0

建设银行授权委托书范本【实用20篇】

浏览

7554

范文

142

建设工程委托监理合同中英文_合同范本

范文类型:委托书,合同协议,适用行业岗位:工程,全文共 35462 字

+ 加入清单

建设工程委托监理合同(中英文

contractregistration no: ______    _____

合 同  登 记  号:

supervision contract

for construction project

建设工程委托监理合同

project name:

工程项目名称:

entrustor (client):

委托方:  (业主)

service provider: shanghai tongji project management       (supervisor)        and consulting co. ltd.

服务方:    (监理人)

place of signing:

签订地点:

date of signing:

签订时间:

valid period:

有效日期:

shanghai, p. r. china

中国,上海

XX年  月  日

supervision contract for constructionproject

建设工程委托监理合同

part iagreement

第一部分 建设工程委托监理合同

this agreement is signed between                                 (hereinafter referred to as "theclient") and shanghai tongjiproject management and consulting co. ltd. (hereinafter referred toas the "supervisor") through mutual consultation.

委托人      与监理人---------    经过双方协商一致,签订本合同.

i.    brief information of the project for which the client desires thosesupervision services should be performed by the supervisor (hereinafterreferred to as "the project") is as follows:

委托人委托监理人监理的工程(以下简称"本工程")概况如下:

project name:

工程名称:               908新基地建设项目

projectlocation:

工程地点:          重庆北部黄茅坪组团经开园b04地块

project size:        about  185252 m2

工程规模:             约185252 m2

totalinvestment:     about           yuan rmb

总投资:           约       万元人民币

ii.    in this agreement words shall have the same meanings as areassigned to them in part ii of this supervision contract (hereinafter referredto as “the contract”) - standard conditions.

本合同的有关词语含义与本合同第二部分>中赋予它们的定义相同.

iii.       the following documents shall be deemed to form part of thisagreement:

下列文件均为本合同的组成部分:

(1)        this agreement;

此协议书;

(2)        standard conditions of the contract;

本合同标准条件;(条款)

(3)        conditions of particular application;

本合同专用条件;( 条款)

(4)        supplementary documents and amendments jointly signed by the twoparties during the execution of the contract.

在实施过程中双方共同签署的补充与修正文件.

⑸  监理人在报价时确定的的拟派现场监理人员名单和现场监理人员进场计划作为本合同附件。

iv.     in consideration of the payment to be made by the client to thesupervisor as hereinafter mentioned, the supervisor hereby covenants with theclient to perform supervision services in the scope as stated in the conditionsof particular application in conformity with the provisions of the contract.

考虑到以下提到的委托人向监理人的付款,监理人向委托人承诺,按照本合同的规定,承担本合同专用条件中议定范围内的监理业务.

v.      the client hereby covenants to pay the supervisor, inconsideration of the performance of the supervision services, such amount asmay become payable under the provisions of the contract at the times and in themanner and currency type prescribed by the contract.

考虑到监理人提供的监理服务,委托人向监理人承诺按照本合同注明的期限,方式,币种,向监理人支付报酬.

inwitness whereof the parties hereto have caused this agreement to beexecuted from april, to october, . if for any reasons the project stops for more than one month uninterrupted, the ending date will be postponedwith same periods.

本合同自施工单位进场时开始, 至整个工程竣工验收止完成. 如果项目进行中,被停止连续时间超过一个月,完成时间应该被顺延。

this agreement has sixsets of original copies, they have the same legal effect, and each party shallhold three copies.

本合同一式 陆 份,具有同等法律效力, 双方各执 叁 份.

the client:

委托人:

(seal)

(签章))

the supervisor:     shanghai tongji project                                   management and                                      consulting co. ltd.

监理人:

(seal)

(签章)

address:

住所:

address:     73 chifeng road

shanghai, XX92

住所:             上海市赤峰路73号,XX92

legal representative: (signature)

法定代表人: (签章)

legal representative: (signature)

法定代表人: (签章)

principal bank:

开户银行:

principal bank:

开户银行: 交行赤峰路支行

bank account no.:

10017215-09300007736

帐号:

bank account no.:

帐号: 310066344010141052919

tel.

电话:

tel.           8621 65989931

电话:        8621 65989931

this contract is signedon   ,

本合同签订于: XX年 -- 月  日

part ii    standardconditions

第二部分    标准条件

definitions,applicable languages and laws词语定义, 适用语言和法规

article 1  the following words and expressions shall havethe meanings assigned to them except where the context otherwise requires:

第一条 下列名词和用语,除上下文另有规定外,具有如下所赋予的含义:

(1)          "project" means the projectfor which the supervision services are to be provided.

"工程" 是指实施委托人委托监理人监理的工程。

(2)          "client" means the party whois responsible for the direct investment and who employs the supervisor, andlegal successors to the client.

"委托人"是指承担直接投资责任和委托监理人的一方,以及其合法继承人。

(3)     "supervisor" means the party whois employed by the client to perform supervision services and assumesupervision liabilities, and legal successors to the supervisor.

"监理人"是指受委托人委托承担监理业务和监理责任的一方,以及其合法继承人.

(4)                 "supervision team"means the group of staff sent by the supervisor to carry out supervision on thesite of the project.

"监理机构"是指监理人派驻本工程现场实施监理业务的组织.

(5)                 "chief supervisionengineer" means the person certificated by the local authority as  chief supervision engineer and designated bythe client and supervisor to be fully responsible for supervising the executionof the contract.

"总监理工程师"是指经当地政府部门认证为的总监理工程师并且由委托人及监理人指定对监督履行本合同全权负责的人.

(6)                 "contractor" meansthe person(s) other than the supervisor with whom the client signs contract inrelation to the construction of the project.

"承包人"是指除监理人以外,委托人就本工程的建设有关事宜签订合同的当事人.

(7)                 "normal services"means the scope of supervision work prescribed in the conditions of particular application.

"正常工作"是指双方在专用条件中约定的监理工作的范围.

(8)                 "additional services"means: 1) works outside of the scope of supervision work, and added to thecontract by written agreement of the parties; 2) additional works as a resultof addition to the scope of construction work or program delay on the part ofthe client or the contractor.

"附加工作"是指: 1)监理工作范围以外,通过双方书面协议另外增如本合同的工作;2)建设工作范围的增加或者由于委托人或承包人原因致使进度的延误,而造成的附加的工作.

(9)                 "exceptionalservices" means the works other than the normal services and theadditional services, but which are necessarily performed by the supervisor inaccordance with article 33.

"额外工作"是指正常工作和附加工作以外,根据第三十三条规定监理人需要完成的工作。

(10)        "day" means the period betweenany one 0:00 a.m. and the next.

"日"是指任何一个零时至第二天零时的时间段.

(11)               "month" means a periodof one month according to the gregorian calendar commencing with any day of themonth.

"月"是指根据公历从一个月份中任何一天开始的一个月的时间段.

article2  this supervision contract shall begoverned by chinese laws, statutes, administrative regulations, anddepartmental rules & regulations, local laws, rules & regulationsspecified in the standard conditions and conditions of particular application.

第二条   本建设工程委托监理合同适用的法律是中国的法律,条例,行政法规,以及标准条件及专用条件中载明的部门规章或地方法规,地方规章。

article 3  the contract shall be written in both englishand chinese, both of which shall be equally binding.

第三条   本合同应以中文和英文记载,中英文应具有同等效力。

obligations of the supervisor监理人的义务

article 4 the supervisor shall designate the supervision team andsuperintendents necessary for carrying out the supervising works; provide tothe client a name-list of the chief supervision engineer, main staff of thesupervision team and a supervision plan and perform the supervision serviceswithin the scope of work as stated in the conditions of particular application.during the execution of the contract, the supervisor shall submit supervisionreport to the client at regular interval as stated in the contract.

第四条 监理人应派出监理工作需要的监理机构及监理人员,向委托人报送委派的总监理工程师及其监理机构主要成员名单,监理规划,完成监理合同专用条件中约定的监理工程范围内的监理业务。在履行本合同义务期间,应按合同约定定期向委托人报告监理工作。

article5  thesupervisor shall exercise reasonable care and diligence, provide advice at anappropriate level in the performance of the obligations under the contract tothe client and indemnify the lawful rights and interests of various parties.

第五条   监理人应认真,勤奋地工作,在履行合同义务时为委托人提供与其水平相应的咨询意见,公正维护各方的合法权益。

article6  any facilities and articles supplied by theclient for use by the supervisor shall be properly used and maintained andremain the property to the client . when the services are completed orterminated the supervisor shall deliver to the client such facilities andunconsumed articles in good working order.

第六条   监理人使用委托人提供的设施和物品属委托人的财产,应恰当使用和维护。在监理工作完成或中止时,应将其设施和剩余的物品完好地移交给委托人。

article7  during thecontract period or after the contract is terminated, without the consent of theclient, the supervisor shall not disclose the confidential information inrelation to the project and the contract.

第七条   合同期内或本合同终止后,未征得委托人同意,不得泄露与本工程和本 合同有关的保密信息。

obligationsof the client

委托人的义务

article 8  the client shall pay anadvance payment to the supervisor prior to the commencement of the services ofthe supervisor, if such advance  payment is stated in the conditions ofparticular application.

第八条       委托人在监理人开展监理业务之前应向监理人支付预付款,如果该预付款在专用条件中陈述。

article 9  the client shall beresponsible for all coordination of external relationships in relation to theconstruction of the project. if the client assigns part or all of suchcoordination works to the supervisor as is necessary, then the work to beassigned and relevant terms of remuneration shall be specified in thesupplemental clauses.

第九条       委托人应当负责本工程建设的所有外部关系的协调(监理人所属协调关系除外)。根据需要,如需将 部分或全部协调工作委托监理人承担,则需在补充条款中明确委托的工作和相应的报酬条款。

article 10  theclient shall, within the agreed time, provide to the supervisor free of chargeall information pertaining to the project and necessary for the supervisionservices.

第十条       委托人应当在双方约定的时间内免费向监理人提供与本工程有关的并为监理工作需要的所有信息。

article 11 on all matters properly referred to him in writing bythe supervisor, the client shall give his decision in writing within the timespecified in the conditions of particular application of the contract.

第十一条   委托人应当在专用条件约定的时间内就监理人向委托人以恰当的书面形式提交的一切事宜作出书面决定。

article 12  the client shall appoint aclients representative (to be specified in the conditions of particularapplication) who is familiar with the project and able to make decision withinspecified time for the purpose of contacting the supervisor. should theclients representative be replaced, the client shall notify the supervisor inadvance.

第十二条   委托人应当授权一名熟悉本工程情况,能在规定时间内作出决定的委托人的代表(将在专用条件中明确)负责与监理人联系,更换委托人代表要提前通知监理人。

article13  the client shall timely notify theawarded contractor, in writing, of the power of the supervisor, roles andauthorities of main staff of the supervisor. such information shall be madeclear in the contract signed by the client and any third party.

第十三条      委托人应当将授予监理人的监理权利,以及监理人主要成员的职能分工及监理权限及时书面通知已选定的合同承包商,并在与任何第三方签订的合同中予以明确。

article14  the client shall notify to contractorto provide the following information to the supervisor within such a time thatthe supervisors work will not be hampered:

第十四条      委托人应通知承包人在不影响监理人开展监理工作的时间内向监理人提供如 下资料:

(1)   listof suppliers & manufacturers of the raw materials, components and parts,mechanical equipment etc. to be used in the project;

与将用于本工程的原材料,构配件,机械设备等的供应和生产厂家名录;

(2)     list of coordinators, cooperators inrelation to the development of the project.

提供与本工程有关的协作人,配合人的名录。

article15  the client shall furnish free ofcharge (including utility fees ) to the supervisor the site office,telecommunication connection, accommodation and other facilities specified in the conditions of particular application.

第十五条      委托人应免费(包括使用费)向监理人提供办公场所、通讯接口,网路接口住宿及合同专用条件约定的其他设施。

article16  given certain circumstances, if thetwo parties agree that the client shallarrange at his own expense for the provision of other personnel to thesupervisor, such agreement shall be reflected in the conditions of particularapplication.

第十六条      根据情况需要,如经双方同意委托人将可以自费向监理人提供其他人员, 应在合同专用条件中予以反映。

rights of the supervisor

监理人的权利

article 17  the supervisor should  havethe following rights within his scope of work. it is hereby understood that anyand all of the following activities shall also be considered as the obligationof the supervisor, who shall perform the following activities whenever it isneeded in order to ensure completion of the project in the best possible mannerand according to the relevant contractual documents and applicable laws:

第十七条      监理人在委托的工程范围内应具有以下权利, 而且在此双方确认任何如下活动也应作为监理人的义务,即其有义务在有必要的情况下为了以最好的方式并以符合全部合同文件和适用的法律的方式完成本项目的目的而进行如下活动。

(1) the right andobligation to make recommendations on the selection of the general contractor

(1)        选择工程总承包人的建议权和义务;

(2) the right andobligation to make recommendations on the selection of the sub-contractor

(2)        选择工程分包人的建议权和义务;

(3)the right and obligation to make recommendations to the client in the respectsof the project including project size, design standard, planning design,technological design and performance requirements.

(3)对工程建设有关事项包括工程规模、设计标准、规划设计、生产工艺设计和使用功能要求,向委托人的建议权和义务;

(4)the right and obligation to advise, in the principles of safety and optimum,the client on the technical problems in the design. if the design is found tobe not in conformity with the quality standards promulgated by the state orspecified in the design contract, the supervisor shall report to the client inwriting.

(4)对工程设计中的技术问题,按照安全和最优化的原则,有权利和义务向委托人提出建议.当发现工程设计不符合国家颁布的建设工程质量标准或设计合同约定的质量标准时,监理人应当书面报告委托人. 并提供处理方案

(5)the right and obligation to review the construction management plan and thetechnical proposal and to  makerecommendation to the client for changes that the contractor could implement toensure quality, on-time completion and cost reduction.

(5)对审查工程施工组织和技术方案, 按照保质量、保工期和降低成本的原则, 并就承包人有可能采取的变化监理人有权利和义务向委托人提出建议并提供处理意见.

(6)   conduct appropriate arrangement andco-ordination with relevant organisations, which can exert beneficial influenceto the development of the project. for all such matters the supervisor shallfirst report to the client in advance and seek the authority of the client tomake such arrangements and co-ordination.

(6)主持工程建设有关协作单位的组织协调, 对于所有协调项应当事先向委托人报告,并要求委托人授权以进行组织协调工作.

(7)   having obtained the consent of the client,the supervisor has the right to give command with regards to commencement,suspension and resumption of the works. but before doing so, he shall report tothe client.  the client’s representativewill be available for contacting in phone to discuss emergency and other matters.

(7)征得委托人同意,监理人有权发布开工令,停工令,复工令,但应当事先向委托人作出书面报告.委托人代表将可以随时电话联系到以就紧急情况和其他事宜与监理人进行研究.

(8)   right and obligation to check and inspect thematerials to be used in the project and quality of construction and to advisethe contractor immediately of any non-conformities. should the contractorcontinue to use the materials after the non-conformity has been identified,then the supervisor must advise the client that the contractor should stopusing them. for materials, components and parts, equipment that are not in conformitywith the design requirements, provisions of the construction contract andnational quality standards, the supervisor has the right to notify the clientthat the contractor should stop using them; for working sequence, divisionaland sub-divisional works that are not in conformity with relevant codes andquality standards, and construction operations that pose safety concerns, thesupervisor has the right to notify the client that the contractor should  stop and make corrections or redo the works.the contractor can resume construction only after he has received the workresumption command from the supervision team via the client..

(8)工程上使用的材料和施工质量的检验权和义务.发现不合格材料应通知承包方,如果承包人在接到通知后仍继续使用该不合格材料, 监理人必须及时通知委托人, 让承包人不得继续使用. 对于不符合设计要求和合同约定及国家质量标准的材料,构配件,设备, 监理人有义务通知委托人让承包人停止使用;对于不符合规范和质量标准的工序,分部分项工程和不安全的施工作业, 监理人有义务及时通知委托人,监理人有权让承包人停工整改,返工. 承包人只有通过委托人收到监理机构发出复工令后才能复工.

(9)rights and obligation to check, supervise the progress of theconstruction.  right to ratify that theactual completion is ahead or behind the completion date specified in theconstruction contract.

(9)工程施工进度的检查、监督权和义务,以及工程实际竣工日期提前或超过工程施工合同规定的竣工期限的签认权和义务;

(10)right and obligation to check and certify by signature that the payment to theconstruction contractor is within the scope of the construction contract, torecheck, confirm, and negate to the settlement of the accounts. without thesignature and confirmation from the chief supervision engineer, the client willnot make payment to the construction contractor.

(10)在工程施工合同约定的工程价格范围内,工程款支付的审核和签认权和义务,以及工程结算的复核确认权与否定权。未经总监理工程师签字确认,委托人不支付工程款。

article 18 during supervision, if theemployee(s) of the contractor is found to be incapable of his job, thesupervision team shall notify the client of the views of the supervision teamon this matter.

第十八条在监理过程中如发现工程承包人员工作不力, 监理机构应将其对此事的观点告知委托人.

article 19 within the scope of work,if the client and the contractor have any dissent and requirement (includingclaim) to each other, and where such dispute is being mediated by an administrativedepartment in charge of construction or being arbitrated by arbitration body(china international economic and trade arbitration commission, shanghai), thesupervisor shall provide relevant proof.

第十九条 在委托的工程范围内,当委托人和承包人对对方有任何意见和要求(包括索赔要求),双方争议由政府建设行政主管部门调解或仲裁机关(中国国际经济贸易仲裁委员会-上海[h1] )仲裁时,监理人应当提供相关证明。

rightsof the client

委托人的权利

article20  the client has the right to appointthe  contractor and enter into a contractwith that contractor.

第二十条      委托人有选定工程承包人,以及与其签订合同的权利。

article21  the client has the right to decidethe project size and agree the design standard, planning design, technologicaldesign and designed performance requirements; and the right to approveconstruction cost, programme and design variation.

第二十一条         委托人享有对工程规模、设计标准,规划设计、生产工艺设计 和设计使用功能要求的认定权,以及对工程造价、进度计划和设计变更的审批权。

article 22  in the event that the supervisor want to replace the chief supervisionengineer, he shall obtain the client’s consent in advance during the contractconducting period.

第二十二条         在履行本合同期间,监理人调换总监理工程师须事先经委托人同意。

article23  the client has the right to requirethe supervisor to submit  supervisionreport and specific report in each discipline within the supervisor’s scope ofwork..

第二十三条 委托人有权要求监理人提交监理工作报告及监理人业务范围内的专项报告。

article 24  in the event that the client find the supervisor’s staff fails to performduties under the contract, or cause any loss to the project or the clientthrough collusion with the contractor, the client shall be entitled to requirethat such staff be replaced by the supervisor or even terminate the contractand demand the supervisor to assume responsibilities or contiguousresponsibilities in paying compensation.

第二十四条 当委托人发现监理人的职员不按本合同履行监理职责,或与承包人串通给本工程或委托人造成任何损失的,委托人有权要求监理人更换该职员,直到终止合同并要求监理人承担相应的赔偿责任或连带赔偿责任。

liabilities of the supervisor监理人的责任

article25  the supervisor’s liability period isthe valid period of the contract (contract period), including the maintenanceperiod. in the event that the project programme is postponed or delay whichresults in the contract period to be extended, the two parties shall makefurther negotiation to agree an extension of the contract period.

第二十五条         监理人的责任期即本合同有效期(合同期),包括维护期。如果因工程进度的推迟或延误而导致合同期将要延长,双方应进一步协商约定的延长合同期。

article26  the supervisor shall perform hisduties during the contract period. should any financial loss be caused by thefault of the supervisor, he shall pay compensation to the client. accumulatedamount of compensation (except for the compensation specified in article 24)shall not exceed the total payment by the client to the supervisor (excludingincome tax).

第二十六条         监理人在合同期内,应当履行约定的责任。如果因监理人过失而造成了委托人的任何经济损失,其应当向委托人赔偿。累计赔偿总额(除第二十四条规定的赔偿以外)不应超过委托人向监理人支付的报酬总数(除去税金)。赔偿按相关法律执行[h2]

article27  the supervisor shall be notresponsible for any contractor’s nonconformity in quality requirements andcompletion time (for submitting drawings or delivery of goods). in the event ofany force majeure which cause part or all of the execution of the contract tobe impossible, the supervisor shall not be held responsible. but for anyinfringement to article 5, the supervisor shall pay compensation to the client.

第二十七条         监理人对承包人违反施工合同规定的质量要求和完工(交图、交 货)时限,因监理人失责应承担相应的责任,因不可抗力导致本合同不能全部或部分履行,监理人不承担责任。但对违反第五条规定引起的与之有关的事宜,应向委托人承担赔偿责任。

article28  if the claim made by the supervisorto the client cannot be justified, the supervisor shall be responsible for anycost incurred by the client in relation to the claim.

第二十八条       监理人向委托人提出赔偿要求不能成立时,监理人应当补偿由 于该索赔所导致委托人的任何费用支出。

liabilities of the client委托人的责任

article29  the client shall carry out his dutiesas stated in the contract. the client shallbe liable to the supervisor if a breach of his duty to the supervisor isestablished against the client, and shall pay compensation for the supervisor’sdirect financial loss.

第二十九条 委托人应当履行本合同约定的义务,如有违反则应当承担违约责任,赔偿给监理人造成的直接经济损失。

article30 if the claim made by the client to thesupervisor cannot be justified, the client shall be responsible for any costincurred by the supervisor in relation to the claim.

第三十条 委托人如果向监理人提出赔偿的要求不能成立,则应当补偿由该索赔所引起的监理人的各种费用支出。

commencement, alteration and termination of the contract本合同的开始、变更与终止

article 31 if  the normal services are impeded or delayed bythe client or the contractor so as to incur additional services or increase theduration of the normal services, the supervisor shall timely inform the clientof the circumstances and probable effects. the time for completion of theservices shall be increased accordingly and the supervisor shall be remuneratedfor such additional services.

第三十一条  由于委托人或承包人的原因使正常的监理工作受到阻碍或延误,以致发生了附加工作或延长了正常监理工作的持续时间,则监理人应当将此情况与可能产生的影响及时通知委托人。完成监理业务的时间相应延长,并得到附加工作报酬。

article 32 if circumstances arise which make it legally or physically impossible forthe supervisor to perform in whole or in part the services in accordance withthe contract he shall promptly dispatch a notice to the client. the time forthe completion of the services shall be extended. when the services are resumed,a reasonable period not exceeding 42 days for resumption shall be added and theclient shall pay the supervisor as agreed between them.

第三十二条         如实际情况发生变化,使得监理人由于法律原因或实际原因不能根据本合同全部或部分执行监理业务时,监理人应当立即通知委托人。经委托人认可,该监理业务的完成时间应予延长。当恢复执行监理业务时,应当增加不超过42日的时间用于恢复执行监理业务,并按双方约定的数量支付监理报酬。

article 33 after the supervisorhas finalized the acceptance check or handover procedures with the client, andthe contractor has signed a defect liability agreement with the client, thesupervisor has received all the payments due from the client, this contractshall be deemed to come to an end, except for any clauses referring to theparties’ liabilities, which may be used, according to statute of limitationsstipulated by the law, for claiming compensation. as to liabilities during thedefect liability period, the two parties can make provisions in the conditionsof particular application.

第三十三条  监理人向委托人办理完竣工验收或工程移交手续,承包人和委托人已签订工程保修责任书,监理人收到所有监理报酬,本合同即终止,除了有关双方的责任的条款,其应可按照相关法律的时效期限用以索赔。保修期间的责任,双方在专用条件中约定。

article 34 if either party hereto wishes to alter or abandon thecontract, he shall notify the other party in 42-day advance. if loss is causedto the other party as a result of the abandonment of the contract, theresponsible party shall pay compensation except for circumstance where hisresponsibility can be remitted in accordance with laws.

第三十四条         当事人一方要求变更或解除合同时,应当在42[h3] 日前通知对方,因解除合同使另一方遭受损失的,除依法可以免除责任的外,应由责任方负责赔偿,

article 35 if the supervisor has not received a paying voucher within 30 days fromthe due date of payment and nor has he received any written explanation fromthe client, or the supervision services has been suspended for more than sixmonths, the supervisor can notify the client to terminate the contract. ifwithin 14 days from the date of notice the supervisor still has not receivedany response from the client, he can make further notice. if within 42 daysfrom the date of the second notice the supervisor still has not received anyresponse from the client, the supervisor can terminate the contract or suspendor continue suspending from performing all or part of his services at hisdiscretion. the client shall assume the responsibility for breach of contract.

第三十五条       监理人在应当获得监理报酬之日起30日内仍未收到支付单据,而委托人又未对监理人提出任何书面解释时,或根据第三十三条及三十四条已暂停执行监理业务时限超过六个月的,监理人可向委托人发出终止合同的通知,发出通知后14日内仍未得到委托人答复,可进一步发出终止合同的通知,如果第二份通知发出后42日内仍未得到委托人答复,可终止合同或自行暂停或继续暂停执行全部或部分监理业务。委托人承担违约责任。

article 36 if the supervisionservices are suspended or terminated due to causes not on the part of the supervisor, works required to resume services orpost-termination settlement works shall be deemed as exceptional services. theperformance of exceptional services shall entitle the supervisor to payment forperforming them.

第三十六条       监理人由于非自己的原因而暂停或终止执行监理业务,不可抗力除外,其善后工作以及恢复执行监理业务的工作致使监理工期延长,经委托人认可,应当视为额外工作,有权得到额外的报酬。

article 37 if in the opinion of theclient that the supervisor is not discharging his rights without justifiablereasons, he can inform the supervisor of such opinion. if within 21 days from the date of notice the client has not receivedany response from the supervisor, he can, within 35 days from the date of thefirst notice, inform the supervisor by notice to terminate the contract. thesupervisor shall assume the responsibility for breach of contract.

第三十七条       当委托人认为监理人无正当理由而又未履行监理义务时,可向监理人发出指明其未履行义务的通知。若委托人发出通知后21日内没有收到答复,可在第一个通知发出后35日内发出终止委托监理合同的通知,合同即行终止。监理人承担违约责任。

article 38 termination of the contract shall not prejudice or affectthe accrued rights and liabilities of the parties.

第三十八条       合同协议的终止并不影响各方应有的权利和应当承担的责任。

payment监理报酬

article 39  the remuneration for normal services,additional services and exceptional services shall be calculated in accordancewith article 9 of the conditions of particular application. the client shallpay the supervisor in accordance with the time and amount stated in thecontract.

第三十九条 正常工作、附加工作和额外工作的报酬,按照监理合同专用条件中第九条的方法计算,并按约定的时间和数额支付。

article 40  if the supervisor does not receive payment within the time specified heshall be paid compensation calculated from the last day of the specified payingperiod.

第四十条   如果委托人在规定的支付期限内未支付监理报酬,自规定之日起,还应向监理人支付滞纳金。滞纳金从规定支付期限最后一日起计算。

article 41  the currency, exchange rate applicable to thecontract is that stated in the conditions of particular application.

第四十一条 本合同适用的货币币种、汇率在专用条件中陈述。

article 42  if any item or part of an item in a paymentapplication submitted by the supervisor is contested by the client, the clientshall give notice with reasons within 24urs from receiving the application andshall not delay payment on the remainder of the invoice.

第四十二条 如果委托人对监理人提交的支付通知中报酬或部分报酬项目提出异议,应当在收到支付通知书24内向监理人发出表示异议理由的通知,但委托人不得拖延其他无异议报酬项目的支付。

others其他

article 43 under the consent of theclient, cost necessarily incurred by the supervisor for visits to cities otherthan shanghai on investigation purpose, testing of materials and equipment canbe reimbursed by the client, within the budget scope, as it actually happens.

第四十三条         委托人根据建设工程需要邀请的建设工程监理所必要的监理人员出外考察、材料设备复试,其费用支出经委托人同意的,在预算范围内向委托人实报实销。

article 44  within the scope of supervision services, if expert is needed to beemployed for consulting or assistance purposes, the supervisor shall bear suchcost when the expert is employed by him, the client shall bear such cost whenthe expert is employed by him.

第四十四条       在监理业务范围内,如需聘用专家咨询或协助,由监理人聘用的,其费用由监理人承担;在监理业务范围外由委托人聘用的,其费用由委托人承担。

article 45 if profit is generated forthe client as a result of recommendations made by the supervisor, the clientmay give bonus to the supervisor.

第四十五条       监理人在监理工作过程中提出的合理化建议,使委托人得到了经济效益,委托人在可以给予监理人经济奖励。

article 46 the on-site supervisionteam or its staff shall not accept any remuneration or money provided by thecontractor.

第四十六条       监理人驻地监理机构及其职员不得接受监理工程项目施工承包人的任何报酬或者经济利益。

the supervisor shall not take part inany activity that may have conflict with the interests of the client and withthe work to be performed according to this contract.

监理人不得参与可能与合同规定的与委托人的利益相冲突的任何活动。

article 47  the supervisor shall notdisclose any information that is declared by the client to be confidential. thesupervisor shall not disclose any information provided and declared to be confidentialby the designer or the contractor either.

第四十七条     监理人不得泄露委托人申明的秘密,监理人亦不得泄露设计人、 承包人等提供并申明的秘密。

article48  the supervisorretains copyright of all documents prepared by him.  the client shall be entitled to use them orcopy them only for the project.

第四十八条       监理人对于由其编制的所有文件拥有版权,委托人仅有权为本工程使用或复制此类文件。

settlement ofdisputes争议的解决

article 49  anyclaim for loss or damage arising out of breach or termination of the contractshall be agreed between the client and the supervisor or failing agreement shallbe referred to a governmental department in charge of construction formediation. if agreement still cannot be reached, the dispute shall be referredto the arbitration body agreed by the parties or start a prosecution in thepeople’s court.

第四十九条     因违反或终止合同而引起的对对方损失和损害的赔偿,双方应当协商解决,如未能达成一致,可提交主管部门协调,如仍未能达成一致时,根据双方约定提交仲裁机关仲裁,或向人民法院起诉。

part iii conditions of particular application第三部分 专用条件

article 1 laws applicable to the contract andrules & regulations and reference standard on which the supervision isbased are:

第一条 本合同适用的法律及监理依据的法规和标准:

1.      the construction contract

2.      this supervision contract

3.      the national and shanghai municipal laws,regulations and policies on the construction

4.      complete sets of constructiondrawings and related documents.

5.       current national regulations for constructioncode and the quality inspection, acceptance, and assessment standard/codes

6.      the specifications on theproject

7.      the supervision documents andprocedure on the project

8.      applicable laws and regulations

1、  工程施工承包合同。

2、  本工程施工监理合同。

3、  国家和上海市重庆市有关工程建设方面的法律、法规、政策和规定。

4、  设计图纸和其它有关文件

5、  现行的国家工程建设规范和质量检验评定标准。

6、  为本工程制定的有关技术文件及规定。

7、  为本工程制定的有关监理文件和程序。

8、相关法律法规。

article 2 the scope of supervision

第二条 监理工作内容

tosupervise the construction quality, progress, contract, and project information,to coordinate between the client and the general contractor, and to urge thegeneral contractor to construct in a safety and civilized manner. the detail ofthe supervision service is the follows,

负责本项目的建筑质量、进度、合同、项目信息管理,协调委托人与总承包方的关系,督促并检查施工单位安全文明施工, 监理工作具体有:

1. to assist the client to sign theconstruction contract

1.      协助委托人签订施工承包合同;

2. to assist the client and thecontractor to draw up the construction commencement report

2.      协助委托人与施工单位编写开工报告;

3. to organize the meeting on theconstruction drawing explanation and check

3.      组织设计交底与图纸会审;

4. to review the construction plan,scheme and the master schedule of the contractor

4.      审核承建单位提出的施工组织设计, 施工技术方案和施工进度计划;

5.to supervise the contractor to execute the construction contract and thenational technical and construction code, as well as the documents referred toat article 1 hereof, to deal with the contractor’s violation against theregulation or the code;

5.      对承建单位执行工程承包合同和国家工程技术规范标准,以及第一条所规定的文件的情况进行督促,检查,参与承包方违约事件的处理;

6.tocheck the list of the material and equipment of the contractor’s; to inspectthe raw material, semi-product, and parts which will be used in the project; toreject the disqualified material, parts and equipment against the constructioncontract and standard.

6.      审查承建单位提出的材料和设备清单, 对工程使用的原材料、半成品、构件、设备进行检查,有权拒绝使用不符合合同要求和标准规定的材料,构件,设备;

7.toinspect the construction progress and quality; to inspect and accept thedivisional, sub-divisional and concealed works; to evaluate the constructionprogress

7.      检查工程进度和施工质量,验收分部分项工程和各项隐蔽工程, 对工程进度进行评估。每周书面向委托人报告工程进度,每周组织召开施工例会。

8.toorganize the client, the designer and the contractor to handle the qualityaccident; to supervise the execution of the technical scheme for the qualityaccident; to inspect, accept and issue the certificate after the qualityaccident is settled.

8.      组织委托人、设计、施工单位处理工程质量事故并提供处理方案和责任划分方案, 监督质量事故技术处理方案的实施, 并对事故处理进行验收和签证;

9. to compile the supervisiondocuments and specifications for filing

9.      整理监理文件和技术档案资料;

10. to organize the designer and theconstruction contractor to pre-inspect and pre-accept for the constructioncompletion

10.  组织设计单位和施工单位进行工程竣工初步验收;

11. to assist the client to executethe completion acceptance.

11.  协助委托人进行竣工验收工作;

12. to submit the supervisionevaluation report for the project to the client .

12.  向委托人提交项目监理评估总结报告;

13.   to organize hse site service:safety strategy, site safety supervision, health control, security of site office.

13. 负责提供安全策略,现场安全监督,现场健康控制,以及现场办公室安全。

article 3 external conditionsinclude: the client is responsible for all the public relations andcoordination for the project including the local government and authorities

第三条   外部条件包括:委托人负责本工程建设的所有包括政府等在内的外部关系的协调;

article 4 project informationrequested by the supervisor should be provided by the client, where it isavailable, shall be issued beforehand.

第四条   对于监理人让委托人提供的工程资料,如果有,应事先提供。

article 5 on all matters properly referredto him in writing by the supervisor, the client shall give his decision inwriting within 5 days.

第五条   委托人应在5天内对监理人适当地书面提交并要求其作出决定的事宜作出书面答复。

article 6 the clientsrepresentatives are        。

第六条 委托人的常驻代表为      。

article 7 during the contract period, the client shall at his own cost provide, orarrange for the provision by others, of personnel to work within the client’sown site team.   the supervision teamshall co-operate with the client’s own team but shall not be responsible forthem or their performance or rely on them or their performance for any of theservices for which the supervisor is responsible.

第七条            在合同期间,委托人应自费提供或安排其他方提供人员组成委托人的现场工作组。监理机构应与委托人的现场工作组合作,但不对他们及其行为负责,也不依靠他们及他们的行为来开展监理人负责的工作。

第八条            监理人派驻现场的监理人员数量和人员资质,必须符合双方商定的人员表和分阶段专业人员进场计划表的规定。根据各阶段实际施工需要,监理人有义务根据委托人要求,在人员表人员的范围内调整和增加人员。委托人有权根据专业人员进场计划表进行人员资质检查和出勤考核。如发现有不符资质及缺员情况,将斟情扣发监理人报酬。

article 9 the supervisor agrees topay compensation if he fails to discharge his duties, [accumulated amount ofcompensation shall not exceed the total payment by the client to the supervisor(bar income tax ), except for the compensation specified in article 24 ofstandard conditions.

compensation fee =the direct loss xthe supervision fee’s charge rate (bar income tax). the supervision fee’scharge rate is equal to total supervision fee divided by total cost of theproject.

第九条            内如果失职,同意赔偿损失[累计赔偿额不超过监理报酬总数(扣税),本合同标准条件

第二十四款规定赔偿的情况除外。赔偿金=直接经济损失*报酬比率(扣除税金)报酬比率为监理费和项目总造价的比率。

article 10 the client agrees to pay thesupervisor for his normal services in an amount calculated in the following wayand at the following time:

第十条 委托人同意按以下的计算方法、支付时间与金额,就监理人提供的正常监理工作支付其报酬:

1.the supervision service period: start from the day, on which the supervisioncommencement notice is issued from the client, and the supervision serviceperiod (interim) is eighteen months

监理服务期:按委托人通知监理服务开始日起算,监理服务期(暂定)为18个月。

2. the supervision fee: fixed lumpsum during the above-said supervision service period(18months)is 1,480,000 rmb yuan.

监理服务费:在监理服务期(18个月)内的固定总价为: 148.0万元。

3. payment method:

支付时间与金额

1) the client should pay to the supervisor 15% of the fixed lumpsum within one week as of the signature date of this supervision contract.

1)合同签定日后一周内委托人向监理人支付监理费总价的15%;

2) then, the client shouldpay the supervisor another 15% of the fixed lump sum every two months (90days), and the number of the payment times is three (i.e. 75% of the fixed lumpsum fee).

2)随后,每三个月(90天),委托人向监理人另支付监理费总价的15%,共5次(计为监理费总价的75%)。

4) the client should paythe supervisor final 10% of the fixed lump sum within one week after theproject passes the completion acceptance examination.

4)工程竣工验收合格后一周内委托人向监理人支付最后的监理费总价的10%

4. the service fee beyond the above-said supervision service period:if the supervision service is beyond 18 months, the client will, on the monthlybase, pay the supervisor at the sum of 82,000 rmb yuan/month.

4. 监理服务期延长期的服务费用: 如果监理服务超过18个月,委托人要按工程内容和现场监理工作要求,合理支付费用,延长期监理费用由双方商定。

article 11 the parties hereto agree that the paymentshall be effected in rmb.

第十一条             双方同意用人民币支付报酬。

article 12 bonus clause; depending on mutualconsultation

第十二条             奖励办法:由双方协商解决

article 13 if a dispute arises betweenthe parties in connection with, or arising out of the contract, consultationshall be made promptly to find a solution. when consultation fails, the partiesagree to refer the dispute to an arbitration commission. the arbitration body shall be china international economic and trade arbitration center, shanghai branch.the arbitration language shall be chinese and english..

第十三条 本合同在履行过程中发生争议时,当事人双方应及时协商解决。协商不成时,双方同意由仲裁委员会仲裁。仲裁机构为中国国际经济贸易仲裁委员会上海分会,仲裁语言为中文和英文。

*

由法律部门定

[h2]由法律部门定

[h3]42天太长,由法律部门定

展开阅读全文

更多相似范文

篇1:项目建设管理委托合同范本

范文类型:委托书,合同协议,全文共 2876 字

+ 加入清单

委托方: (以下简称甲方)

受托方: (以下简称乙方)

根据《中华人民共和国建筑法》、《中华人民共和国合同法》及市政府颁布的《武汉市政府投资项目管理办法(试行)》(武政[20xx]6号)和《武汉市非经营性政府投资项目实行代建制管理办法(试行)的通知》(武政[20xx]7号)精神,遵照国家法律法规、平等、自愿、公平和诚信原则,经协商,甲方同意委托乙方实施全过程代建,全面负责该项目的建设管理。为了明确双方职责,特订立本合同,以资双方共同遵守:

一、工程概况

1、建设地点: ______

2、主要建设内容:

3、总投资及资金来源:

(按审定的预算执行)

4、工程质量:

5、建设工期:

二、委托事项 受托方应负责__________项目的建设管理。主要事项有:

1、负责组建代建项目部,制定工程代建大纲,在合同履行期间,按月、季向甲方报告代建工作情况;

2、负责招标代理、造价咨询、监理及建设过程的全过程代建管理;3、编制工程招标文件,组织建设工程施工及设备材料的招投标工作;

4、负责项目施工阶段设计技术交底、图纸会审以及施工单位施工组织计划的审核;办理现场变更及签证手续,并提出审核意见;

5、制定工期、质量、投资、安全、文明施工管理目标,并进行控制和检查;

6、协调各承包人(施工、专业分包等单位)的业务活动;

7、审查施工单位的施工进度计划并监督其执行,并按各承包人施工进度报告提出付款计划建议;

8、提出合理可行的施工技术措施以加快工程进度,保证现场安全;

9、主持现场施工管理例会,解决处理施工中存在的问题或提出合理化建议和整改措施;

10、协助甲方办理工程决算审计。

三、双方的职责、义务

(一)乙方的职责、义务

1、完成委托事项,实施委托事项完全符合国家及地方法规、法律及甲方的要求,做好建设项目三控二管一协调(三控:指控制投资、质量、工期;二管:指合同和信息的管理;一协调:指协调施工中有关各方关系)工作,确保建设工期、质量、安全目标实现;

2、负责申报办理本项目所需规划、土地、环境、供水供电、绿化、消防、城管、交管等有关手续;

3、做好该建设项目投资控制,科学的项目管理,提高投资效益,编制工程月进度计划并于每月25日(如遇节假日顺延)上报甲方;

4、工程竣工后负责向甲方提供3套竣工图和 3套工程竣工资料;

5、乙方必须按确定目标的标准进行管理,要求建设项目建筑质量等级为“合格”;6、严格按照招投标制和工程监理制,组织工程招标,择优选定承包单位。

7、严格按照甲方批准和审定的建设规模、功能、标准和概算组织建设,不得突破总投资。按照批准的进度组织实施,保证项目按合同规定的期限建成,并确保工程质量。

8、组织各单项工程的质量验收,负责按竣工验收制度申报项目竣工验收、移交等工作,将验收合格后的建设项目和完整的建设档案资料移交甲方和相关档案管理部门;

9、充分听取、尊重甲方的意见,争取甲方指导和全力支持,及时汇报项目建设过程中出现的重大问题。

(二)甲方的职责、义务

1、合同签定后,负责向乙方办理前期工作移交手续,负责提供建设期间各项建管手续报建所必需的政府有关部门批文及相关资料,负责协助乙方办理需要以甲方名义办理的有关建设报建等相关手续;

2、依法缴纳各种政策性费用及工程项目报建规费,依法交纳与本工程有关的各种税费;

3、在项目实施过程中,甲方对项目有重大调整意见时,应会同乙方共同协商达成一致意见后以书面形式通知乙方实施,如由此引起项目投资、规模、工期变化,由甲方承担相应责任;

4、对项目建设过程中的招投标、设备、材料选定的决策审定,对工程质量、进度、规模、标准及资金使用情况进行监督;

5、为乙方提供必需的现场办公条件,及时、足额提供项目建设中所需的各项建设资金,负责建设项目过程中的各项经济合同的会签及最终报价的审定等工作;

6、甲方有权要求乙方提供本工程施工形象进度、投资、质量控制报告;

7、参与竣工验收工作,与乙方办理工程固定资产、全套档案资料交接等手续,工程竣工验收合格后,在1个月内与乙方办理完成接收手续;

8、协助乙方办理施工用水、施工用电等有关手续,协调施工现场与周边环境及机构的关系,因甲方原因导致周边因素影响项目不能正常实施的由甲方承担相应责任。

四、合同价款的确定与支付

代建管理费:经双方协商取费费率为3%,取费基数以工程审计的总投资为准,在过程执行中,先暂按投资额240万元计费,合同签订后即支付暂定代建管理费的50%,工程完工支付余下的50%;监理费按国家取费标准另行签订合同。(监理费含在总投资范围内)

五、工程进度

1、工程开工以监理下达的开工令为开工日期;

2、乙方确保按甲方对各单项工程的实际进度要求,完成委托范围内的全部工作;

3、项目建设过程中,如甲方原因以及不可抗力等因素制约工程进度,造成工程延期则乙方管理工期相应须延,甲方承担相应工程延期而引起的相关责任及费用;

4、项目建设过程中,若因乙方原因造成工期延误则乙方承担相应的经济责任及处罚。

六、合同生效、变更与终止

1、本合同经双方签字盖章后立即生效;

2、由于甲方原因使项目管理工作受到阻碍或延误,以致发生了附加工作或延长了持续时间,则乙方应将此情况与可能产生的影响及时书面通知甲方,完成项目管理业务时间相应延长;

3、乙方办理完工程移交手续及全部的委托事项,本合同即行终止;

4、当事人一方要求变更或解除合同时,应当在15日前通知对方,因解除合同使一方遭受损失的,除依法可以免除责任外,应由责任方负责赔偿。变更或解除合同的通知或协议必须采取书面形式,协议未达成之前,原合同仍然有效;

5、当甲方认为乙方无正当理由而又未履行项目管理业务时,可向乙方发出指明其未履行义务的通知。若乙方不能做出合理书面答复,甲方可予以经济处罚,乃至解除合同并追究相应责任,若甲方发出通知7日内没有收到答复,可在第一个通知发出后15日内发出终止委托项目管理合同的通知。合同即行终止。乙方承担违约责任。

七、其它

1、甲方驻本工程建设现场总负责人为 ,乙方驻本工程建设现场代表为 ;

2、乙方驻地管理机构及其职员不得接受工程项目任何参建各方的任何报酬或经济利益。乙方不得参加合同规定与甲方的利益相冲突的任何活动;

3、乙方在项目管理过程中,不得泄露甲方申明的秘密,乙方亦不得泄露设计人、承包人等提供并申明的秘密;

4、乙方对于其编制的所有文件拥有版权,甲方仅有权为本工程使用此类文件;

5、现场管理办法及专业管理细则由双方现场代表协商制定;

6、乙方若将投资额控制在甲方确认的项目预算范围之内(不包括变更增加内容),甲方给予乙方工程节余资金的15%作为奖励;(按武政【20xx】7号文第21条执行)

7、本合同未尽事宜,双方可协商并另行签订补充协议,所签订补充协议与本合同具有同等法律效力。

八、争议的解决

因违反或终止合同而引起一方的损失和损害的赔偿,双方协商解决,如项目管理委托合同 未能达成一致时,可提交武汉仲裁委员会仲裁。

九、本合同一式肆份,双方各贰份。 甲方:(公章)

法定代表人: 乙方:(公章)

法定代表人:

委托代理人:

地址:

联 系 电 话:

传真:

展开阅读全文

篇2:房屋租赁授权委托书格式范本

范文类型:委托书,全文共 457 字

+ 加入清单

甲方(委托方):______________

乙方(受托方):______________

甲方因人在外地,特将房屋委托乙方代为出租及管理。经甲乙双方友好协商,现明确甲方房屋租赁授权委托的具体事项如下:

一、乙方有义务对甲方的委托房屋及相关的资信严格保密。

二、房屋信息

1、甲方房屋(以下简称该房屋)坐落于;共_______层第_______层。

2、房龄:_______年;房间数量:_______;卫生间数量:_______;总建筑面积:_______平米;房屋朝向:_____;装修情况:______________;房屋用途:______________。

三、委托权限

1、该房屋的出租和日常管理;

2、该房屋的相关设施设备的维护与管理。

四、经甲乙双方签字确认后,该委托授权书即生效。

委托方(甲方):______________受托方(乙方):______________

身份证号:______________身份证号:______________

房产证号:______________

电话:______________

展开阅读全文

篇3:个人授权委托书格式范本

范文类型:委托书,适用行业岗位:个人,全文共 250 字

+ 加入清单

个 人 授 权 委 托 书

委托人:姓名_________身份证编号__________________________ 受托人:姓名_________身份证编号__________________________ 兹委托受托人____________为我的代理人,全权代表我办理____________相关事宜。代理人在其权限范围内签署的一切有关文件,我均予承认,由此在法律上产生的权利、义务均由委托人享有和承担。 代理人有(或无)转委托权。

委 托 人: (签名或盖章)

_____年____月___日

展开阅读全文

篇4:最新授权委托书格式范本

范文类型:委托书,全文共 249 字

+ 加入清单

委托人:ⅹⅹ房屋建设开发有限公司,

住所:ⅹⅹ县ⅹⅹ镇ⅹⅹ路61号,

法定代表人:张ⅹⅹ,该公司董事长。

受委托人:,男,贵州恒易律师事务所律师,执业证号:,联系电话:

委托人现委托上列受委托人作为委托人与ⅹⅹ建设工程有限公司执行纠纷案的执行代理人,代为申请执行被执行人的财产。

上列受委托人的代理权限为:

1、代为申请执行;

2、代为进行执行和解;

3、代为领取执行标的物、财产(包括领取现金);

4、代为调查、提供被执行人的财产线索;

5、代为签收有关法律文书。

委托人:ⅹⅹ房屋建设开发有限公司

时 间: 年 月 日

展开阅读全文

篇5:法人授权委托书范本_委托书_网

范文类型:委托书,适用行业岗位:法人,全文共 862 字

+ 加入清单

法人授权委托书范本三篇

法人授权委托书范本一:

X有限公司

法人授权委托书

第 号

联系单位:

受委托人: (性别: 年龄: 职务: ) 委托范围:联系、洽谈 工程业务,参加招投标事宜。 委托权限:在委托范围内,依照国家有关法律、法规及法定程序全权处理。 委托期限:年 月 日至 年 月 日

年 月 日

X有限公司

法人授权委托书范本二:

[ ]第 号

兹有我单位 同志(性别: 年龄: 职务: )代表我方与贵单位联系、洽谈及建设 工程业务。法人授权委托书委托范围:联系、洽谈、建设工程业务。

授权权限:在委托范围内,依照国家有关法律、法规及法定程序全权处理。

有效期限: 年 月 日至 年 月 日 代理人无转委托权,特此委托!

此致

敬礼

法人单位(盖章) 法人代表(盖章)

年 月 日

法人授权委托书范本三:

中国xx银行 (网点全称): 我单位(公司)现委托下述受委托人作为我方代理人到你行办理以下业务: 委托人:

法定代表人:

企业(单位)名称:

受委托人之一:

姓名: 性别:

证件类型: 证件号码:

受委托人之二:

姓名: 性别:

证件类型: 证件号码:法人授权委托书一、授权权限:

现委托上述受委托人作为我方的代理人。代理权限为:

(一)代理我方办理我方在你行开立的以下账户的电子银行业务

□申请注册;□注销;□信息变更;□证书挂失;□补办;□更新;□证书与密码信封领取;□其他____________事项(入选项打“√”,不选项打“×” ):

1、

2、

3、(二)代理我方向上述银行领取我方企业网上银行的管理员、操作员证书两码信封。需领取两码的管理员及操作员的相关信息如下: 管理员: (证件名称: 证件号码: ) 操作员: (证件名称: 证件号码: )

操作员: (证件名称: 证件号码: ) 操作员: (证件名称: 证件号码: ) 操作员: (证件名称: 证件号码: )

二、授权期限:

上述授权权限自签发之日起至 年 月 日止。

三、特别声明:

上述代理事项两位受委托人均可独立代理。各受委托人在权限内代我方办理的上述事项我方均予以承认。

委托人(公章):

法定代表人:

年 月 日

展开阅读全文

篇6:有关个人授权委托书范本

范文类型:委托书,适用行业岗位:个人,全文共 448 字

+ 加入清单

授权人:

被授权人:

授权范围:授权 (被授权人名称或姓名)代表 (授权人名称或姓名)负责在中国境内接受法律文件送达,直至解除授权为止。

被授权人地址:

联系方式:电话 邮政编码

电子邮箱

授权人签字:

被授权人盖章或签字:

年 月 日 注:

1.此授权委托书适用于外商投资的有限责任公司和股份有限公司(法人企业),授权人为境外投资者。

2.被授权人可以是境外投资者、发起人在中国境内设立的分支机构或拟设立的公司(被授权人为拟设立公司的,公司设立后委托生效)或者其他境内有关单位或自然人。

3.“授权人签字”,投资者为企业、公司和其他经济组织的,写明全称并由法定代表人签字;投资者为自然人的,由本人亲笔签字。

4.“被授权人盖章或签字”,被授权人为企业、有关单位的,加盖其公章;

5.附被授权委托人的资格证明复印件,其中被委托人为企业和其他经济组织的,其资格证明文件复印件应加盖其公章。

6.变更被授权人应当签署新的《法律文件送达授权委托书》,及时向公司登记机关备案;被委托人变更名称、地址等事项也应及时向公司登记机关备案。

展开阅读全文

篇7:个人授权委托书格式范本

范文类型:委托书,适用行业岗位:个人,全文共 206 字

+ 加入清单

授权人:

被授权人:

我公司受政府相关部门授权委托,作为项目业主开发、建设经国家和省政府相关部门核准的建设项目。项目批复总投资额亿元人民币。

为确保完成项目的融资、建设、管理,经有限公司董事会研究决定:全权授权依照我国的相关法律、政策、规定,全权受托办理项目的融资、建设、管理。我公司对等在授权范围内的融资、建设、管理行为予以认可,并按融资、建设、管理的要求予以配合。

特此授权委托

委托单位(章)

法人代表:(签字)

年月日

展开阅读全文

篇8:授权委托书范本内容

范文类型:委托书,全文共 352 字

+ 加入清单

委托方:______________________

受托方:_______________身份证号码:_____________________________

委托方因业务需要,特委托__________在其与__________(付款企业)的业务往来中,作为_____(款项)的收款代理人。代收金额:人民币_____拾_____万_____仟_____佰_____拾_____元_____角_____分(¥ ___________________)。付款企业对以下受托方账号的付款行为即视为向委托方完成付款。委托方委托收款行为所引起的一切经济及法律责任与付款企业无关。

特此委托!

户 名:__________

账 号:__________

开户行:__________

日期:_________________

展开阅读全文

篇9:中国建设银行个人住房贷款保证合同_合同范本

范文类型:合同协议,适用行业岗位:银行,个人,全文共 1300 字

+ 加入清单

(中国建设银行)个人住房贷款保证合同

┌──────────────────────────────────┐

│ │

│ (中国建设银行)个人住房贷款 │

│ 保 证 合 同 │

│(封面) │

│合同编号: 年 字第 号 │

│ │

│保证人(甲方): 贷款银行(乙方): │

│住所: 住 所: │

│法定代表人: 法定代表人(或授权代理人) │

│电话: 电 话: │

│邮政编码: 邮政编码: │

│开户金融机构及账号: │

└──────────────────────────────────┘

为确保乙方与__________签订的__________号借款合同(以下简称借款合同)的履行,甲方愿意向乙方提供保证担保。甲、乙双方根据有关法律规定,经协商一致,约定如下条款:

第一条 甲方保证担保的贷款金额(大写)__________元,贷款期限自______年______月______日至_______年_______月______日。

第二条 本合同的保证方式为连带责任保证,甲方对借款合同中的借款人的债务承担连带责任。如借款人没有按借款合同约定履行或者没有全部履行其债务,乙方有权直接要求甲方承担保证责任。甲方应在接到乙方《催收到(逾)期贷款通知书》之日起_______个工作日内行履行清偿义务。

第三条 保证担保的范围:贷款金额(大写)___________元及利息、借款人应支付的违约金(包括罚息)和赔偿金以及实现贷款债权的费用(包括诉讼费、律师费等)。

第四条 保证期间:自本合同生效之日起至__________止。

第五条 本合同的效力独立于被保证的借款合同,借款合同无效并不影响本合同的效力。

第六条 保证期间,借款合同的当事人双方协议变更借款合同除贷款利率以外的其他内容,应当事先取得本合同甲方的书面同意。

第七条 保证期间,甲方发生机构变更、撤销或其他足以影响其保证能力变故,甲方应提前一天书面通知乙方,本合同项下的全部义务由变更后的机构承担或由甲方在__________日之内落实为乙方所接受的新的保证人。

第八条 保证期间,乙方有权对甲方的资金和财产状况或个人经济收入情况进行监督,有权要求甲方提供其财务报表或经济收入证明等资料,甲方应如实提供。

第九条 保证期间,甲方不得向第三方提供超出其自身负担能力的担保。

第十条 发生下列情况之一,乙方有权要求甲方提前承担保证责任,甲方同意提前承担保证责任:

共2页,当前第1页12

展开阅读全文

篇10:银行个人授权委托书

范文类型:委托书,适用行业岗位:银行,个人,全文共 503 字

+ 加入清单

委 托 人:__________ ,性别:__________ ,民族:__________ ,出生日期:__________ _____年 _____月 _____日,身份证号码:__________ ,住址为 ,联系方式:__________ 。

受委托人:__________ ,性别:__________ ,民族:__________ ,出生日期:__________ _____年 _____月 _____日,身份证号码:__________ ,住址为 ,联系方式:__________ 。

委托原因及事项:__________

本人于 _____年 _____月 _____日,因 被关押于 监狱,不能亲自领取扣押在 的私人物品。现本人委托受委托人作为本人的合法代理人代表本人领取上述私人用品,对受委托人在办理上述事项的过程中所签署的有关文件,本人均予以认可,并承担相应的法律责任。

委 托 人(签字、捺印):__________ 受委托人(签字、捺印):__________

_____年 _____月 _____日 _____年 _____月 _____日

特此请求

监狱批准并盖章:__________

展开阅读全文

篇11:房屋租赁授权委托书格式范本

范文类型:委托书,全文共 723 字

+ 加入清单

委托物业帮办协议

合同编号:

委托方(以下简称甲方):

受托方(以下简称乙方):

甲、乙双方根据《中华人民共和国委托合同法》,在平等、自愿的原则上签定本协议。

一、乙方有义务对甲方的房屋及相关的资信严格保密。

二、甲方自愿将坐落于 的房屋(以下简称该房屋),产权属于 的房屋全权委托乙方办理物业管理事宜,以后有关此房屋的物业管理事宜全部由乙方负责。

该房屋基本情况:家具,设施,租房合同,等见附件.

三、甲乙双方商定的委托期为 , 自 年 月 日至 年 月 日止。在此期间,甲方需将该房屋的合法有效产权凭证复印件,房主本人的身份证等复印件,交给乙方保管或向乙方出示正本。

四、乙方负责按《租房合同》要求的日期,向租客收取房租(按租客需要提供收据或发票,如提供发票金额收取税费10%)并将房租转交给甲方。租客如不按时交租,乙方有责任按租约及时追讨,直至租客交租或搬出。

五、当租客需要修理该房屋内部的设备。如洁具、水龙头、水管,灯泡等。乙方应及时赶到修理(所需费用由甲方负责)。

六、1.在委托期间,甲方应支付委托费用 元/月,上述费用可从乙方代收的租金中扣除或由甲方直接交给乙方。直至合同终止。

2.如房客提前解除合同,甲方已付的费用不予退回,乙方应协助甲方向房客追究违约责任。

3.如乙方没有及时履行甲方指示的事宜,造成直接经济损失。甲方有权中止委托。

七、甲方应保证房屋及承租人符合如下条件,否则造成一切纠纷及损失由甲方自行负责:

1.甲方应保证此房屋没有使用及产权纠纷。

2.甲方保证此房屋各项附属设施无欠费、损坏。

3.甲方对承租人的信用负责。

4.甲方应如期支付委托物业帮办费用。

八、此合同委托期满后,如不另行续约则自动终止。

甲方: 乙方:

代表人: 代表人:

地址: 地址:

展开阅读全文

篇12:关于个人授权委托书格式范本

范文类型:委托书,适用行业岗位:个人,全文共 203 字

+ 加入清单

_______单位:

本人因_________原因不能亲自到________办理_______事项,兹授权委托 _______先生/女士处理代办事项。委托人在权限范围内年签署的一切有关文件,我均承认。由此所造成的一切责任均由本人承担。

委托人(签名或盖章)_________被委托人(签名)_________

委托人身份证号码_________ 受托人身份证号_________

委托人_________

年 月 日

展开阅读全文

篇13:2024最新公司授权委托书范本

范文类型:委托书,适用行业岗位:企业,全文共 277 字

+ 加入清单

授权委托书声明:我 系 南京江宁经济技术开发区市政工程有限责任公司 的法定代表人,现授权委托 南京江宁经济技术开发区市政工程有限责任公司混凝土分公司 的 张振国(业务经理) 为我公司签署本工程已递交的投标文件内容我均承认。

代理人无转委托权,特此委托。

代理人:_____________性别:____________年龄:__________

身份证号码:________________职务:__________________

投标人:

南京江宁经济技术开发区

市政工程有限责任公司混凝土分公司

法定代表人:(签字或盖章)

授权委托日期: **年 X 月 X 日

展开阅读全文

篇14:中国建设银行个人消费借款合同_合同范本

范文类型:合同协议,适用行业岗位:银行,个人,全文共 1888 字

+ 加入清单

中国建设银行个人消费借款合同

合同编号:___________

贷款人:中国建设银行

住所:___________________________________________

联系电话:_______________________________________

传真号码:_______________________________________

借款人姓名:_____________________________________

工作单位:_______________________________________

家庭住址:_______________________________________

联系电话:_______________________________________

还款账号:_______________________________________

保证人:_________________________________________

住所:___________________________________________

通讯地址:_______________________________________

电话:___________________________________________

存款金融机构及账号:_____________________________

传真号码:_______________________________________

出质人:_________________________________________

住所:___________________________________________

通讯地址:_______________________________________

电话:___________________________________________

开户金融机构及账号:_____________________________

传真号码:_______________________________________

抵押人:_________________________________________

住所:___________________________________________

通讯地址:_______________________________________

电话:___________________________________________

开户金融机构及账号:_____________________________

借款人(以下称甲方):___________________________

贷款人(以下称乙方):___________________________

甲方因____________________需要,向乙方申请____________________贷款,乙方经审查同意发放贷款。甲乙双方根据《中国建设银行个人____________贷款管理办法》,经协商一致,订立本合同。

第一条 借款用途

(一)消费人或使用受益人:____________________。

(二)借款用于________________________________。

(三)指定的商户或单位:______________________。

第二条 借款金额

人民币(大写) _______________________________。

第三条 借款期限

本合同约定借款期限为__________年,自乙方将借款划入到本合同规定账户之日起计算,即(或)从________年_______月____日至________年____月____日。

第四条 放款条件

本合同项下的担保合同生效后,乙方将借款划入到本合同规定账户。

第五条 贷款支用

(一)双方约定在本合同生效后______个工作日内办理贷款支用。

(二)贷款支用方式:甲方同意乙方将贷款划入下述账户:

1.账户名称:______________,账号:____________________。

2.账户名称:______________,账号:____________________。

3.账户名称:______________,账号:____________________。

第六条 借款利率

(一)双方约定月利率为__________________。

共4页,当前第1页1234

展开阅读全文

篇15:法人授权委托书最新范本

范文类型:委托书,适用行业岗位:法人,全文共 301 字

+ 加入清单

X有限公司

法人授权委托书

第 号

联系单位:

受委托人: (性别: 年龄: 职务: ) 委托范围:联系、洽谈 工程业务,参加招投标事宜。 委托权限:在委托范围内,依照国家有关法律、法规及法定程序全权处理。 委托期限:年 月 日至 年 月 日

年 月 日

X有限公司

法人授权委托书

[ ]第 号

兹有我单位 同志(性别: 年龄: 职务: )代表我方与贵单位联系、洽谈及建设 工程业务。法人授权委托书委托范围:联系、洽谈、建设工程业务。

授权权限:在委托范围内,依照国家有关法律、法规及法定程序全权处理。

有效期限: 年 月 日至 年 月 日 代理人无转委托权,特此委托!

此致

敬礼

法人单位(盖章) 法人代表(盖章)

年 月 日

展开阅读全文

篇16:个人授权委托书格式_个人授权委托书范本

范文类型:委托书,适用行业岗位:个人,全文共 282 字

+ 加入清单

委托人姓名: _________身份证号:_________

地址:_________

联系电话:_________ 邮编:_________

受委托人姓名:_________ 性别:_________ ,工作单位:__________________ 地址: __________________,身份证号:_________

联系电话: _________邮编:_________

委托人委托上列受委托人在委托人与 (单位、个人)的 业务中,作为委托人的取货代理人,其代理权限为全权代理,即:全权收取委托人有权从(单位、个人)收取的全部货物。

委托人:

受委托人:

年 月 日

展开阅读全文

篇17:建设工程招标代理委托合同_合同范本

范文类型:委托书,合同协议,适用行业岗位:工程,招投标,全文共 1076 字

+ 加入清单

建设工程招标代理委托合同

招代字()第__03__号

项目名称:

委托单位(甲方):(公章)

代理单位(乙方): (公章)

合同签订日期:XX年3月01日

本合同双方:

委托单位(甲方):

代理单位(乙方):

委托方将 杭州某花园社区排屋高层建设 项目的招标事宜委托乙方代理,依据《中华人民共和国招标投标法》及有关法律、法规的规定,合同双方经协商一致,签订本合同。

一、代理业务的内容、形式:

1、甲方委托乙方组织建设工程招标活动。

2、工程概况:

3、本次招标范围 :

(1)招标代理的内容:填写申请表格,编制招标文件(包括编制资格预审文件);审查投标人资格;组织投标人踏勘现场和答疑;组织开标、评标、定标;提供招标前期咨询等业务。

(2)招标代理的形式:

二、工作条件和协作事项:

1、建设工程规划临时许可证、建设项目资金来源证明等(详见《办理建设工程招标投标需提交的资料》清单)。

2、委托方提供能够满足施工,标价计算要求的施工图纸及技术资料;或者经符合资质条件的工程造价咨询机构编制的建设项目投资预概算。

3、乙方代理过程中,遵守国家、地方有关工程建设招标、投标法规,坚持公开、公平、公正和诚实信用的原则,按照有关程序规定进行,接受招标监督管理部门的监督。

4、委托代理人在签订本合同时,应出具委托证书。

三、委托期限:

本合同自签订之日起执行,中标通知书签发后自行废止。

四、费用支付方式及日期:

1、本工程造价为人民币_______(大写),收取代理费用合计人民币_______(大写)。付款方式为现金或转账,代理费用应在开标前全部付清。代理费用不包含编制标底的费用、资格预审及评标专家费用。(收费标准:按国家计委计价格[]1980号)

2、投标单位购买标书每份工本费计人民币_______元(大写),所得归乙方。

五、违约责任:

1、双方都必须严格遵守签订的代理合同条款、不得违约;

2、委托方应提供真实可靠的相关资料,及按第四款第一条约定支付代理费用,否则一切责任由委托方自负。

3、双方在合同执行过程中出现争议,可协商解决,也可由相关部门进行调解。

4、双方对代理合同条款变更时必须另签补充合同条款,补充合同条款作为本代理合同的组成部分与主合同具有同等法律效力。

5、本合同一式三份,甲方一份,乙方一份,报招标管理机构一份。

六、双方协议的其他条款:

委托方(甲方): 代理方(乙方):_______工程招标代理有限公司

法定代表人(签章): 法定代表人(签章):

单位地址: 单位地址:

联系电话: 联系电话:

邮政编码: 邮政编码:

开户银行: 开户银行:

银行帐号: 银行帐号:

签定日期:XX年03月01日

展开阅读全文

篇18:法人授权委托书格式范本_委托书_网

范文类型:委托书,适用行业岗位:法人,全文共 544 字

+ 加入清单

法人授权委托书格式范本

法人委托书是相对于个人委托书的一种授权委托书。 注意区分一个概念,法人不是法定代表人,法定代表人是个人,如一个公司的董事长,而法人是单位,是法律上拟制的人,是相对于自然人的另一类法律主体。以下是小编为大家收集的关于法人委托书的范本欢迎大家借鉴!

法人委托书范本

本人 是 公司法定代表人,现授权委托 (身份证号)为本公司资质申报业务负责人,全权负责本公司的资质申请材料报送、审查意见反馈、资质证书领取、文件签收等事项。

受委托人无转委托权。

委托有效期: 年 月 日至 年 月 日止。

法定代表人手机号码:

受委托人手机号码:

法定代表人签字:

公司公章

年 月 日

法人委托书范本

兹有我单位×××同志(性别:× 职务:××××身份证号××××××××××××××××××)受我委托到你处办理人事代理等相关事宜,产生的法律责任由我单位承担。

兹委托×××(姓名、性别、年龄、职务)代表本企业为×××(项目名称)的代理人,其权限如下:

本人 (姓名) 是 (甲单位名称) 的法定代表人,现授权我单位 (姓名) (身份证号: (身份证号))为正式合法的代理人。该代理人有权在 (项目名称) 项目中,以 (甲单位名称)的名义并代表我单位全权处理投标报名相关事宜。

法定代表人签字:

公司公章

年 月 日

展开阅读全文

篇19:工程建设招标投标合同投标银行保证书_合同范本

范文类型:合同协议,保证书,适用行业岗位:工程,招投标,银行,全文共 606 字

+ 加入清单

工程建设招标投标合同(投标银行保证书

鉴于_________(投标人名称)已于_________年_________月_________日(日期)提交了建设_________(合同名称)的投标书(以下称投标书)。

根据本文件,兹宣布,我行_________(以下称银行)向业主立约担保支付_________的保证金。本保证书对银行及其继承人和受让人均有约束力。

银行名称(盖章):_________

_________年____月____日

附件

本保证义务的条件是:

(1)如果投标人在投标书中规定的投标书有效期内撤回投标书;或如果投标人在投标书有效期内接到业主所发的中标通知书后;

(2)未能或拒绝根据投标须知的规定,按要求签署合同协议书;或未能或拒绝接投标须知的规定,提供法的保证金。

我行保证在收到业主第一次书面要求后,即对业主支付上述款额,无须业主出具任何证明,只需在其书面要求中说明条件是在此要求业主将注意到索款是由于出现了上述条件中的一种或两种,并具体说明情况。本保证书在投标须知规定的有效期或在该日期前已延长的投标书有效期后30天(会第30天)内有效。延长投标书有效期无须通知银行,任何索款要求应在上述日期前交到银行。

银行名称:_________(盖章)

证人:_________(签字)

证人所在单位:_________

单位地址:_________

日期:_________年_________月_________日

展开阅读全文

篇20:建设工程勘察设计委托协议_合同范本

范文类型:委托书,合同协议,适用行业岗位:工程,设计,全文共 1249 字

+ 加入清单

建设工程勘察设计委托协议

委托方:_________(以下简称甲方)

承包方:_________(以下简称乙方)

依照《中华人民共和国合同法》、《建设工程勘察设计合同条例》的有关规定,经双方协商一致,签订本合同。

第一条 甲方委托乙方承担的工程勘察设计项目名称、内容、规模与范围详见委托勘察设计项目表(见附件)。

第二条 乙方根据委托的勘察设计项目,和主管部门的规定,按初步设计(方案设计)和施工图设计,分阶段进行。在具备各个阶段设计条件时,双方签订阶段协议书,具体规定甲方应提交的勘察设计基础资料的名称和日期,乙方需交付的勘察设计文件资料的名称和日期,做为本合同的附件。

第三条 双方责任

1.甲方责任

(一)按照各设计阶段协议书的规定,向乙方提供有关建设项目审批文件和勘察设计基础资料,并对提供的时间、进度与资料的可靠性负责。

委托勘察测绘工作的,在勘测工作开展前,应提出勘察测绘技术要求及标有拟建工程准确位置的地形图,圈定测量范围的平面图。土地使用证的复制件,并安排好现场工作条件。

委托初步设计应提出以下资料:①经过批准的设计任务书,②选址报告;③规划要求;④原料(或经过批准的资源报告)、燃料、水、电、运输等方面的协议文件;⑤经批准的工艺设计资料,民用项目的使用要求;⑥能满足初步设计要求的勘测资料,需要经过科研取得的技术资料、人防、消防、劳动保护、工业卫生、环境保护预测资料等。

委托施工图设计时,应提供经过批准的初步设计文件和满足施工图设计要求的勘察资料,施工条件,以及有关设备的技术资料。

(二)收到乙方交付的设计文件后,应及时报请有关部门审查,审查意见用书面转送给乙方。组织施工单位与设计单位共同商定有关技术条件,组织设计技术交底,通知乙方参加试车考核及竣工验收。

(三)在勘察设计人员进入现场作业或配合施工时,应负责提供必要的工作和生活条件。

(四)委托配合引进项目的设计任务,从询价、对外谈判、国内外技术考察直至建成投产的各阶段,应吸收承担有关设计任务的单位参加。

(五)维护乙方的勘察设计文件,不得擅自修改,未经乙方同意不得转让给第三方重复使用。对转让后重复使用的项目,乙方不负任何技术责任。

(六)按照国家和本市有关规定,按时付给勘察、设计费。

2.乙方责任

(一)按照甲方提供的建设项目审批文件和设计基础资料编制设计文件。根据各阶段协议书的规定,按期交付各阶段的设计文件(初步设计六份,施工图设计八份),并保证质量。需增加设计文件的份数时另行收费。需复制供应标准图时另行收费。

(二)乙方要根据批准的设计任务书或上一阶段设计的批准文件。以及有关设计技术经济协议文件,设计标准、技术规范、规程、定额等,提出勘察技术要求和进行设计,并按合同规定的进度和质量提出设计文件(包括概、预算文件、材料、设备清单)。

(三)初步设计经上级主管部门审查后,在原定任务书范围内的必要修改,由乙方负责。原定任务书有重大变更而需重作设计时,须有设计审批机关或设计任务书批准机关的意见书,经双方协商,另订合同。

共3页,当前第1页123

展开阅读全文