The Seller is prevented by the relevant authority of the Buyer’s country from being paid in accordance with the Contract; or
C. The other party is prevented from performing its contractual obligations by any event of Force Majeure for more than one hundred and twenty (120) days.
18.7 In the event of termination of the Contract, without prejudice to any other remedies available according to the Contract and/or applicable laws,
The Buyer shall cease all its further exploitation of the Patent and/or Know-how and any acceptance of further orders from third parties for the Contract Products.
All the delivered literatures, drawings, samples, instruments, equipment, and other documents including the interpretations related to Patent and/or Know-how shall be returned to the Seller as the Seller’s requests.
All the contracts on sales of the Contract Products signed between the Buyer and third parties shall be terminated by the Buyer, otherwise the Seller shall be paid accordingly.
In case the termination is due to the Seller’s default, the Buyer shall be entitled to complete the performance of the contracts on sales of the Contract Products already signed between the Buyer and third parties before the termination.
The Seller shall be paid by the Buyer for all the contractual obligations performed by the Seller till the date of termination within _______days from receipt of the termination notice.
E. Termination of the Contract shall not release either party from its confidential obligations under the Contract
Article 19 Miscellaneous
19.1 The Contract is signed by the authorized representatives of both parties in ____ ( ) originals. Each party shall keep ____ ( ).
19.2 The Contract supersedes all communications, negotiations and agreements between the parties prior to the signing date of this Contract.
19.3 All amendments, supplements and alternations to terms of the Contract shall be made in written form and signed by the authorized representatives of both parties. These amendments, supplements and alternations shall form integral parts of the Contract.
If any costs occur or delivery delay due to amendment or explanation of the new law or statute or regulations enacted by the Buyer’s country after the effectiveness of the Contract,the Seller shall have the right to ask for necessary adjustment in relation to the Contract price and the delivery schedule.
19.4 No assignment, cession, novation, or transfer of any right or obligation under this Contract shall be made by either party to a third party without the prior written consent of the other party.
19.5 All communications between both parties in the course of implementation of the Contract should be in English language in written form at the address set forth below. The faxes concerning the important matters shall be confirmed in due time by registered or express mail or letter delivered by hand.
The Buyer:
Address:
Post Code:
Fax: __________________________
Tel.: __________________________
Email:__________________________
Attention: ______________________
The Seller :
Address:
Post Code:
Fax: __________________________
Tel.: __________________________
Email:__________________________
Attention: ______________________
IN WITNESS WHEREOF, the parties hereto have caused this Contract to be duly executed.
The Buyer:
The Seller:
By:______________________[Signature]
Name: [printed name]
By:_______________________ [Signature]
Name: [printed name]
Title:
Title:
Appendices
Appendix 1 Specifications and Guarantee Indices (Omitted)
篇13:外贸公司实习总结
本人实习的公司是漳州市兴华金属制品外贸有限公司,那是一家专业生产钢管家具,超市货架、网片等,并生产各类家具配件,拥有专业的模具车间、生产车间,拥有大小型冲床两百余台,公司拥有专业生产流水线、自动静电喷涂流水线以及模具设计、制造等优质服务。此公司的产品畅销欧美东南亚等国家和地区。
这个公司设备先进.技术力量雄厚.现有冲床,折弯机,剪板机,线切割,磨床,火花机等160余台.一模具生产研发车间,一条喷塑流水线.拥有完善的生产、加工及检测设备!生产的产品全部执行国家标准.批量生产.规格齐全. 兴华金属(制品)有限公司自建厂以来.产品销往全国各地.深受用户好评.特别质量始终处于同类厂家领先地位.公司将以实惠的价格、热诚的服务.完善的检测手段,优良的售后服务著称。
本人在此公司的业务部,身为外贸业务员的我必须做到的几件事如下:
1.每天至少两次收发反馈信箱,早上上班和晚上下班之前,每天必须保证收到的反馈及时回复完。(有时晚上加班不可避免,但是可以与客户同步,加快沟通的频率,占的先机)。
2,做好客户信息管理:建立一个excel表格,将所有收到的客户信息及时填写到表格中,并且做好客户分类工作,将询盘内容,质量比较高的客户做为a类客户重点跟踪(但是也不能够忽略小客户,任何客户都是从小做到大的,就象卖东西,要把客户从头回客户做到回头客户---忠实客户----传代客户)。
3,主动到相关商务网站里寻找买家(要整理分类,针对不同地区的客户进行不同的发盘,做到简洁,有针对性)。
4,每隔几天到相关商务网站(例如阿里巴巴网站,跨国采购网,国际进出口贸易网),发布一条具有商业价值的信息。(虽然可能效果不是很好,但是也花不了多少时间,如果更新的快的话,产品信息就会出现目录的首页,说不定就会有所收获。)
5,每个季度定期更换网页内容。将新产品信息发布上网,或者将产品的图片替换一下。这些都会让买家及时了解公司的最新信息,吸引新客户。
6,定期给老客户或者潜在的客户发送公司的最新产品信息(据统计开发一个新客户所花费的费用相当于维持十个老客户所花费的费用,在开发新客户的时候一定不能忽视老客户的维持,可以在节日的时候给客人发送卡片祝福,客人都会觉得很亲切,合作的愉快)
7,身为业务人员要每周汇报反馈询盘及跟进情况。(把这些表统一整理,留做备份,至少这些都是以后的潜在客户)
篇14:进口合同范本_合同范本
进口合同范本
下面是由应届毕业生合同范本介绍的一份进口合同
买 方:____________ 地址:________________ 电话:____________
法定代表人:____________ 职务:________________ 国籍:____________
卖 方:____________ 地址:________________ 电话:____________
法定代表人:____________ 职务:________________ 国籍:____________
买卖双方在平等、互利原则上,经充分协商一致,由买方购进,卖方出售下列货物,并按下列条款履行:
第一条 货物名称、规格、生产国别、制造工厂、包装及唛头。
每件货物上用不褪色的涂料标明货号、毛重、净重、编号、尺码、目的口岸,并标明下列唛头
第二条 数量、单价、总值。
第三条 装运期限:
每月交货数量必须一次交清,不得分批装运。
第四条 装运口岸:
第五条 目的口岸:
第六条 付款条件:买方在收到卖方关于预计装船日期及准备装船的数量的通知后,应于装运前20天通过________银行开立以卖方为受益人的不可撤消的信用证。该信用证凭即期汇款票及本合同规定的单据在开证行付款。
第七条 单据:各项单据均须使用与本合同相一致的文字,以便买方审核查对:
A.填写通知目的口岸对外贸易运输公司的空白抬头、空白背书的全套已装船的清洁提单(如本合同为FOB价格条件时,提单应注明“运费到付”或“运费按租船合同办理”字样;如本合同为CFR价格条件时,提单应注明“运费已付”字样)。
B发票:注明合同号、唛头、载货船名及信用证号;如果分批装运,须注明分批号。
C.装箱单及/或重量单:注明合同号及唛头,并逐件列明毛重、净重和货号。
D.制造工厂的品质及数量/重量证明书。
品质证明书内应列入根据合同规定的标准按货号进行化学成分、机械性能及其他各种试验的实际试验结果。数量/重量证明书应按货号列明重量。
单证
份数
寄送 A
B
C
D
E
F
送交方议付银行 3
4
3
3
1
1
送交议付银行(副本)
1
空邮目的岸外运公司(副本)
2
2
2
2
E.按本合同规定的装运通知电报抄本。
F.按本合同规定的航行证明书(如本合同为CFR价格条件时,需要此项证明书;如本合同为FOB价格条件时,则不需此项证明书)。
第八条 装运条件:
A.离岸价条款:
(a)装运本合同货物的船只,由买方或卖方运输代理人________租船公司租订舱位。卖方负担货物的一切费用风险到货装到船面为止。
(b)卖方必须在合同规定的交货期限30天前,将合同号码、货物名称、数量、装运口岸及预计货物运达装运口岸日期,以电报通知买方以便买方安排舱位。并同时通知买方在装货港的船舶代理,若在规定期限内买方未接到前述通知,即作为卖方同意在合同规定期内任何日期交货,并由买方主动租订舱位。
(c)买方应在船只受载期12天前将船名、预计受载日期、装载数量、合同号码、船舶代理人,以电报通知卖方,卖方应联系船舶代理人配合,按期备货装船。如买方因故需要变更船只或更改船期时,买方或船舶代理人应及时通知卖方。
(d)买方所租船只按期到达装运口岸后,如卖方不能按时备货装船,买方因而遭受的一切损失包括空舱费、延期费及/或罚款等由卖方负担。如船只不能于船舶代理人所确定的受载期内到达,在港口免费堆存期满后第16天起发生的仓库租费、保险费由买方负担,但卖方仍负有载货船只到达装运口岸后立即将货物装船之义务并负担费用及风险,前述各种损失均凭原始单据核实支付。
B.成本加运费价条款:
卖方负责将合同所列货物由装运口岸装班轮到达目的口岸,中途不得转船。货物不得用悬挂买方不能接受的国家的旗帜的船只装运。载货船只在驶抵本合同规定的口岸前不得停靠________或________附近地区。
第九条 装运通知:卖方在货物装船后,立即将合同号、品名、件数、毛重、发票金额、载货船名及装船日期以电报通知买方。
第十条 保险:自装船起由买方自理,但卖方应按本合同规定通知买方。如卖方未能按此办理,买方因而遭受的一切损失全由卖方负担。
第十一条 检验和索赔:货卸目的口岸,买方有权申请____ 国商品检验局进行检验。如发现货物的品质及/或数量/重量与合同或发票不符,除属于保险公司及/或船公司的责任外,买方有权在货卸目的口岸后90天内,根据____ 商品检验局出具的证明书向卖方提出索赔,因索赔所发生的一切费用(包括检验费用)均由卖方负担。FOB价格条件时,买方有权同时索赔短重部分的运费。
第十二条 不可抗力:由于人力不可抗拒事故,使卖方不能在合同规定期限内交货或者不能交货,卖方不负责任。但卖方必须立即以电报通知买方,并以挂号函向买方提出有关政府机关或者商会所出具的证明,以证明事故的存在。由于人力不可抗拒事故致使交货延期一个月以上时,买方有权撤消合同,卖方不能取得出口许可证,不得作为不可抗力。
第十三条 延期交货及罚款:除不可抗拒原因外,如卖方不能如期交货,买方有权撤销该部分的合同,或经买方同意在卖方缴纳罚款的条件下延期交货。买方可同意给予卖方15天的优惠期。罚款率为每10天按货款总额的1%。不足10天者按10天计算。罚款自第16天起计算,最多不超过延期货款总额的5%。
第十四条 仲裁:一切因执行本合同或与本合同有关的争执,应由双方通过友好方式协商解决。如经协商不能得到解决时,应提交中国国际经济贸易仲裁委员会,按照该仲裁委员会仲裁程序进行仲裁。仲裁委员会的裁决为终局裁决。对双方均有约束力,仲裁费用除仲裁委员会另有决定外,由败诉一方负担。
第十五条 本合同于____年____月____日于____国____市用____文签署,正本一式两份,买卖双方各持一份。
买 方:________ (盖章)
代表人:________
卖 方:________ (盖章)
篇15:外贸专业实习自我鉴定
自从我在XX年3月进入进入实习单位实习已经过去了三个月,在这三个月的工作和学习中,我有很多的感受和收获,深深体会到了社会实践经验与课本理论知识的巨大差异,所谓“从实践中来,到实践中去”。当我开始实际的工作的时候,我更加明白了自己的斤两,知道自己只有付出更多的汗水与辛劳,才能做好本职工作,不辜负实习单位领导的期望。感谢,单位领导们给我足够的宽容和耐心,加上同事们毫无保留的“授业解惑”,无论是思想上还是工作上我都得到了很大的锻炼和提高,取得了长足的发展和巨大的收获。
工作近三个月,接触了不少人和事,在为自己的成长欢欣鼓舞的同时,我也明白自己尚有许多缺点需要改正。我认识到做任何工作都要有足够的耐心与细致,首先需要改正的就是尚显浮躁的心态,有时候做事只求速度而忽略了质量;有时在做一件事的时候忽略了其他事情与此事的关系,造成前后矛盾,更需要时刻警醒自己。如果不是同事们及时为我指正,恐怕到现在我也不自知而无法提高自己,因此我经常是带着一种感恩的心态在工作;其次就是专业知识不够熟练。就这些情况,我将来更需要多多学习的,希望以后能够少犯错误,做出成绩。
作为实习单位中的一分子,我惟有踏踏实实做事,谦虚低调做人,努力学习行业新知识,向同事们学习经验技巧,在领导和同事们的帮助下,尽力与其一起努力保证日常工作的更新,保证工作任务的顺利进行。这是我职责之所在,价值之所在。
在实际工作中,更重要的是牢固树立了强烈的事业心、高度的责任感和团队精神。我想毕业以后我会继续以朝气蓬勃、奋发有为的精神状态,努力发挥聪明才智,相信在自我的奋斗下,我一定能够实现人生的理想。
篇16:海运、空运出口运输代理协议
合同编号: 托运方: (以下简称甲方)
承运方:(以下简称乙方)
经甲乙双方自愿平等友好协商,根据中华人民共和国相关法律法规规定,双方就有关代办货物运输事宜达成如下协议,以便双方共同遵守。
甲乙双方必须保证各自履行本合同之行为均为合法经营之所需,任何一方为非法目的而履行本协议的,由该方承担其非法经营的责任。
第一条 承运内容
1.1合同标的: 。
1.2运输方式:集装箱整箱运输,公路水路联运。
第二条 运价及运输期限
②以上运价按照 尺柜进行核算;
③以上运输周期不可抗力的因素除外;
④如果确定费率所依赖的客观形势发生了较大变化,例如市物价局、港务局、交通部、海关规定,或者船东、船代、码头及堆场费率、燃油价格上涨或过路过桥费用上涨_____%以上等,则乙方可以调整费率,但乙方应提前以书面形式通知甲方。
第三条 货物的交运及验收
3.1甲方在货物出运前 日以书面形式向乙方通报货物托运计划。甲方委托货物运输,应当向乙方准确表明发货人、收货人的名称或者姓名、联系方式、货物的名称、性质、数量、重量、体积、包装方式、装船日期、目的港及收货地点、特殊运输要求等有关货物运输的必要情况并提供与货物运输有关的一切文件单证。甲方应对其提供的资料真实性负责,因甲方申报不实或者遗漏重要情况,造成乙方损失的,甲方应承担损害赔偿责任。
3.2乙方应在接到甲方货物托运通知后,按照甲方的托运计划及时订舱,尽快备妥集装箱运输车辆,到甲方仓库或者指定场所,以便甲方准备货物装箱等事宜。
3.3甲方按照委托书中规定的时间和数量交付托运货物并负责装箱、计数、封箱。甲方对托运的货物应按照国家主管机关规定的标准包装;没有统一规定包装标准的,应根据保证货物运输安全的原则进行包装,否则乙方有权拒绝承运。
3.4若甲方托运易燃、易爆、有毒、有腐蚀性、有放射性等危险物品或易变质物品的,应当按照国家有关危险物品运输或易变质物品的规定对危险品或易变质物品妥善包装,做出危险物或易变质物品标志和标签,并将有关危险品或易变质物品的名称、性质和防范措施的书面材料在交运前提交乙方。甲方违反上述规定的,乙方有权拒绝运输,也可以采取相应措施以避免损失的发生,因此产生的费用由甲方承担。
3.5交货及验收工作的完毕以双方签署的托运单为标志。
第四条 货物的承运
4.1乙方应妥善运输甲方托运的货物,对托运的货物要负责运输过程中的安全,保证货物无毁损、灭失,运输过程中因甲方原因发生货物毁损、灭失的,应承担赔偿义务。
4.2货物托运后,甲方需要变更到货地点或收货人,或者取消托运时,有权向乙方提出变更合同的内容或解除合同的要求,但必须在货物未运到目的地之前通知乙方。甲方应支付乙方由于执行该要求所产生的全部合理费用及因此导致的任何第三方索赔。
4.3甲方有权随时获知货物在承运过程中的实际情况。
第五条 货物的交付及交货验收
5.1乙方应在约定时间内将货物送到指定的地点。货物运输到达目的地后,乙方应当及时向托运单上甲方指定的收货人发出到货通知。甲方指定的收货人在乙方发出通知后应及时提货,甲方亦应与收货方协调交货事宜,及时督促收货人收货,逾期未提货的,乙方有权自行将货物卸下,由此产生的卸货费、仓储保管费及相关费用由甲方和甲方指定收货方承担。【或甲方应当保证收货人在卸货港及时提货,由于提货不及时而造成的额外堆存费和滞箱费(按照公布的费率计收)应由甲方承担,上述费用必须在提货前直接支付给码头和船公司代理。(适用港口提货)】
5.2货物送达指定地点后,乙方验明收货人身份后办理交货手续。在铅封完好、集装箱表面状况良好的前提下,箱内货物发生灭失、短少、变质、损坏的,乙方不承担责任;若铅封损坏或箱体破漏,货物发生灭失、短少、变质、损坏的,乙方应协助甲方向责任方追索赔偿。
5.3甲方指定的收货人负责卸货。因甲方指定的收货人卸货不当造成货物的灭失、损坏或者造成的任何第三方责任与乙方无关,由甲方指定的收货人承担责任。
5.4货物送达后,联系不到甲方指定的收货人或收货人拒收货物的,乙方应在妥善保管货物的同时及时联系甲方,依甲方指示处理,由此产生的额外费用由甲方承担。在此过程中,货物的一切风险由甲方自行承担。
第六条 运输保险
6.1起运前,甲方书面要求乙方是否代办货物运输保险,并确认被保险人、保险公司、保险险种、保险费率、核定货物保额、免赔率等。费用凭保单向甲方收取。
6.2因发生保险责任范围内的事故导致货物毁损、灭失的,乙方应当即时通知甲方和保险公司,并有义务协助甲方办理保险理赔事宜。
6.3为防患在途货物风险,甲方应自行负责货物的保险或委托乙方代买保险,否则,在甲方怠于履行义务并发生货损的情况下,属于保险事故责任范围内可理赔的货物毁损、灭失部分的,乙方不予承担赔偿责任,乙方仅在其投保的承运货物责任险的限度内承担相应的责任。
第七条 运费结算
7.1运费结算方式为“按月结算”,结算单位为人民币元。
7.2运费的结算日为每月末(结算期限为每月一日至月末)。双方合作的第一笔业务发生之日至该月月底,算一个月;次月起以整月计。乙方于结算日后三个工作日内向甲方发出或传真上月的运费催缴通知书,甲方应在收到通知后的三个工作日内予以书面确认,签字或加盖有效印章回传乙方;逾期不确认的,视为默认,甲方应按照乙方的催款数额支付。甲方应在每月十五日前将上月的应缴款项如数汇(转)入乙方指定账户。
对于上述费用,甲方若需要以本协议外的第三方支付其费用给乙方的,必须以书面通知乙方,且得到乙方书面确认,如果第三方不付款或逾期未付款时,乙方有权向甲方催讨,甲方应保证在甲方催讨通知之日起 的15天内付清所有应付款项。
收款人:
开户行:
帐 号:
7.3甲方应及时支付运费、保管费以及其他运输费用(包括代收代投保险费)。如果甲方不支付或不按时交付约定的各种运杂费用,乙方应书面通知甲方及时补交。甲方收到乙方催款通知后仍不及时支付运杂费的,乙方有权停止运输或留置甲方任何有效单证或未支付的运费数额同等货值的货物直至甲方交付运杂费,由此产生的额外费用损失和责任由甲方承担。同时,每逾期一天,甲方应按未支付运费的 %作为违约金支付给乙方。甲方未及时付费造成承运人依法留置单据或货物的,由甲方自行承担责任。
第八条 违约责任
(一)甲方责任
8.1 若乙方在指定的时间内提供适合甲方要求的集装箱车辆到甲方指定的地点待装,但甲方因货源、搬运等问题造成乙方无法在集装箱车辆到达后的 小时内装运完毕的,每延迟一天按单次运费的 %作为空车费/空箱费支付给乙方。
因甲方原因或甲方指定收货人原因延迟卸货导致乙方无法在车辆到达后 小时内卸载完毕,由此造成的滞车费/滞箱费、仓储保管费等相关费用由甲方承担。在此过程中,货物的风险由甲方承担责任。
8.2由于甲方假报货名、在普通货物中夹带国家禁运物品、危险品,错报笨重货物重量等而招致吊具断裂、货物摔损、吊机倾翻、爆炸、腐蚀等一切后果由甲方承担。
8.3由于货物包装缺陷产生破损,致使其它货物或运输工具、机械设备被污染、腐蚀、损坏,甲方应承担赔偿责任。
8.4 因甲方违反法律法规及本协议等给乙方造成损失的其他情况。
(二)乙方责任
8.5运输过程中因乙方原因造成的货物毁损、灭失的,乙方应赔偿甲方该毁损、灭失的损失。属于保险事故的,依照本合同第六条约定。货物损失金额按甲方出厂价格赔偿。在符合法律和协议规定条件下的运输,乙方能够证明货物的毁损、灭失是下列原因造成的,乙方不承担损害赔偿责任:
①不可抗力; ②货物本身的自然性质变化或者合理损耗; ③包装缺陷造成的货物受损;④包装体外表面完好而内装货物毁坏或灭失;⑤在运输开始前,货物已存在的品质不良或数量短差所造成的损失;⑥托运人或收货人本身的过错;⑦经国家有关部门认定的违法、非法货物;⑧法律法规或本协议约定承运人可免责的其它事由。
8.6 乙方逾期送达的,对确认属于货物延期交付的索赔,应以该部分货物所涉及的运输费用为限。对于延期交付而产生的间接损失,乙方不承担赔偿责任。但遇塌方、桥梁中断、洪水、台风、海啸等不可抗力导致车辆、船舶无法正常通行或因甲方原因造成的,免除该违约责任。
8.7若乙方将货物错运送达地点或收货人,应当无偿运至合同约定的送达地点或收货人,逾期送达的,按前款约定承担违约责任。
8.8运输途中如遇检查部门(公安、工商、税务、海关)对货物有异议被扣留或罚款均由甲方负责处理,并提供有关有效证件,并承担由此给乙方带来的一切经济损失。
第九条 不可抗力
9.1不可抗力,是指不可预见、不能避免、不能克服的客观情况,包括但不限于地震、台风、水灾、火灾及其他自然灾害,战争、暴乱、骚乱、戒严,及其他受影响一方不能控制的客观情况。
9.2 受不可抗力影响的一方,应在不可抗力事件发生后及时通知另一方,出具不可抗力的有效依据,并应当采取合理措施尽量减少不可抗力事件的影响,尽可能在最短时间内恢复履行本合同。
9.3若发生不可抗力事件,任何一方无需对另一方因本合同未能履行或延迟履行而遭受的任何损失承担责任。若发生不可抗力事件不能履行本合同的,经双方商议,可视情况顺延履行期限或终止履行。
第十条 争议解决
本合同未尽事宜,由合同双方当事人协商一致解决。若不能协商解决时,本合同项下发生的任何争议,或者裁决是终局的,对双方都有约束力。(注:以上两条款,只能选择一项,请根据实际情况决定。)
第十一条 附 则
11.1 任何一方未经对方事前书面同意,不得转让本合同项下的任何一项权利和义务。
11.2 本合同所有附件、单据、传真、信函等为本合同不可分割的部分,与本合同具有同等效力。未尽事宜,经双方协商,可订立补充协议。
11.3 本合同有效期自 年 月 日至 年 月 日,自双方签字盖章之日起生效。期满由双方决定是否续签。未经同意,双方中任意一方不得将此协议内容泄露给第三方,否则所造成的损失由责任方承担。或者本合同项下的货物经收货人签收后则表明此合同已完结,乙方不承担签收后货物短损等问题。(注:以上两条款,只能选择一项,请根据实际决定。)
11.4 本合同一式二份,双方各执一份,具有同等效力。
甲方(签章): 乙方(签章):
地址: 地址:
有权签字人: 有权签字人:
税号: 税号: 开户行: 开户行:
帐号: 帐号:
联系人:____________ 联系人:____________
电话: 电话:
传真: 传真:
签约时间: 签约地点:
篇17:外贸业务员辞职报告范文
尊敬的公司领导:
您好!
首先感谢公司对我的培养,长期以来对我的关心和照顾,使我得到了家庭般的温暖。和大家在一起的日子里,让我学到了很多知识,学会了很多为人处事的原则。
认真回顾过去的这一年,我在xx公司学到了很多东西,无论是专业技能还是为人处事方面都有很大的提高,我也非常热爱我的这份工作。此外,我也非常感谢我的同事们,感谢他们一直以来对我的帮助和关怀,以及大家在一起的那份和睦,那份团结一致。
现由于个人原因(家庭原因/身体原因等等)不能在公司继续工作了,请领导给予批准!
此致
敬礼
申请人:
*年*月*日
篇18:进口国际货物贸易合同格式合同
卖方________
地址:________
电报挂号:________
买方:________
地址:________
电报挂号:________
日期:________
签约地点:________
兹经卖买双方同意成交下列商品订立条款如下:
1.商品:________
2.规格:________
3.数量:________
4.单价:________
5.总价:______U.S.D.(大写:________)
6.包装:________
7.装运期:________收到信用证后____天
8.装运口岸和目的地:从____经____至____。
9.保险:________
10.付款条件:________
(1)买方须于______年____月____日前将保兑的、不可撤销的、可转让、可分割的即期信用证开到卖方。信用证议付有效期延至上列装运期后,____天在____到期。
(2)买方须于签约后即付定金______%。
11.装船标记及交货条件:货运标记由卖方指定。
12.注意:开立信用证时请注明合同编号号码。
13.备注:____________________
卖方:________
日期:________
买方:________
日期:________
篇19:关于进口贸易的合同
合同编号:_____
甲方:_____公司(以下简称供方),由_____代表。
乙方:_____公司(以下简称购方),由_____代表。
目录
第一条合同标的
第二条技术资料
第三条供货条件--包装和标记
第四条设备质量
第五条合同价格和支付条件
第六条保证
第七条不可抗力
第八条仲裁
第九条通知
第十条语言
第十一条其他条件
附件1设备技术说明书
甲方___(供方)与乙方____(购方)达成如下协议:
第一条合同标的
供方同意出售,购方同意购买____。(详见本合同附件1,该附件为本合同不可分割的一部分)。
第二条技术资料
供方应向购方提供设备使用及维修技术资料一份,购方负有对该技术资料保密之义务。
第三条供货条件--包装和标记
供方应在设备全额信用证开立之后的__个月内用密封集装箱或其他包皮包装从____发运设备。供方有权从任何对其方便的港口发运设备。供方应把设备运至商定的独联体东海岸___港。
自设备从船舷运抵独联体远东港口时起灭失和(或)损坏的风险由供方转移到购方。供方承担设备运输的一切费用及运抵港口前的保险费。设备从独联体港口继续运到安装地的一切费用由购方承担。发货前__天内供方应向购方通知发运情况,明确交通工具的种类和名称、计划发运日期及其他有关信息。购方应支付履行海关手续的所有费用和一切与设备运入独联体境内有关的开支。设备和技术资料用密封集装箱或其他包皮装运并附具包装清单,标记使用英语刷写。
发货单证包:
(1)发货帐单(三份)
(2)海运提单
(3)装箱单
(4)保险单
第四条设备质量
按本合同所供设备的质量应符合生产厂家的技术条件。如生产厂家有保证书,应用保证书加以确认。
第五条合同价格和支付条件
所供设备的总额为___美元(cif价)。购方应在合同签订后的__天内开立以供方为受益人的不可撤销的保兑信用证。该信用证在开立时起的__天内有效。
开证行应为独联体外经银行或日本、南韩、西欧、美国、加拿大的某家银行。
一切与在开证行开立信用证有关的费用由购方承担,而一切与议付行收取信用证有关的费用由供方承担。
支付在向议付行提交下列单据后进行:
(1)发货帐单(3份)
(2)海运提单
(3)装箱单
(4)保险单
第六条保证
供方保证所供设备在投入使用日起的__个月内,但不超过发货日起的__月内正常工作。
第七条不可抗力
在发生不可抗力情况致使合同一方不能全部或部分履行本合同的义务时,按此种不可抗力情况存在的时间推迟履行合同义务。
不可抗力情况是指双方不能预见或预测的由于非常事件而出现的情况,即:影响履行所承担义务的火灾、风暴、地震和其他自然现象,以及战争、任何性质的军事行动,各国政府的封锁与制裁等。
因不可抗力情况而不能履行义务的一方,应在不可抗力情况发生和停止的20天内书面通知另一方关于其发生和停止的情况。收信人所在国邮局在收到通知函日
加盖的日期作为得悉该信息的日期。
协约双方国商会出具的证明书将成为证明上述情况发生及延续时间的必要证据。如这些情况延续3个多月,每一方都有权拒绝继续履行本合同义务,同时任何
一方都无权要求对方赔偿可能发生的损失。
第八条仲裁
所有可能由本合同而产生的纠纷或分歧均应由合同双方友好解决。如果无法解决纠纷,则该纠纷应提交莫斯科市外贸仲裁委员会按其业务规章审理(提交一般法院审理者除外),该委员会的决定对于双方均为终审,必须执行。
第九条通知
一切通知等双方均应按本合同条件以书面形式进行。
第十条语言
本合同用俄语书就。供方提供英文的全部技术资料和供货单证。
第十一条其他条件
自本合同签署之日起,所有在此以前的有关谈判和往来信函均告失效。 对本合同的任何修改和补充只有在以书面形式形成并经双方有关全权代表签字后方能生效。经双方确认的往来信函、传真、电子邮件等,将作为本合同的组成部分,并有合同的效力。任何一方都无权在未征得对方书面同意之前将自己对合同的权利和义务转让给
第三者。
本合同于____年____在俄罗斯___签署。一式两份,两份具有同等效力。
供方:_____
购方:____
篇20:外贸采购合同
需方: (以下简称需方)
供方: (以下简称供方)
供、需双方本着平等、互惠互利原则,经协商一致,就需方向供方采购、供方向需方供应附件一中所列产品签订本合同。
一、供货方式:
1.由需方以《物料订购单》方式向供方下达采购订单,供方须按照订单要求提供产品。
2.供方在收到《物料订购单》后应回传确认函,如有任何问题必须在一个工作日(8小时)内书面通知需方,否则视为默认。
3.需方有权根据生产计划的变更以及供方产品的供货质量、采购订单的执行情况、售后服务质量等条件对供方的供货品质及数量进行及时调整,供方有义务积极配合。
4.为保证产品数量的准确性,供方须免费提供1-3%的易损耗件和需方客户所必须的随柜修补件。
二、 产品的质量要求:
1.供方应按需方认可的产品供货,未经需方事先书面同意,不得对产品本身和生产场地有任何改变。
2.供方需严格按照经需方认可的质量和技术规格要求生产和供应产品,如有任何改变,需方负责知会供方更新有关图纸或菲林等,供方积极跟进相关的变化。
3.供方应保证所生产或供应的产品均符合有关环保法规要求及国家标准、行业标准。
三、品质保证:
1.供方应保证所使用的原材料符合需方要求,对未曾使用过的原辅材料的变更,必须提前书面报需方确认。
2.供方应建立有效的质量保证体系以满足需方要求,需方有权随时对此进行检查考核。
3.供方供货前应严格按要求自检,其检测项目不得少于需方标准和图纸所规定的进货检测项目,并有书面记录。
4.对需方提出的质量问题和要求整改意见,供方必须及时解决和整改,若在规定期限内未得到解决和整改,需方有权停止供方供货。
四、包装要求:
供方须按需方要求定量包装,并在外包装上标识制造批号、物料名称、材质、型号、规格、颜色、数量等,包装物应适应*车装卸、长途运输,符合防潮、防震、防尘要求,因包装、运输不当引起的锈蚀、损伤等由供方负责。
五、交货地点及运输、装卸费用承担:
1.交货地点:需方工厂仓库或指定地点 。
2.运输、装卸费用:由供方承担。
六、价格及付款方式:
1.供、需双方均应不断改进,通过提高质量与效率来降低成本及价格,并让利给最终客户,双方确认努力保持这种降低成本的趋势,每年至少检讨一次价格。
2.供方报价中含有模具费的产品,在需方购满规定数量后,供方应自动下调采购价格。
3.供、需双方同意在本合同明确的交货条件及付款条件下,共同遵守经买方批准的价格。
4.付款条件:月结 天,结算日期以供方产品入库后,需方在每月 日前收到供方提供的正本发票开始计算(收到发票日期以签收单为准)。
七、交货及验收:
1.供方须按需方要求定量包装,并按订单要求的交货时间将货物送至指定地点,并附上《送货清单》及供方的出货自检报告或证明(必要时需提供第三方检测的材料性能测试报告)供需方备查。《送货清单》须列明需方订购单号及物料信息(制造批号、物料名称、材质、规格、颜色、数量等)。
2.需方依据双方约定的品质标准、技术要求和检测方案,并参照原封样件的要求进行检验和判定是否合格。
3需方检测不合格应及时通知供方,供方如对检测结果有异议,应及时向需方提出书面申请意见复检,否则视同接受。
4.虽已检验合格入库,但在需方装配和使用过程中发现的不合格品,供方仍应承担质量责任,并及时配合需方采取有效措施予以补救,以满足需方正常生产的需要。
5.需方对供方产品所行使的检验,并不能免除供方对产品质量的责任。
八、供方违约责任:
1.供方不能交货的,应向甲方偿付不能交货部分货款的 %(标准件、通用件产品的幅度为3-5%,非标准件、专用件的幅度为10%-30%)的违约金。并赔偿由此而给需方造成的损失费用。
2.供方交付的产品品种、型号、规格、颜色等质量不符合合同规定的,如果需方同意利用,应当按质论价;如果需方不能利用的,应根据产品的具体情况,由供方负责挑选、返修或退换,所发生的费用由供方负责;如使用紧急需挑选、返修时,则供方应立即组织挑选、返修或需方直接组织挑选、返修,因此发生的费用由供方承担(人工费:10元/小时•人);供方不能返修或调换的,按不能交货处理。
3.供方因产品包装不符合规定,必须返修或重新包装的,供方应负责返修或重新包装,并承担支付的费用,需方不要求返修或重新包装而要求赔偿损失的,供方应当偿付需方该不合格包装物低于合格包装物的价值部分,因包装不符合规定造成货物损坏或丢失的,供方应当负责赔偿。
4.供方逾期交货的,供方必须事先与需方联系,说明原因和解决方案,并获得需方同意后方可实施,并向需方支付逾期交货的违约金,违约金按逾期交货部分货款的同期人民银行贷款利率计算,供方还须赔偿因逾期供货而给需方造成损失的费用。
5.供方提前交货的产品、多交的产品和品种、型号、规格、颜色等质量不符合规定的产品,甲方在代保管期内实际支付的保管、保养等费用以及非因需方保管不善而发生的损失,应当由供方承担;供方提前交货,需方接货后,仍可按合同规定的交货时间付款,合同规定自提的,需方可拒绝提前提货。
6.因供方产品不合格进行挑选、返修或退换,而造成需方生产停工待料时,需方有权视情况严重程度进行罚款,每延误一个工作日处以至少壹仟元罚款,延误需方出货期而需空运或遭到需方客户延误交期索赔的费用由供方承担。
7.因供方提供需方的产品质量问题导致需方客户投诉,造成需方损失的,需方对其有形损失(费用、索赔)及无形损失(公司信誉)进行核算后,以书面通知供方,经供方对质量问题确认后从供方货款中扣除,如供方对质量问题有异议,可提交合同签订地所在质量技术监督局进行质量鉴定。
九、需方违约责任:
需方如不能按合同规定付款期支付供方货款,须事先与供方联系,说明原因及解决方案,获得供方同意后,并向供方支付逾期付款违约金,违约金按逾期付款金额同期人民银行贷款利率计算。
十、保密条款:
1.在未取得双方事先许可的情况下,不得将本协议内容向第三方公开或泄露。
2.供方从需方得到的图纸、规格书、技术文件、模具和样品等,未经需方同意,供方不得向第三者转让、公开、泄露或被使用。
3.供方绝不允许把需方提供的图纸、技术文件和模具转让给第三方加工、制作产品出售,其所造成的后果,均由供方负全部责任。
4.本规定在本合同终止后继续有效。
十一、合同解除:
1.供方有以下任何事项时,需方不需要任何通知,可马上解除本合同:
A.违反本合同条款约定的行为或事实时;
B.在供应期间内,不能满足需方数量及品质要求无能力供应时;
C.被政府机关停止或取消营业资格给予处分时。
2.协议一旦解除,供方接到需方通知后,应立即归还需方所提供的模具、图纸、技术文件等,并偿还一切债务。
3.因违反合同条款造成需方损失的,需方有权要求供方赔偿损失。
十二、合同纠纷解决:
供、需双方之间产生有关本合同的一切纠纷,双方应通过友好协商解决,如果协商不能解决,双方当事人可向合同签订地人民法院提出诉讼。
十三、合同期限:
本合同经双方签章后,即刻生效。本合同一式两份,供、需双方各执一份。
合同期限为: 年 月 日至 年 月 日鉴于供、需双方合作的长期性和稳定性,在本合同期满前三个月内,如合同一方提出需延长合同的有效期,经另一方确认后可延长合同期限。
十四、合同所有附件是本合同不可分割的组成部分,具有同等法律效力。
本合同未尽事宜,应由双方共同协商,作为补充合同,补充合同与本合同具有同等效力。
甲方(公章):_________ 乙方(公章):_________
法定代表人(签字):_________ 法定代表人(签字):_________
_________年____月____日 _________年____月____日